W9128F25RA050 GDSM Stoplog Seal Mod Specifications 2of3.pdf

SPECIFICATIONS

(For Construction Contract) Solicitation Number W9128F25RA050

Garrison Dam Spillway Modification Modifications to Existing Stoplogs Garrison Dam, ND

June 2025

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 00 CONSTRUCTION GENERAL

01 20 00 PRICE AND PAYMENT PROCEDURES

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

DIVISION 05 - METALS

05 59 20 FABRICATION OF HYDRAULIC STEEL STRUCTURES

DIVISION 09 - FINISHES

09 97 02 PAINTING: HYDRAULIC STRUCTURES

APPENDICES

APPENDIX A PHOTOS

APPENDIX B EXISTING CONDITION DRAWINGS

-- End of Project Table of Contents --

Garrison Spillway Stoplog Seal Modification - Garrison Dam, ND GR00119

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 SUBMITTALS

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 STOPLOG TRANSPORTATION

1.3.1 Final Inspection

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Meeting Minutes

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes modifications to the existing Garrison Dam Spillway Stoplogs and incidental related work. The base scope is the modification of (8) stoplogs. There are contract options for the modification of (10) additional stoplogs; see pricing schedule for details.

The existing seals and springs will be replaced by modified seals, springs, and associated detailing. The major work activities are as follows:

a. Pre-removal inspection, removal from the dam and transport to shop: All stoplogs must be inspected by Contractor/USACE prior to removal from site. The stoplogs must be loaded and transported from Garrison Dam’s Spillway to the Contractor’s fabrication shop where all modifications are to be performed. This work includes rigging and handling by the contractor to remove the stoplogs from the machinery platform of spillway monoliths M31 and M32 (NW side of the spillway).

Photos of the pick-up/drop-off location are provided in Appendix A of these specifications.

b. Steel Fabrication/Welding and Spring Replacement as indicated on the contract drawings: Work will include demolition of existing steel components and fabrication of new seal and spring related components.

Welding per AWS D1.5 on Fracture Critical Members (FCM) is required per section 05 59 20 FABRICATION OF HYDRAULIC STEEL STRUCTURES.

c. Install New Seals and Springs as indicated on the contract drawings.

d. Painting: After the steel modifications are complete, paint per specification section 09 97 02 PAINTING: HYDRAULIC STRUCTURES. All damage to the stoplogs must be repaired at the Contractor's expense.

e. Return Stoplogs to Dam and Final Inspection: Return the stoplogs to the location where they were picked up. Provide rigging and equipment to place stoplogs in the machinery platform of M31 and M32.

The Contracter and the Contracting Officer must perform a final

SECTION 01 11 00 Page 2 insepction upon return of the stoplogs.

1.2.2 Location

The stoplogs are stored at the Garrison Dam Spillway. Refer to the contract drawings for Project Location Map, the Access Route Location and the Stoplog Loading Area. Work on the stoplogs must occur at the Contractor's shop.

1.3 STOPLOG TRANSPORTATION

The Contractor is required to transport the stoplogs from the dam to the Contractor's fabrication shop and return them after shop work is complete.

The stoplogs will be positioned on the north side of the maintenance platform of the east abutment under the bridge and monorail hoist by the Government. Refer to the drawings C-101 and C-102 and the photos in Appendix A of these specifications for the pick-up/drop-off location. The completed stoplogs MUST be delivered to the same location they were in when picked up by the Contractor to ensure the monorail crane can properly attach to them.

1.3.1 Final Inspection

The Government must perform an inspection upon final placement of a completed stoplog in the Dam maintenance platform by the Contractor to document any damages from transport that the Contractor must remedy. The Contractor must participate in this inspection with the Government for concurrence. Notify the Contracting Officer at least 28 days prior to return of the stoplogs.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

1.6 PUBLIC ROADS

1.6.1 Temporary Traffic Control (TTC)

1.6.2 Operations

1.6.2.1 Flaggers

1.7 COOPERATION WITH OTHER CONTRACTORS

1.8 ORDER OF WORK

1.9 WINTER WORK

1.10 COORDINATION AND OUTAGES

1.11 SUBMITTALS

1.12 WARRANTY OF CONSTRUCTION (MAR 1994)

1.13 TELEPHONE/INTERNET

1.14 USE OF GOVERNMENT EQUIPMENT

1.14.1 Spillway Monorail Crane Operation

1.14.2 Working Hours

1.14.3 Hours of Use and Overtime Payment

1.15 AS-BUILT DRAWINGS

1.16 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to FAR clause 52.236-10 entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the

SECTION 01 12 00 Page 2 work.

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.6 PUBLIC ROADS

1.6.1 Temporary Traffic Control (TTC)

The Contractor shall be responsible for the safe control of traffic on all haul and access roads used primarily for the work under these specifications and at their crossings with roads used by others. The Contractor shall, at the Contractor's own expense, furnish all personnel, and traffic control devices necessary for the safe movement of all road users through or around Temporary Traffic Control zone. Traffic control plans, including a listing of equipment and its employment, shall be submitted for review and approval prior to construction.

1.6.2 Operations

When operations are being conducted near a U. S. or State Highway or when construction equipment is being used on or adjacent to such highway, the Contractor shall furnish all necessary traffic control devices and personnel to provide safe and effective movement of all road users through or around Temporary Traffic Control zone as required by MUTCD All required state and/or local permits shall be obtained at the Contractor's expense in advance and shall be provided to the COR. The highways and streets shall be kept open at all times.

1.6.2.1 Flaggers

The Contractor shall provide flaggers when:

a) Construction equipment and/or vehicles are blocking the roadway making it difficult for vehicles to pass or see or due to terrain.

b) One-way traffic is required thru a construction zone.

c) Trucks are pulling onto and/or off of a roadway or operating at a reduced speed causing a hazardous situation for drivers.

d) Anytime the Contractor feels that road users are at risk due to Construction activity.

Flagger shall have all qualifications, high-visibility safety apparel, and appropriate hand-signaling devices in accordance with MUTCD requirements.

The flagger shall be properly trained as required by the state. The Contractor shall furnish all necessary traffic control devices to establish appropriate TTC zone when the Flagger Control is utilized.

1.7 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of others working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits.

SECTION 01 12 00 Page 3

The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.8 ORDER OF WORK

The sequence of operations shall be maintained so that the maximum amount of work may be done under favorable working conditions in accordance with the completion time set forth in Section 00 73 00 SPECIAL CONTRACT REQUIREMENTS, paragraph: Commencement, Prosecution, and Completion of Work. The Contractor shall submit for approval, within 15 days after receipt of notice to proceed a narrative description of the proposed method s of operation.

1.9 WINTER WORK

No separate payment will be made for winterizing or other protective measures that are required for the Contractor to maintain the scheduled progress. Contractor to not deliver logs 31 October to 15 April of any given year due to winter weather conditions. This must be incorporated into the Contractor's schedule to ensure completion of work on time.

1.10 COORDINATION AND OUTAGES

The Contractor's employees shall not open, close or tamper with switches, valves or control devices for existing installed equipment. Only Government operating personnel will be authorized to open or close existing switches, valves and control devices to enable the Contractor to make connections or modifications to existing equipment. Work shall be coordinated and scheduled to reduce the "Down" time of operating equipment or systems to a minimum.

1.11 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-AO

Construction Right-of-Way

(Right-of-Way Agreements)

Temporary Traffic Control (TTC); G, AO

SD-02 Shop Drawings

Care of Water; G-AO

SD-11 Closeout Submittals

Warranty of Construction

SECTION 01 12 00 Page 4

(List of warranties with copy of each)

1.12 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable

SECTION 01 12 00 Page 5 for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.13 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.14 USE OF GOVERNMENT EQUIPMENT

1.14.1 Spillway Monorail Crane Operation

Government personnel only will operate the spillway monorail crane. The Contractor will be responsible for furnishing and performing all rigging for all lifts. The Government must inspect and approve all rigging prior to performing the lift. The Contractor will be responsible for all off-loading, movement, and loading of required construction equipment. .

1.14.2 Working Hours

The Contractor shall properly prepare and plan all lifts such that Government operators are required for a minimum number of occasions. Use of the crane will only be during normal Government working hours. A crane operator will not be furnished on a standby basis. The Contractor shall coordinate with the Contracting Officer, in writing 24 hours in advance, the need for a crane operator. The Government will operate the crane during the normal daytime working hours of 7:00 am to 4:30 pm Monday thru Thursday. The crane will be unavailable for use 31 October through 15 April. {If operation after hours is required, the Contractor shall make arrangements for payment to the Government (see paragraph below).}

1.14.3 Hours of Use and Overtime Payment

The Contractor will be allowed 8 hours of crane time during the life of the Contract. If more than 8 hours is required, the Contractor will be charged $100.00 per hour for the additional use.

1.15 AS-BUILT DRAWINGS

The Contractor shall provide a marked-up half size drawing to show actual work performed to include necessary sketches, modification drawings, shop drawings and notes. Red ink is to be used for additions and deviations from the contract. Green ink is to be used to indicate work deleted from the contract. The drawings shall be maintained by the Contractor as the work progresses and available for review by the government representatives. The as-built drawings shall be submitted for approval at the completion of the project. Final as-built drawings shall be submitted as CAD files, incorporating all changes from the contract. A coordination meeting shall be held with the contractor, COR, and Garrison CAD technician to ensure as-builts are completed correctly. Drawings expected to be updated include new seal design drawings and S-001 through S-004 as shown in Appendix B. PDF versions of these drawings will be provided to the contractor for updating in CADD.

SECTION 01 12 00 Page 6

In accordance with the clause "Payment Under Fixed - Price Construction Contracts", $25,000 will be withheld from payment for the creation of As-Built Drawings until Final As-Built Drawings are delivered to and accepted by the COR.

1.16 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1630 hrs Monday through Thursday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. Additionally, the Contractor will not have access to the site 31 October to 15 April of any given year.

These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 7

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 CONTRACT COST BREAKDOWN

1.2 SINGLE JOB PAYMENT ITEMS

1.2.1 CLIN 001: Mobilization and Stoplog Retrieval

1.2.1.1 Payment

1.2.1.2 Unit of Measure

1.2.2 CLIN 002: Modification of Stoplogs

1.2.2.1 Payment

1.2.2.2 Unit of Measure

1.2.3 CLIN 003: Stoplog Return, Final Inspection, and Touch-Up

Painting

1.2.3.1 Payment

1.2.3.2 Unit of Measure

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 20 00 Page 1

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This Contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

1.2 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this Contract for which Contract job payments will be made are listed in the PRICING SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.2.1 CLIN 001: Mobilization and Stoplog Retrieval

1.2.1.1 Payment

Payment will be made for all labor, materials, and equipment, including crane, to retrieve (8) stoplogs from Garrison Dam's Spillway maintenance bay and haul to Contractor's fabrication shop. This CLIN includes an Initial Inspection and documentation of Stoplogs.

1.2.1.2 Unit of Measure

Unit of measure: Job.

1.2.2 CLIN 002: Modification of Stoplogs

1.2.2.1 Payment

Payment will be made for all labor, materials, and equipment for modifying

(8) stoplogs per the plans and specifications. This CLIN also includes any incidental or other costs not affiliated with other basic CLINs.

1.2.2.2 Unit of Measure

Unit of measure: Job.

SECTION 01 20 00 Page 2

1.2.3 CLIN 003: Stoplog Return, Final Inspection, and Touch-Up Painting

1.2.3.1 Payment

Payment will be made for all labor, materials, and equipment, including crane to haul (8) stoplogs from Contractor's shop to Garrison Dam's Spillway maintenance bay. This CLIN includes coordinated final inspection with Government, documentation, and any repairs to paint deemed as the Contractor's responsibility from handling.

1.2.3.2 Unit of Measure

Unit of measure: Job.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 20 00 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.6 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

1.7 CONTRACT DRAWINGS AND SPECIFICATIONS

1.7.1 SETS FURNISHED

1.7.2 DISTRIBUTION

1.7.3 NOTIFICATION OF DISCREPANCIES

1.7.4 OMISSIONS

1.8 SUBMITTALS

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

1.9.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.10 AVAILABILITY AND USE OF UTILITY SERVICES

1.11 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.12 INSURANCE REQUIRED

1.13 SUPERVISION

1.13.1 Superintendent Qualifications

1.13.2 Minimum Communication Requirements

1.13.3 Duties

1.13.4 Non-Compliance Actions

1.14 PRECONSTRUCTION CONFERENCE

1.14.1 Attendees

1.15 CONTRACTOR QUALITY CONTROL (CQC)

1.16 NONDOMESTIC CONSTRUCTION MATERIALS

1.17 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.18 PARTNERING

1.18.1 Team-Led (Informal) Partnering

1.19 PROFIT

1.20 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.21 DRAWING SCALES

1.22 CYBERSECURITY DURING CONSTRUCTION

1.22.1 Contractor Computer Equipment

1.22.1.1 Operating System

1.22.1.2 Anti-Malware Software

1.22.1.3 Passwords and Passphrases

1.22.1.4 Contractor Computer Cybersecurity Compliance Statements

PART 2 NOT USED

SECTION 01 30 00.24 Page 1

PART 3 NOT USED

SECTION 01 30 00.24 Page 2

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.usace.army.mil/Cost-Engineering/EP1110-1-8/ .

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a.Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. Use an electronic payroll service capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

SECTION 01 30 00.24 Page 3

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. Provide this durable record copy of data from the electronic payroll processing system to the Government during contract closeout.

d. Include all Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service in the Contractor's price for the overall work under the contract. Do not include the costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services as a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS). After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site:

SECTION 01 30 00.24 Page 4 https://www.cpars.gov .

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. General security requirements and guidance:

The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts.

The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations.

Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures.

The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures-this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

2. Not Used

3. Physical security and access control requirements:

All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned

SECTION 01 30 00.24 Page 5 property shall comply with key and lock control procedures of the RA.

4. Not Used

5. Not Used

6. Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something):

All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

This training shall be completed within 10 days prior to mobilization and within 30 calendar days of new employees commencing performance with the results reported to the COR. (submittal: iWATCH and/or CorpsWatch Training Sign In Sheets).

7. Not Used

8. Not Used

9. Not Used

10. Not Used

11. Not Used

12. Not Used

13. Escorting in classified and/or sensitive areas: In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas. There is no classified information or operations associated with this contract.

14. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

15. Not Used

16. Not Used

1.6 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

No work will be required at the construction site during the period 31

SECTION 01 30 00.24 Page 6

October through 15 April inclusive. Due to anticipated weather impacts, the spillway bridge overhead crane will not be available to move the stoplogs during this no work period. The days in this period have been included in computing the calendar days for completion of the work. The Contractor may perform work at the site during all or any part of this period upon giving prior written notice to the Contracting Officer.

Working during this non-work period requires approval by the Contracting Officer. No time extensions will be granted for delays during this period.

1.7 CONTRACT DRAWINGS AND SPECIFICATIONS

1.7.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.7.2 DISTRIBUTION

The Government will provide the Contractor with Adobe Acrobat.pdf contract drawings and conformed specification sets.

1.7.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in lieu of scale measurements.

Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34".

If any other size drawings are furnished or plotted adjust the scales accordingly. Advise sub-contractors of the above. Compare all drawings and verify the figures before laying out the work and take responsibility for any errors which might have been avoided thereby.

1.7.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work. Perform as if fully and correctly set forth and described in the drawings and specifications.

1.8 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

SECTION 01 30 00.24 Page 7 iWATCH and/or CorpsWatch Training Sign In Sheets ;

Sign In Sheets for all employee training required for iWATCH and/or CorpsWatch Training, see OPSEC paragraphs, subparagraph 6

E-Verify ;

Provide E-Verify completion sheets required for OPSEC, see OPSEC paragraphs, subparagraph 14

Contractor Computer Cybersecurity Compliance Statements; G, RO

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Project Engineer.

1.9.2 PAYMENT FOR MATERIALS STORED OFFSITE

a. As allowed under (FAR) 52.232-5 "Payments Under Fixed Price Construction Contracts", the Administrative Contracting Officer, at their discretion, may authorize progress payments for any material stored off-site provided:

(1) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract,

(2) Material is stored in such a manner to protect it from damage, fire, theft, etc .

(3) The Contractor provides evidence of insurance for material, and,

(4) Material is clearly identified and delineated by contract number for use on the applicable project.

b. The Administrative Contracting Officer reserves the right to inspect any off-site material prior to authorizing progress payments. Provide paid invoices listing the value of material and labor incorporated in the items.

1.10 AVAILABILITY AND USE OF UTILITY SERVICES

a. The Government will make available, from existing outlets and supplies, all reasonably required amounts of electricity required in the performance of the work without charge to the Contractor. The spillway has 120v and/or 480v 3 phase power available for Contractor use. To use the 480v power, the contractor must procure their own Meltric DSN60-or the like-male plug. The Contractor must provide all extension cords, ladders, and any other tools, equipment and materials

SECTION 01 30 00.24 Page 8 needed to perform the contract.

b. Carefully conserve utilities furnished without charge. Limit use of utilities to what is needed to perform work. The Government will not allow the charging of electric vehicles owned or operated by the Contractor or subcontractors at Government charging stations. Install and maintain all necessary temporary connections and distribution lines in a workmanlike manner satisfactory to the Contracting Officer, pay all associated costs, and remove the same prior to final acceptance of the construction.

1.11 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with FAR 52.249-10 "Default: (Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 23 Feb 17 Mar 13 Apr 4 May 3 Jun 6 Jul 3 Aug 4 Sep 4 Oct 3 Nov 12 Dec 20

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must

SECTION 01 30 00.24 Page 9 acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.12 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.13 SUPERVISION

1.13.1 Superintendent Qualifications

Provide project superintendent with a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

For projects where the superintendent is permitted to also serve as the Quality Control (QC) Manager as established in Section01 45 00 QUALITY CONTROL, the superintendent must have qualifications in accordance with that section.

1.13.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract

SECTION 01 30 00.24 Page 10 work. In addition, if a Quality Control (QC) representative is required on the Contract, then that individual must also have fluent English communication skills.

1.13.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent is required to attend Red Zone meetings, partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.13.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time or excess costs or damages by the Contractor.

1.14 PRECONSTRUCTION CONFERENCE

Immediately after award, prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Conference . The conference must take place within 35 calendar days after award of the contract, but prior to commencement of any work at the site. The purpose of this conference is to discuss and develop a mutual understanding of the administrative requirements of the Contract including but not limited to: daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, quality control, schedule of prices or earned value report, shop drawings, submittals, cybersecurity, prosecution of the work, government acceptance, final inspections and contract close-out.

Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.14.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), Quality Control Manager and major subcontractors.

1.15 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00 QUALITY CONTROL.

1.16 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials…