A.2.11.4 W9128A22R0009 Am-0004 Specifications.pdf
PDF 97 KB Posted
- Solicitation number
- W9128A22R0009
About this file
This document contains specifications for a federal construction contract and details of a related federal contract opportunity. The specifications require contractors to carry bodily injury and property damage insurance and workers compensation insurance, including Defense Base Act insurance purchased through the mandatory USACE program. Contractors must report claims and injuries to the contracting officer. Time extensions may be granted for unusually severe weather following the schedule of anticipated delays. The contract opportunity is a solicitation to construct a concrete Rotary Wing Aircraft Parking Apron and supporting facilities at Wheeler Army Airfield in Hawaii. The estimated value is between $25-75 million. The acquisition will use lowest priced technically acceptable procedures, evaluating experience, past performance, technical approach, small business participation, and price. The prime contractor must maintain SAM registration.
View the file
Other files
Show all 11
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Section 01 90 00 (Am-0004)
(1) Bodily Injury: Minimum coverage of $200,000 per person and $500,000 per occurrence.
(2) Property Damage: Minimum coverage of $20,000 per occurrence.
The Contractor shall insert the substance of this clause in subcontracts under this contract that require work on a Government installation.
The Certificate Holder for both the Prime’s and Subcontractors' Certificates of Insurance shall be the U.S. Army Engineer District, Honolulu, Fort Shafter, Hawaii 96858-5440. [FAR 28.306 and 28.307-2]
[End of Statement]
S-28.14 WORKERS COMPENSATION INSURANCE (DEFENSE BASE ACT) - CONSTRUCTION (OCT
2009)
(a) This Special Contract Requirement supplements FAR Clause 52.228-3 Workers' Compensation Insurance (Defense Base Act).
(b) The contractor agrees to procure Defense Base Act (DBA) insurance pursuant to the terms of the contract between the U.S. Army Corps of Engineers (USACE) and CNA Insurance unless the contractor has a DBA self-insurance program approved by the Department of Labor. Proof of this self-insurance shall be provided to the Contracting Officer. The contractor shall submit proof of a valid DBA Insurance policy with CNA Insurance for the Prime and their Subcontractor's at every tier prior to performance of the contract. The current rate under the USACE and JCC-I/A contract is $6.00 per $100 of compensation for construction.
(c) The contractor agrees to insert a Special Contract Requirement substantially the same as this one in all subcontracts (at every tier) to which DBA is applicable.
(d) Should the rates for DBA insurance coverage increase or decrease during the performance of this contract, USACE shall modify the contract accordingly. However, the revised rates will not be applicable until the Contractor's or Subcontractor's DBA Insurance policy is due to be renewed.
(e) Premiums will be reimbursed only if coverage is purchased through the USACE mandatory requirements DBA contract administered by CNA Insurance and their Managing Broker, Rutherfoord International.
(f) Claims Reporting - The Contractor shall make timely Defense Base Act insurance claims on behalf of each employee who is injured or killed in the course of their employment under this contract, and shall ensure that similar language is in each Subcontractor's contract. The Contractor's Safety Officer shall, in addition to any other duties required to be performed under the contract, perform the following:
(i) Make timely Defense Base Act insurance claims on behalf of each employee who is injured or killed in the course of their employment under this contract; and
(ii) Make monthly written reports to the Contracting Officer, Administrative Contracting Officer, and the District/Center Safety and Occupational Health Manager, providing the names of each such injured or deceased employee, the circumstances surrounding each injury or death, the dates of each injury or death, the date the insurance claim was made on behalf of each employee, and the current status of each claim.
The District/Center Safety and Occupational Health Manager POC is:
John A. Alden John.A.Alden@usace.army.mil
Section 01 90 00 (Am-0004)
(g) Failure to comply and purchase Defense Base Act (DBA) Insurance in accordance with FAR Clauses
52.228-3 Workers' Compensation Insurance (Defense Base Act), from the U.S. Army Corps of Engineers mandatory Insurance Carrier/Broker (CNA Insurance/Rutherfoord International) for the Prime and all of the
Subcontractors at every tier, shall be considered a material breech and could cause your contract to be terminated for default/cause.
S-36.5 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER
1. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause entitled DEFAULT (FIXED-PRICE CONSTRUCTION). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:
a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.
b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.
2. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON 5 DAY WORK WEEK
LOCATION JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
CENTRAL OAHU To include sites from Fort Ruger through Fort Shafter to Pearl City
3 3 2 1 1 0 1 1 1 2 2 3
3. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 2, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled DEFAULT (FIXED-PRICE CONSTRUCTION). [ER 415-1-15, 31 Oct 89]
S-36.7 IDENTIFICATION OF EMPLOYEES
The Contractor shall be responsible for furnishing to each employee and for requiring each employee engaged on the work to display such identification as may be approved and directed by the Contracting Officer. All prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon the release of any
File details come from the government source that posted it. Updated .