A.2.11.4 W9128A21B0003 Am-0007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

FY20 Repair and Replace Vapor Recovery System, Underground Storage Tanks, and Piping at Gas Station AMR 880, Aliamanu Military Reservation, Oahu, Haw aii

See Continuation Page.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W9128A21B0003

X 9B. DATED (SEE ITEM 11)

17-Jun-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

Am-0007

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

05-Aug-2021

CODE

CONTRACTING DIVISION

USACE, HONOLULU DISTRICT

BLDG 230 (CECT-POH)

FT. SHAFTER HI 96858-5440

W9128A 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9128A21B0003 Am-0007

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

1. CHANGES TO SPECIFICATIONS. Attached hereto are revised pages/paragraphs to the specifications. The revision mark “(Am-0007)” is shown on each revised page.

a. REVISED SECTIONS. The following are revised pages to the solicitation. Changes are marked in “*” asterisks and bold.

Standard Form 1442 – Page 1 Section 00 10 00 – Page 2 Section 00 72 00 – Page 3

2. The bid opening date and time is extended to August 12, 2021, 3:00 PM Hawaii Standard Time (see Standard Form 1442, Page 1, Block 13A).

FY21 Repair and Replace Vapor Recovery System, Underground Storage Tanks, and Piping at Gas Station AMR 880, Aliamanu Military Reservation, Oahu, Hawaii

X

COLIN K WAKI 808-835-4393

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

17-Jun-2021

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______ 7 calendar days and complete it within ________ 400 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 12 Aug 2021 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 90 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIVISION

USACE, HONOLULU DISTRICT

BLDG 230 (CECT-POH)

FT. SHAFTER HI 96858-5440

W9128A

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

03:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL: TEL: FAX:

W9128A21B0003 2

(Am-0007)

Section 00 10 00 – Page 2 (Am-0007)

5. All Bidders shall provide one (1) copy of the entire bid on a CD within seven (7) calendar days after the date of bid opening.

6. The magnitude of the construction project is between $1,000,000 and $5,000,000.

7. SITE VISIT. The clauses at 52.236-2 Differing Site Conditions, and 52.236-3 Site Investigations and Conditions Affecting the Work, will be included in this contract. Accordingly, offerors are urged and expected to inspect the site where the work will be performed.

Participants will be required to obtain a day pass for installation access from Buckner Gate, Fort Shafter. All vehicles shall have a current registration, safety check, proof of insurance, and if renting a vehicle, the rental agreement. Please plan accordingly to ensure you have ample time to obtain a base pass to attend the site visit.

8. The performance of period stated in FAR Clause 52.211-10 remains unchanged. Due to the Building 880 Gas Station being active and there is a long lead time for the Underground Storage Tank (UST), the Contractor will not have access to the project site until proper documentation of the arrival of the UST on Oahu is provided to the Government. The minimum lead time for the Contractor to notify the Government of the UST arrival is 25 calendar days.

Section 00 72 00 – Page 3 (Am-0007)

52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.247-63 Preference For U.S. Flag Air Carriers JUN 2003 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Termination For Convenience Of The Government (Fixed-Price) APR 2012 52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) (Apr 2012) - Alternate I SEP 1996 52.249-10 Default (Fixed-Price Construction) APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 400 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,116.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

(a) Definitions. As used in this clause--

"Active duty wartime or campaign badge veteran," "Armed Forces service medal veteran," "disabled veteran," "protected veteran," "qualified disabled veteran," and "recently separated veteran" have the meanings given at Federal Acquisition Regulation (FAR) 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.