B.08 Solicitation Amendment - (W9127N24R0012 0005) BNBIPRQ24.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is to extend the Period of Performance and extend the proposal due date to 11:00 A.M. on 14-AUG-2024.

See Summary of Changes. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 30-Jul-2024

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9127N24R0012

X 9B. DATED (SEE ITEM 11)

10-Jun-2024

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

30-Jul-2024

CODE

USACE, PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204

W9127N 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127N24R0012

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 31-Jul-2024 11:00 AM to 14-Aug-2024 11:00 AM.

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569 FOB: Destination

960412

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

925 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0002 has been changed from:

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

CAGE

925 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0003 has been changed from:

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

CAGE

925 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0004 has been changed from:

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0005 has been changed from:

CAGE

850 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

CAGE

925 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0006 has been changed from:

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

The following Delivery Schedule item for CLIN 0007 has been changed from:

CAGE

670 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

CAGE

925 dys. ADC 1 BONNEVILLE LOCK & DAM PROJECT

ROBIN NORRIS

USACE PORTLAND DISTRICT

BONNEVILLE LOCK AND D

CASCADE LOCKS OR 97014-0150

(541) 374-4569

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than:

FINAL CONSTRUCTION PHYSICAL COMPLETION: No more than 925 days after notice to proceed. Should the Government execute optional CLIN 0005, FINAL CONSTRUCTION PHYSICAL COMPLETION will be extended by 180 days.

CONTRACT END DATE: No more than 120 days after FINAL CONSTRUCTION PHYSICAL COMPLETION.

The time stated for FINAL CONSTRUCTION PHYSICAL COMPLETION includes physical completion of all site work, site cleanup, and demobilization.

The time stated for CONTRACT END DATE includes completion of submission and approval of all requirements detailed in Sections 01 33 00 Submittal Procedures, 01 78 23.00 25 Operations and Maintenance Data, and 01 78 39.00 25 Record Drawings for final work document requirements.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed ten (10) days after contract award. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)