W9127N22R0020 P00002 Solicitation Amendment.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This amendment serves to update provide updated to the follow ing items;

1. Clause 52.211-10

2. Specification SECTION 01 22 00.00 25

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 12-Dec-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9127N22R0020

X 9B. DATED (SEE ITEM 11)

08-Nov-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

12-Dec-2022

CODE

USACE, PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204

W9127N 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127N22R0020

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

CHANGES TO SPECIFICATIONS

SECTION 01 22 00.00 25

Table of Contents for 1.4.3 which previously read;

1.4.3 Mobilization and Demobilization Season 3, CLIN 0003

Shall now read

1.4.3 Mobilization and Demobilization Seasons 3 and 4, CLIN 0003

Paragraph 1.4.2(b) which previously read;

b. Payment: Payment will be made at the Contract amount under CLIN 0003 as stated in Contract Clause 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (Dec 1991). Submit a schedule of mobilization and demobilization costs for approval prior to submitting the first request for payment.

Shall now read;

b. Payment: Payment will be made at the Contract amount under CLIN 0002 as stated in Contract Clause 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (Dec 1991). Submit a schedule of mobilization and demobilization costs for approval prior to submitting the first request for payment for Season 2 of construction.

Paragraph 1.4.3 which previusly read;

1.4.3 Mobilization and Demobilization Season 3, CLIN 0003

a. Measurement: Measurement will be made as a job for mobilizing and demobilizing all plant, equipment, fuel, supplies, materials, and personnel to and from the job site for a third work season.

This Contract Line Item Number (CLIN) applies to the Prime Contractor and all subcontractor mobilization and demobilization.

b. Payment: Payment will be made at the Contract amount under CLIN 0005 as stated in Contract Clause 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (Dec 1991). Submit a schedule of mobilization and demobilization costs for approval prior to submitting the first request for payment.

Shall now read;

1.4.3 Mobilization and Demobilization Seasons 3 and 4, CLIN 0003

a. Measurement: Measurement will be made as a job for mobilizing and demobilizing all plant, equipment, fuel, supplies, materials, and personnel to and from the job site for a third and fourth work season. This Contract Line Item Number (CLIN) applies to the Prime Contractor and all subcontractor mobilization and demobilization.

b. Payment: Payment will be made at the Contract amount under CLIN 0003 as stated in Contract Clause 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (Dec 1991). Submit a schedule of mobilization and demobilization costs for approval prior to submitting the first request for payment for Season 3 of construction.

SECTION 00 10 00 - SOLICITATION

CLIN 0003

The CLIN description has changed from Mobilization and Demobilization Season 3 to Mobilization and Demobilization Seasons.

The CLIN extended description has changed from:

IAW Project specifications

To:

Mobilization and Demobilization Seasons 3 and 4 IAW Project specifications

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by March 3, 2023. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

FINAL CONSTRUCTION PHYSICAL COMPLETION: Not later than October 1, 2026

CONTRACT END DATE: will be February 1. 2027..

The time stated for FINAL CONSTRUCTION PHYSICAL COMPLETION includes physical completion of all site work, site cleanup, and demobilization.

The time stated for CONTRACT END DATE includes submission and approval of all final remaining work documents. (See Sections 01 33 00 Submittal Procedures, 01 78 23.00 25 Operations and Maintenance Data, and 01

78 39.00 25 Record Drawings for final work document requirements.)

(End of clause)

(End of Summary of Changes)