B3_W9126G17B0026-Specs.pdf

SOLICITATION NO. W9126G17B0026

SABINE-NECHES WATERWAY, TEXAS

SABINE-NECHES WATERWAY, PORT ARTHUR CANAL

JUNCTION AREA, AND SABINE PASS CHANNEL

IN JEFFERSON AND ORANGE COUNTIES, TEXAS

AND CAMERON PARISH, LOUISIANA

PROJECT MANUAL FOR

PIPELINE DREDGING

JULY 2017

DEPARTMENT OF THE ARMY

GALVESTON DISTRICT, CORPS OF ENGINEERS

P.O. BOX 1229

GALVESTON, TEXAS

"INCREASE PROFIT - SUBMIT VECP'S"

This project was designed by the Galveston District of the U.S. Army Corps of Engineers.

The initials or signatures and registration designations of individuals appear on these project documents within the scope of their employment as required by ER 1110-1-8152.

ROBERT C. THOMAS, P.E.

CHIEF, ENGINEERING AND CONSTRUCTION DIVISION

SWG FILE NO.:SN 101-300 SOLICITATION NO.: W9126G17B0026

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 00 00 SOLICITATION, OFFER AND AWARD, SF-1442

00 11 00.00 45 BID SCHEDULE

00 21 00 BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

00 45 00 REPRESENTATION AND CERTIFICATIONS

00 72 00 CONTRACT CLAUSES

00 73 00.01 45 SPECIAL CONTRACT REQUIREMENTS, STANDARD

00 73 46 WAGE RATES

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00.01 45 NON-REGULATED SPECIAL CONTRACT REQUIREMENTS

01 22 00.10 MEASUREMENT AND PAYMENT

01 32 01.01 45 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26.01 45 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 01.00 QUALITY CONTROL

01 57 20.00 45 ENVIRONMENTAL PROTECTION

01 58 13.04 45 BULLETIN BOARD

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 23.17 45 PIPELINE DREDGING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

W45VAK70174178

THIS SOLICITATION IS BEING ISSUED AN UNRESTRICTED BID (IFB) FOR MAINTENANCE DREDGING OF THE SABINE-NECHES WATERWAY, TEXAS, PORT ARTHUR CANAL JUNCTION AREA AND SABINE PASS CHANNEL IN JEFFERSON AND ORANGE COUNTIES, TEXAS AND

CAMERON PARISH, LOUISIANA, PIPELINE DREDGNG, DEEP DRAFT CHANNEL.

PER AFARS 5132.702(B) "FUNDS ARE NOT PRESENTLY AVAILABLE FOR THIS ACQUISITION. NO CONTRACT WILL BE MADE UNTIL

APPROPRIATED FUNDS ARE MADE AVAILABLE."

ESTIMATED CONSTRUCTION RANGE 9FAR 36.204) - THE ESTIMATED PRICE RANGE OF THE PROPOSED CONSTRUCTION IS BETWEEN

$1,000,000 AND $5,000,000.

X

TRACI D ROBICHEAUX 409 766 6306

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

31-Jul-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________00 73 00.01 45

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________30 Aug 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS FORT WORTH

2000 FORT POINT ROAD

GALVESTON TX 77550-1229

W9126G CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

409 766 3010FAX:TEL: 409 766 3845 TEL: FAX:

W9126G17B0026

PAGE OF PAGES

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 11 00.00 45

BID SCHEDULE

PART 1 GENERAL

1.1 BID SCHEDULE

1.1.1 Schedule No. 1

1.1.2 Option No. 1

1.1.3 Option No. 2

1.2 MODIFICATIONS (CESWG)

1.3 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

-- End of Section Table of Contents --

DOCUMENT 00 11 00.00 45 Page 1

SECTION 00 11 00.00 45

BID SCHEDULE

PART 1 GENERAL

1.1 BID SCHEDULE

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.1 Schedule No. 1

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

SCHEDULE NO. 1

0001 Mobilization and Demobilization

1 JOB SUM $___________

0002 Pipeline Management 1 JOB SUM $___________

0003 Dredging Section Nos. 3 and 4

999,000 C.Y. $_________ $___________

0004 Dredging Section Nos. 5 and 6

1,454,000 C.Y. $_________ $___________

TOTAL SCHEDULE NO. 1 $___________

NOTE: Completion time stated in SECTION 00 73 00.01 45 SPECIAL CONTRACT REQUIREMENTS, STANDARD is for Schedule No. 1 work.

DOCUMENT 00 11 00.00 45 Page 2

BID SCHEDULE (CONT'D)

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.2 Option No. 1

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 1

0005 Dredging Section No. 1 113,000 C.Y. $_________ $___________

0006 Pipeline Management 1 JOB SUM $___________

TOTAL OPTION NO. 1 $___________

TOTAL SCHEDULE NO. 1 AND OPTION NO. 1 $___________

NOTE FOR OPTION NO. 1: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. Award of this Option is contingent upon availability of funds. An additional time of 12 calendar days will be added to this Contract for completion of this Option.

DOCUMENT 00 11 00.00 45 Page 3

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.3 Option No. 2

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 2

0007 Dredging Section No. 2 141,000 C.Y. $_________ $___________

0008 Pipeline Management 1 JOB SUM $___________

0009 Standby for Port of Port Arthur Dredging

72 HOUR $_________ $___________

TOTAL OPTION NO. 2 $___________

TOTAL SCHEDULE NO. 1 AND OPTIONS NOS. 1 AND 2 $___________

NOTE FOR OPTION NO. 2: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. Award of this Option is contingent upon availability of funds. An additional time of 14 calendar days will be added to this Contract for completion of this Option.

DOCUMENT 00 11 00.00 45 Page 4

(TO BE ATTACHED TO STANDARD FORM 1442)

1.2 MODIFICATIONS (CESWG)

If a modification to a bid based on unit prices is submitted, which provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment of each unit price in the bid schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the bid schedule.

1.3 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

-- End of Document --

DOCUMENT 00 11 00.00 45 Page 5

SWG FILE NO.:SN 101-300 SOLICITATION NO.:W9126G17B0026

Section 00 21 00 - Page 1

Section 00 21 00 - Instructions, Conditions and Notices to Offerors

GENERAL INSTRUCTIONS

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $1,000,000 and $5,000,000.

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON ASFI and FBO

After solicitation issuance, contractors may register to be placed on a plan holders list, view and/or download this solicitation and all amendments at the following internet addresses: http://www.fbo.gov/ Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the FBO website daily (using the above links) for amendments to the solicitation.

You must be registered in the System for Award Management (SAM) to receive a government contract award. You may register with the SAM at https://www.sam.gov

1.3 TECHNICAL INFORMATION DREDGING

(a)For technical information regarding the plans and specifications submit questions in PROJNET, see paragraph 1.10 of this section for details.”

(b)The Contractor [ ] shall [x] shall not be permitted to use self-propelled hopper dredges to perform the work specified herein.

1.4 PREAWARD INFORMATION DREDGING

The apparent low bidder shall submit within (1) working day after Bid Opening, the following information:

(a) A statement as to whether he is now or ever has been engaged in performing dredging of [X ] deep or [ ] shallow draft channels.

(b) A list of key personnel available for the current project and their qualifications.

(c) A copy of the bidder's latest financial statement, including the names of banks or other financial institutions with which the bidder conducts business. If the financial statement is more than 60 days old, a certificate should be attached stating that the financial condition is substantially the same, or if not the same, the changes that have taken place. Such statement will be treated as confidential.

(d) A list of present commitments, including the dollar value thereof, name of office under which the work is being performed, the scheduled completion date of each, days ahead or behind schedule and the name of the Dredge to be used on the job.

(e) Name and location of the firm's dredging plant to perform the work under this contract, the date this plant will commence work, and the plants capability to perform the work as required by the specifications.

(f) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within ten (10) working days after Bid Opening.

1.5 DISPOSAL OF EXCAVATED MATERIAL

The following owners in the vicinity of the work to be accomplished under this Invitation for Bids are known to desire fill material:

NAME ADDRESS

Section 00 21 00 - Page 2

If any of the areas owned by the above-listed owners are proposed to be utilized by the Contractor in the performance of the work, the provision for use of alternate areas DREDGING: PLACEMENT OF EXCAVATED MATERIAL of the specifications will be applicable.

1.6 BIDDER'S QUALIFICATIONS

Before a bid is considered for award, the bidder may be requested by the Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

1.7 CAUTIONS & REMINDERS TO BIDDERS

All information required by the terms of the Invitation must be furnished.

MISTAKES OR OMISSIONS CAN BE COSTLY. Important items for you to check are included in but not limited to, those listed below. This checklist is furnished only to assist you in submitting a proper bid. Check as you read.

Have you acknowledged all amendments?

Have you completed SECTION 00 45 00, REPRESENTATIONS & CERTIFICATIONS portion of the bid package? Is your bid properly signed?

If a bid guarantee is required, is it included with your bid?

(A late bid guarantee is treated the same as a late bid).

Is your bid guarantee in the proper amount? Bid guarantee shall be in the amount of 20 percent of the amount of the bid, or $3 million, whichever is less.

If your bid guarantee is in the form of a bid bond, is the bond properly signed by both the bidder and surety and are all required seals affixed?

Is the name in which you submitted the bid the same on your bid as on your bid bond?

If required have you entered a unit price for each bid item?

(The Invitation will specifically state when this is necessary).

Are decimals in unit prices in the proper places?

Are your figures legible? Are the extensions of your unit prices, and your total bid price correct?

Are all erasures or corrections initialed by the person signing the bid?

I have not restricted my bid by altering the provisions of the Invitation.

Is the envelope containing your bid properly identified that it is a sealed bid and does it contain the correct invitation number and bid opening time?

Will your bid arrive on time? Late hand-carried bids will not be considered. Late mailed bids may be considered if sent by Registered or Certified Mail; if late receipt was due to delay in mails, or if specific requirements have been met. (See the portion of the Invitation pertaining to "Late Bids and Modifications or Withdrawals").

Section 00 21 00 - Page 3

REMINDER TO BIDDERS

REMINDER #1 - Acknowledge all Amendments on the reverse side of SF 1442, Item 19, Solicitation, Offer, and Award.

REMINDER #2 - The Contracting Officer signing this contract is the Primary Contracting Officer. However, any Contracting Officer assigned to the Galveston District may take formal action. See Section entitled "Specific Project Requirements".

1.8 SPECIAL INSTRUCTIONS PERTAINING TO HAND-CARRIED BIDS/OFFERS:

Hand-carried Bids/Offers must be delivered to: the Contract Specialist or Contracting Officer located at the US Army Corps of Engineers, Jadwin Building, 2000 Fort Point Road, Galveston District, Galveston, TX 77550.

Not Later than the Due Date and Time. Bids/Offers will only be accepted by contracting personnel. Guards are not authorized to accept Bids/Offers on behalf of the Government.

Galveston District has a security gate located on Fort Point Rd and requires all occupants of the vehicle to have a valid driver’s license for entry. Parking is limited. Firearms are not permitted on the installation.

Offerors are cautioned to allow sufficient time for travelling over the causeway or ferry. Neither will constitute Government-caused delay.

Offerors are also cautioned that Galveston is an island that, during Spring Break and the Summer Season, can have traffic slowdowns and congestion because the District is collocated with the Bolivar Ferry traffic waiting to board and can delay access to the District Office.

(End of Clause)

1.9 BIDDER INQUIRY – PROJNET

1. Prospective Offerors should submit questions concerning this solicitation via Bidder Inquiry in ProjNet at www.projnet.org/projnet A. To submit and review bid inquiry items, bidders will need to be a current registered user or self-register into the system. To self-register, go to the aforementioned web page and click on the BID tab.

Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

***Please Note: Offerors shall only submit one question per inquiry.

Inquiries containing multiple questions may be rejected.

B. From this page, you may view all bidder inquiries or add inquiry.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

D. The Solicitation Number is: W9126G-17-B-0026

The Bidder Inquiry Key is: RF2636-R9GRAQ

2. The Bidder Inquiry System will be unavailable for new inquires fifteen

(15) calendar days prior to offer submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specification in its entirety, Section 00 21 00 - Page 4 review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

5. Offers will be publicly opened at the date/time stated in the solicitation.

1.10 Service of Protest

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the Contracting Officer, US Army Corps of Engineers, Galveston District, PO Box 1229, Galveston, Texas 77553- 1229, Fax No. (409) 766-3010, submitting the protest at SWF-protest@usace.army.mil .

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

1.11 DAVIS-BACON ACT

Paragraph entitled DAVIS-BACON ACT of (CONTRACT CLAUSES - Section 00 72 00, FAR 52.222-6) is applicable to this solicitation. Wage Rates will be incorporated by amendment, if they are not included in this solicitation.

Section 00 45 00 - Page 1

Section 00 45 00 - Representations and Certifications

CLAUSES INCORPORATED BY REFERENCE

52.204-17 Ownership or Control of Offeror JUL 2016 52.204-19 Incorporation by Reference of

Representations and Certifications.

DEC 2014

52.204-20 Predecessor of Offeror JUL 2016 52.209-12 Certification Regarding Tax Matters FEB 2016 52.223-22 Public Disclosure of Greenhouse Gas

Emissions and Reduction Goals -- Representation.

DEC 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.204-7004 Alt A

System for Award Management Alternate A FEB 2014

252.247-7022 Representation Of Extent Of Transportation Of Supplies By Sea

AUG 1992

252.247-7022 Representation Of Extent Of Transportation Of Supplies By Sea

AUG 1992

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2016)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $27.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

Section 00 45 00 - Page 2

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vi) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(viii) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(ix) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

Section 00 45 00 - Page 3

(x) 52.219-1, Small Business Program Representations (Basic & Alternate I).

This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xi) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements.

This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xv) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xix) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

Section 00 45 00 - Page 4

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xx) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxi) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiii) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

Section 00 45 00 - Page 5

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

Section 00 45 00 - Page 6

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY

OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

Section 00 45 00 - Page 7

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

The offeror represents that --

(a) ( ) It has, ( ) has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation;

(b) ( ) It has, ( ) has not, filed all required compliance reports; and

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

Section 00 72 00 - Page 1

Section 00 72 00 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The SEP 2006 Government 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds MAY 2014 for Illegal or Improper Activity 52.203-10 Price Or Fee Adjustment For Illegal Or MAY 2014 Improper Activity 52.203-12 Limitation On Payments To Influence Certain Federal OCT 2010 Transactions 52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and APR 2014 Requirement To Inform Employees of Whistleblower Rights 52.204-4 Printed or Copied Double-Sided on Postconsumer MAY 2011 Fiber Content Paper 52.204-10 Reporting Executive Compensation and First-Tier OCT 2016 Subcontract Awards 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.209-6 Protecting the Government's Interest When OCT 2015 Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment 52.209-9 Updates of Publicly Available Information Regarding JUL 2013 Responsibility Matters 52.209-10 Prohibition on Contracting With Inverted NOV 2015 Domestic Corporations 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost AUG 2011 or Pricing Data - Modifications - Sealed Bidding 52.214-28 Subcontracting Certified Cost Or Pricing Data-- OCT 2010

Modifications--Sealed Bidding 52.215-20 Requirements for Certified Cost or Pricing Data OCT 2010 or Information Other Than Certified Cost or Pricing Data 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-9 Alt I Small Business Subcontracting Plan (JAN 2017) NOV 2016 Alternate I 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime MAY 2014 Compensation 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014

Section 00 72 00 - Page 2

52.222-13 Compliance With Construction Wage Rate MAY 2014 Requirements and Related Regulations

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for APR 2015 Construction 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the DEC 2010 Relations Act 52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 (Jan JAN 2017 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text AUG 2011 While Driving 52.225-11 Buy American-Construction Materials Under Trade MAY 2014 Agreements (OCT 2016) Alternate I 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.226-1 Utilization Of Indian Organizations And Indian- JUN 2000 Economic Enterprises 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And DEC 2007 Infringement 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.232-33 Payment by Electronic Funds Transfer--System for JUL 2013 Management 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business DEC 2013 Subcontractors 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, APR 1984 Utilities, and Improvements 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984

Section 00 72 00 - Page 3

52.236-13 Accident Prevention NOV 1991

52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.244-2 Subcontracts OCT 2010 52.246-12 Inspection of Construction AUG 1996 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government SEP 1996 (Fixed- Price) (Apr 2012)

- Alternate I 52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former SEP 2011 DoD Officials 252.203-7001 Prohibition On Persons Convicted of Fraud or DEC 2008 Other Defense- Contract-Related Felonies 252.203-7002 Requirement to Inform Employees of Whistleblower SEP 2013 Rights 252.203-7003 Agency Office of the Inspector General DEC 2012 252.203-7004 Display of Hotline Posters OCT 2016 252.203-7005 Representation Relating to Compensation of Former NOV 2011 DoD Officials 252.203-7997 (Dev) Prohibition on Contracting with Entities that Require

Certain Internal Confidentiality Agreements (Deviation 2016-

O0003) OCT 2015

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7015 Notice of Authorized Disclosure of Information for MAY 2016 Litigation Support 252.205-7000 Provision Of Information To Cooperative Agreement DEC 1991 Holders 252.209-7004 Subcontracting With Firms That Are Owned or OCT 2015 Controlled By The Government of a Country that is a State Sponsor of Terrorism 252.215-7008 Only One Offer OCT 2013 252.219-7003 Small Business Subcontracting Plan (DOD Contracts) MAR 2016 --Basic 252.223-7004 Drug Free Work Force SEP 1988 252.225-7012 Preference For Certain Domestic Commodities AUG 2016 252.226-7001 Utilization of Indian Organizations and SEP 2004 Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns 252.227-7033 Rights in Shop Drawings APR 1966 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and JUN 2012 Receiving Reports 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991

Section 00 72 00 - Page 4

252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea APR 2014 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

CLAUSES INCORPORATED BY FULL TEXT

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within see Section 0 11 00.00 45, prior to completion of all authorized work under Schedule No. 1.

Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of clause)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK

(MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (OCT 2015)

(a) Definitions. As used in this clause--

``Active duty wartime or campaign badge veteran,'' ``Armed Forces service medal veteran,'' ``disabled veteran,'' ``protected veteran,'' ``qualified disabled veteran,'' and ``recently

Section 00 72 00 - Page 5 separated veteran'' have the meanings given at FAR 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

52.225-11 BUY AMERICAN--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (OCT

2016)

Caribbean Basin country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country;

or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Section 00 72 00 - Page 6

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Moldova, Montenegro, Netherlands, New Zealand, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan, Ukraine, or United Kingdom);

(2) A Free Trade Agreement (FTA) country (Australia, Bahrain, Canada, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, South Sudan, Tanzania,…