B3_Amendment_0003-W9126G17B0026.pdf

W45VAK70174178

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is show n on the pages follow ing. See pages follow ing.

BID OPENING REMAINS ON 30 AUG 2017 @ 2:00 P.M. LOCAL TIME.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W9126G17B0026

X 9B. DATED (SEE ITEM 11)

31-Jul-2017

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Aug-2017

CODE

US ARMY CORPS OF ENGINEERS FORT WORTH

2000 FORT POINT ROAD

GALVESTON TX 77550-1229

W9126G 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

Amendment 0003

W9126G17B0026

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

SUMMARY AMENDMENT 0003

1 – A revised SF 1442 is provided. Changes are:

Block 10 - Estimated Construction Range corrected to read, “between $5,000,000 and $10,000,000

Block 11 – contractor performance shall begin performance within 10 calendar days and complete it within * calendar days after receiving…… (NOTE- the asterick in Block 11 is to see 00 73 00.01 45)

2 – Section 00 21 00 GENERAL INSTRUCTIONS

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $5,000,000 and $10,000,000.

3 - Section 00 21 00 GENERAL INSTRUCTIONS

1.5 PREAWARD INFORMATION DREDGING

(f) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within one (1) working day after Bid Opening.

NO OTHER CHANGES.

(End of Summary of Changes)

W45VAK70174178

THIS SOLICITATION IS BEING ISSUED AN UNRESTRICTED BID (IFB) FOR MAINTENANCE DREDGING OF THE SABINE-NECHES WATERWAY, TEXAS, PORT ARTHUR CANAL JUNCTION AREA AND SABINE PASS CHANNEL IN JEFFERSON AND ORANGE COUNTIES, TEXAS AND

CAMERON PARISH, LOUISIANA, PIPELINE DREDGNG, DEEP DRAFT CHANNEL.

PER AFARS 5132.702(B) "FUNDS ARE NOT PRESENTLY AVAILABLE FOR THIS ACQUISITION. NO CONTRACT WILL BE MADE UNTIL

APPROPRIATED FUNDS ARE MADE AVAILABLE."

ESTIMATED CONSTRUCTION RANGE 9FAR 36.204) - THE ESTIMATED PRICE RANGE OF THE PROPOSED CONSTRUCTION IS BETWEEN

$ ,000,000 AND $ ,000,000 .

X

TRACI D ROBICHEAUX 409 766 6306

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

31-Jul-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________00 73 00.01 45

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________30 Aug 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS FORT WORTH

2000 FORT POINT ROAD

GALVESTON TX 77550-1229

W9126G

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

409 766 3010FAX:TEL: 409 766 3845 TEL: FAX:

W9126G17B0026 37

AMD#3

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W9126G17B0026

Section 00 21 00 - Instructions, Conditions and Notices to Offerors

GENERAL INSTRUCTIONS

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $ ,000,000 and $ ,000,000 .

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON ASFI and FBO

After solicitation issuance, contractors may register to be placed on a plan holders list, view and/or download this solicitation and all amendments at the following internet addresses: http://www.fbo.gov/ Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the FBO website daily (using the above links) for amendments to the solicitation. You must be registered in the System for Award Management (SAM) to receive a government contract award. You may register with the SAM at https://www.sam.gov

1.3 EQUIPMENT OWNERSHIP AND OPERATION EXPENSE SCHEDULE (18 MAR 2013) (UAI 31.105-100) In accordance with FAR 31.105(d)(2)(i)(b), equipment ownership and operating cost shall be determined using EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule.

1.4 TECHNICAL INFORMATION DREDGING

(a) For technical information regarding the plans and specifications submit questions in PROJNET, see paragraph

1.10 of this section for details.”

(b) The Contractor [ ] shall [x] shall not be permitted to use self-propelled hopper dredges to perform the work specified herein.

1.5 PREAWARD INFORMATION DREDGING

The apparent low bidder shall submit within (1) working day after Bid Opening, the following information:

(a) A statement as to whether he is now or ever has been engaged in performing dredging of [X ] deep or [ ] shallow draft channels.

(b) A list of key personnel available for the current project and their qualifications.

(c) A copy of the bidder's latest financial statement, including the names of banks or other financial institutions with which the bidder conducts business. If the financial statement is more than 60 days old, a certificate should be attached stating that the financial condition is substantially the same, or if not the same, the changes that have taken place. Such statement will be treated as confidential.

(d) A list of present commitments, including the dollar value thereof, name of office under which the work is being performed, the scheduled completion date of each, days ahead or behind schedule and the name of the Dredge to be used on the job.

(e) Name and location of the firm's dredging plant to perform the work under this contract, the date this plant will commence work, and the plants capability to perform the work as required by the specifications.

(f) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within one (1) working day after Bid Opening. (AMD #3)

1.6 DISPOSAL OF EXCAVATED MATERIAL

The following owners in the vicinity of the work to be accomplished under this Invitation for Bids are known to desire fill material:

NAME ADDRESS

If any of the areas owned by the above-listed owners are proposed to be utilized by the Contractor in the performance of the work, the provision for use of alternate areas DREDGING: PLACEMENT OF EXCAVATED MATERIAL of the specifications will be applicable.

1.7 BIDDER'S QUALIFICATIONS