Attachment 12 Revised Specifications.pdf

SOLICITATION NO. W91238-23-B-0005

Amendment 0004

AMERICAN RIVER COMMON FEATURES (ARCF)

SACRAMENTO WEIR WIDENING

YOLO COUNTY, CA

AMENDMENT 0004 - SUMMARY:

A) SPECIFICATION 2279

a. Replace entire Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

b. Replace entire Section 03 30 00 CAST-IN-PLACE CONCRETE

ARCF (2016) - Sacramento Weir Widening 2279

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 19

TEMPORARY ENVIRONMENTAL CONTROLS

PART 1 GENERAL

1.1 PAYMENT

1.2 REFERENCES

1.3 DEFINITIONS

1.3.1 Active Nest

1.3.2 Biological Opinion

1.3.3 Class I and II Ozone Depleting Substance (ODS)

1.3.4 Contractor Generated Hazardous Waste

1.3.5 Cultural Resources

1.3.6 Electronics Waste

1.3.7 Environmental Pollution and Damage

1.3.8 Environmental Protection

1.3.9 Hazardous Debris

1.3.10 Hazardous Materials

1.3.11 Hazardous Waste

1.3.12 Historic Properties

1.3.13 Inactive Nest

1.3.14 Land Application for Discharge Water

1.3.15 Listed Bird Species

1.3.16 Non-Nesting Season

1.3.17 Municipal Separate Storm Sewer System (MS4) Permit

1.3.18 National Pollutant Discharge Elimination System (NPDES)

1.3.19 Oily Waste

1.3.20 Pesticide

1.3.21 Pesticide Treatment Plan

1.3.22 Pests

1.3.23 Regulated Waste

1.3.24 Sediment

1.3.25 Solid Waste

1.3.25.1 Debris

1.3.25.2 Green Waste

1.3.25.3 Material Not Regulated As Solid Waste

1.3.25.4 Non-Hazardous Waste

1.3.25.5 Recyclables

1.3.25.6 Surplus Soil

1.3.25.7 Scrap Metal

1.3.25.8 Wood

1.3.26 Surface Discharge

1.3.27 Tribal Cultural Resources

1.3.28 Trees

1.3.29 Wastewater

1.3.29.1 Storm Water

1.3.30 Waters of the United States

1.3.31 Wetlands

1.3.32 Universal Waste

SECTION 01 57 19 Page 1

1.4 GENERAL REQUIREMENTS

1.4.1 Subcontractors

1.5 SUBMITTALS

1.6 ENVIRONMENTAL PROTECTION REQUIREMENTS

1.6.1 Protection Features

1.7 QUALIFICATIONS

1.7.1 Archaeological Monitor

1.7.1.1 Lead Field Monitors

1.7.1.2 Other Field Monitors

1.7.2 Biological Monitor

1.8 SPECIAL ENVIRONMENTAL REQUIREMENTS

1.9 QUALITY ASSURANCE

1.9.1 Preconstruction Survey And Protection Of Features

1.9.2 Regulatory Notifications

1.9.3 Environmental Brief

1.9.4 Environmental Manager

1.9.5 Employee Training Records

1.9.6 Non-Compliance Notifications

1.10 ENVIRONMENTAL PROTECTION PLAN

1.10.1 General Overview and Purpose

1.10.1.1 Descriptions

1.10.1.2 Duties

1.10.1.3 Procedures

1.10.1.4 Communications

1.10.1.5 Contact Information

1.10.2 General Site Information

1.10.2.1 Drawings

1.10.2.2 Work Area

1.10.2.3 Traffic Control Plan

1.10.2.4 Appointment Letter

1.10.3 Storm Water Management and Control

1.10.4 Protection of the Environment from Waste Derived from

Contractor Operations

1.10.5 Non-Hazardous Solid Waste Disposal Plan

1.10.6 Spill Control Plan

1.10.7 Prevention of Releases to the Environment

1.10.8 Regulatory Notification and Permits

1.10.9 Clean Air Act Compliance

1.10.9.1 Air Quality Control Plan

1.10.9.2 Contaminant Prevention Plan

1.10.9.3 Haul Route

1.10.9.4 Pollution Generating Equipment

1.10.9.5 Stationary Internal Combustion Engines

1.10.9.6 Air Pollution-engineering Processes

1.10.10 Pesticide Treatment Plan

1.10.11 Water Quality Management Plan

1.10.12 Water Quality Monitoring Plan

1.10.13 Dewatering Plan

1.10.14 Waste Water Management Plan

1.10.15 Historical, Archaeological, Cultural Resources, Biological

Resources And Wetlands Protection Plans

1.10.16 Restoration Plan

1.10.17 Compliance

1.10.18 Appendix

1.11 LICENSES AND PERMITS

1.11.1 Section 401 Fill Permit

1.11.2 Section 401 Water Quality Certification

1.11.3 Air Quality

1.11.4 Portable Equipment Registration Program (PERP)

SECTION 01 57 19 Page 2

1.11.5 Dewatering Permit

1.11.6 Construction General Permit (NPDES Permit)

1.11.7 Solid Waste Management Permit

1.11.7.1 Monthly Solid Waste Management Report

1.12 ENVIRONMENTAL RECORDS BINDER

1.13 PESTICIDE DELIVERY, STORAGE, AND HANDLING

1.13.1 Delivery and Storage

1.13.2 Handling Requirements

1.14 ENVIRONMENTAL ASSESSMENT OF CONTRACT DEVIATIONS

1.15 NOTIFICATION

1.16 HAZARDOUS, TOXIC AND RADIOACTIVE WASTE (HTRW) PERIMETER AIR

MONITORING

PART 2 PRODUCTS

2.1 COMPLIANT MATERIALS

PART 3 EXECUTION

3.1 PROTECTION OF NATURAL RESOURCES

3.1.1 Flow Ways

3.1.2 Vegetation

3.1.3 Streams

3.2 STORM WATER

3.2.1 Construction General Permit

3.2.1.1 Stormwater Pollution Prevention Plan

3.2.1.2 Stormwater Notice of Intent for Construction Activities

3.2.1.3 Inspection Reports

3.2.1.4 Stormwater Pollution Prevention Plan Compliance Notebook

3.2.1.5 Storm water Notice of Termination for Construction

Activities

3.3 LAND RESOURCES

3.3.1 Work Area Limits

3.3.2 Contractor Facilities and Work Areas

3.3.3 Landscape

3.3.4 Tree Protection

3.3.5 Erosion and Sediment Controls

3.4 WATER RESOURCES

3.4.1 Water Quality Limits

3.4.2 Cofferdams, Diversions, and Dewatering Operations

3.4.2.1 Dewatering

3.4.2.1.1 Fish Handling and Relocation

3.4.2.2 Removal Of Cofferdams And Diversions

3.4.3 Stream Crossings

3.4.4 Wetlands

3.4.5 Equipment, Fuel and Oil Requirements

3.4.6 Control of Mercury-Containing Soils

3.5 HISTORICAL, ARCHAEOLOGICAL, AND CULTURAL RESOURCES

3.5.1 Archaeological Monitoring and Support Services

3.5.2 Archaeological Monitor Responsibilities

3.5.3 Post Review Discoveries

3.5.4 Human Remains

3.5.5 Recovery of Human Remains

3.6 TRIBAL MONITORS

3.7 BIOLOGICAL RESOURCES

3.7.1 State Listed Birds

3.7.2 Migratory Birds

3.7.3 Migratory Bird Nesting Season

3.7.4 Giant Garter Snake

SECTION 01 57 19 Page 3

3.7.5 Elderberry Shrubs

3.7.5.1 Fence Elderberry Shrubs

3.7.6 Tree-Roosting Bats

3.7.6.1 Avoiding Tree-Roosting Bats

3.7.7 Special Status Bats

3.7.8 Fish and Wildlife

3.7.8.1 Fish Take Reports

3.8 AIR RESOURCES

3.8.1 Pre-construction Air Quality Mitigation and Report and Air

Quality Mitigation

3.8.2 Air Quality Control

3.8.3 Dust Control

3.8.3.1 Particulates

3.8.4 Odors

3.8.5 Burning

3.8.6 Class I and II ODS (Ozone Depleting Substance) Prohibition

3.8.7 Accidental Venting of Refrigerant

3.8.8 EPA Certification Requirements

3.8.9 Emissions From Motorized Equipment

3.8.10 On-Road Equipment

3.8.11 Off-Road Powered Equipment

3.8.11.1 NOx and PM Emissions

3.8.11.2 Visible Emissions

3.8.11.3 PM10 Dust

3.8.11.4 Naturally Occurring Asbestos (NOA)

3.8.12 Diesel Generators

3.8.13 Marine Equipment Standards

3.9 IN-WATER CONSTRUCTION ACTIVITIES

3.10 CHEMICAL MATERIALS MANAGEMENT AND WASTE DISPOSAL

3.10.1 Solid Wastes

3.10.2 Chemicals and Chemical Wastes

3.10.3 Contractor Generated Hazardous Wastes/Excess Hazardous

Materials

3.10.4 Fuel and Lubricants

3.11 RECYCLING AND WASTE MINIMIZATION

3.12 NON-HAZARDOUS SOLID WASTE DIVERSION REPORT

3.13 WASTE MANAGEMENT AND DISPOSAL

3.13.1 Waste Determination Documentation

3.13.1.1 Sampling and Analysis of Waste

3.13.1.1.1 Waste Sampling

3.13.1.1.2 Laboratory Analysis

3.13.1.1.3 Analysis Type

3.13.2 Solid Waste Management

3.13.2.1 Project Solid Waste Disposal Documentation Report

3.13.2.2 Control and Management of Solid Wastes

3.13.3 Control and Management of Hazardous Waste

3.13.3.1 Hazardous Waste/Debris Management

3.13.3.2 Waste Storage/Satellite Accumulation/90 Day Storage Areas

3.13.3.3 Hazardous Waste Disposal

3.13.3.3.1 Responsibilities for Contractor's Disposal

3.13.3.3.1.1 Services

3.13.3.3.1.2 Samples

3.13.3.3.1.3 Analysis

3.13.3.3.1.4 Labeling

3.13.3.4 Universal Waste Management

3.13.3.5 Electronics End-of-Life Management

3.13.3.6 Disposal Documentation for Hazardous and Regulated Waste

3.13.4 Releases/Spills of Oil and Hazardous Substances

3.13.4.1 Response and Notifications

SECTION 01 57 19 Page 4

3.13.4.2 Clean Up

3.13.5 Mercury Materials

3.13.6 Wastewater

3.13.6.1 Treatment

3.13.6.2 Surface Discharge

3.13.6.3 Land Application

3.14 HAZARDOUS MATERIAL MANAGEMENT

3.14.1 Control And Management Of Asbestos-Containing Material (ACM)

3.14.2 Control And Management Of Lead-Based Paint (LBP)

3.14.3 Control And Management Of Polychlorinated Biphenyls (PCBS)

3.14.4 Control And Management Of Lighting Ballast And Lamps

Containing PCBS

3.15 PREVIOUSLY USED EQUIPMENT

3.16 CONTROL AND MANAGEMENT OF LEAD-BASED PAINT (LBP)

3.17 MAINTENANCE OF POLLUTION FACILITIES

3.18 PETROLEUM, OIL, LUBRICANT (POL) STORAGE AND FUELING

3.18.1 Used Oil and Lubricants Management

3.18.2 Oil Storage Including Fuel Tanks

3.19 INADVERTENT DISCOVERY OF PETROLEUM-CONTAMINATED SOIL OR HAZARDOUS

WASTES

3.20 PEST MANAGEMENT

3.20.1 Qualifications

3.20.2 Application

3.21 CONTAMINATED MEDIA MANAGEMENT

3.22 SOUND INTRUSION

3.22.1 Heavy Truck Delivery Restrictions

3.23 TRAINING OF CONTRACTOR PERSONNEL

3.24 SITE RESTORATION

-- End of Section Table of Contents --

SECTION 01 57 19 Page 5

SECTION 01 57 19

TEMPORARY ENVIRONMENTAL CONTROLS

PART 1 GENERAL

1.1 PAYMENT

No separate payment will be made for work covered under this section.

Payment of fees associated with encroachment permits, environmental permits, application, or notices obtained by the Contractor, and payment of all fines and associated fees for violation or non-compliance with Federal, State, Regional and local laws and regulations are the Contractor's responsibility. Include all costs associated with this section in the contract price.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

CALIFORNIA AIR RESOURCES BOARD (CARB)

CARB 13 CCR 2450-2466 Portable Equipment and Engine Registration

CARB 13 CCR 2485 Airborne Toxic Control Measure to Limit Diesel-Fueled Commercial Motor Vehicle Idling

CARB 17 CCR 93105 (2002)Asbestos ATCM for Construction, Grading, Quarrying, and Surface Mining Operations

CALIFORNIA PUBLIC RESOURCES CODE (PCR)

PRC 5097.98 CHAPTER 1.75. Native American Historical, Cultural, and Sacred Sites

CALIFORNIA CENTRAL VALLEY REGIONAL WATER QUALITY CONTROL BOARD

(CVRWQCB)

CVRWQCB Basin Plan (2009) The Water Quality Control Plan (Basin Plan) for the California Regional Water Quality Control Board Central Valley Region, Sacramento River Basin and San Joaquin River Basin.

YOLO-SOLANO AIR QUALITY MANAGEMENT DISTRICT (YSAQMD)

PM2.5 Plan Proposed PM2.5 Implementation/Maintenance Plan and Redesignation Request for Sacramento PM2.5 Nonattainment Area

Air Quality Emissions YSAQMD's Guide to Air Quality

SECTION 01 57 19 Page 6

Assessment and Mitigation Assessment in Yolo County

PM10 Plan YSAQMD Particulate Matter (PM) 10 Attainment Redesignation and Maintenance Plan

STATE OF CALIFORNIA DEPARTMENT OF TRANSPORTATION (CALTRANS)

CDT MUTCD (2014) California Manual on Uniform Traffic Control Devices, Revision 1

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

ERDC/EL TR-08-28 (2008) Regional Supplement to the Corps of Engineers Wetland Delineation Manual: Arid West Region (Version 2.0)

TR Y-87-1 (1987) Corps of Engineers Wetlands Delineation Manual

U.S. Code (USC)

16 USC 1531-1544 Endangered Species Act

16 USC 703-712 Migratory Bird Treaty Act

U.S. ENVIRONMENTAL PROTECTION AGENCY (EPA)

EPA SW-846 (Third Edition; Update IV) Test Methods for Evaluating Solid Waste:

Physical/Chemical Methods

NPDES (1972; R 2005) National Pollutant Discharge Elimination System

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910.1053 Respirable Crystalline Silica

29 CFR 1926.1153 Respirable Crystalline Silica

33 CFR 328 Definition Of Waters Of The United States

29 CFR 1910.120 Hazardous Waste Operations and Emergency Response

40 CFR 122.26 Storm Water Discharges (Applicable to State NPDES Programs, see section 123.25)

40 CFR 112 Oil Pollution Prevention

40 CFR 152 Pesticide Registration and Classification Procedures

40 CFR 241 Guidelines for Disposal of Solid Waste

SECTION 01 57 19 Page 7

40 CFR 243 Guidelines for the Storage and Collection of Residential, Commercial, and Institutional Solid Waste

40 CFR 258 Subtitle D Landfill Requirements

40 CFR 260 Hazardous Waste Management System: General

40 CFR 261 Identification and Listing of Hazardous Waste

40 CFR 261.7 Residues of Hazardous Waste in Empty Containers

40 CFR 262 Standards Applicable to Generators of Hazardous Waste

40 CFR 262.31 Standards Applicable to Generators of Hazardous Waste-Labeling

40 CFR 262.34 Standards Applicable to Generators of Hazardous Waste-Accumulation Time

40 CFR 263 Standards Applicable to Transporters of Hazardous Waste

40 CFR 264 Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 265 Interim Status Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 266 Standards for the Management of Specific Hazardous Wastes and Specific Types of Hazardous Waste Management Facilities

40 CFR 268 Land Disposal Restrictions

40 CFR 273 Standards for Universal Waste Management

40 CFR 273.2 Standards for Universal Waste Management - Batteries

40 CFR 273.4 Standards for Universal Waste Management - Mercury Containing Equipment

40 CFR 273.5 Standards for Universal Waste Management - Lamps

40 CFR 279 Standards for the Management of Used Oil

40 CFR 300 National Oil and Hazardous Substances Pollution Contingency Plan

40 CFR 300.125 National Oil and Hazardous Substances Pollution Contingency Plan - Notification and Communications

SECTION 01 57 19 Page 8

40 CFR 302 Designation, Reportable Quantities, and Notification

40 CFR 355 Emergency Planning and Notification

40 CFR 403 General Pretreatment Regulations for Existing and New Sources of Pollution

40 CFR 50 National Primary and Secondary Ambient Air Quality Standards

40 CFR 60 Standards of Performance for New Stationary Sources

40 CFR 61 National Emission Standards for Hazardous Air Pollutants

40 CFR 68 Chemical Accident Prevention Provisions

40 CFR 63 National Emission Standards for Hazardous Air Pollutants for Source Categories

40 CFR 745 Lead-Based Paint Poisoning Prevention in Certain Residential Structures

40 CFR 761 Polychlorinated Biphenyls (PCBs) Manufacturing, Processing, Distribution in Commerce, and Use Prohibitions

49 CFR 171 - 178 Hazardous Materials Regulations

49 CFR 171 General Information, Regulations, and Definitions

49 CFR 172 Hazardous Materials Table, Special Provisions, Hazardous Materials Communications, Emergency Response Information, and Training Requirements

49 CFR 173 Shippers - General Requirements for Shipments and Packagings

49 CFR 178 Specifications for Packagings

1.3 DEFINITIONS

1.3.1 Active Nest

Active nest refers to any bird nest with eggs or chicks present.

1.3.2 Biological Opinion

The document that states the opinion of the US Fish & Wildlife Service and the National Marine Fisheries Service (NMFS) Provided in Appendix B Environmental) as to whether or not the Federal action is likely to jeopardize the continued existence of listed species or result in the destruction or adverse modification of critical habitat while specifying the extent of take allowed, the reasonable and prudent measures that would

SECTION 01 57 19 Page 9 minimize impacts from the federal action, and the terms and conditions with which the federal action agency must comply.

1.3.3 Class I and II Ozone Depleting Substance (ODS)

Class I ODS (Ozone Depleting Substance) is defined in Section 602(a) of The Clean Air Act. A list of Class I ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances.

Class II ODS (Ozone Depleting Substance) is defined in Section 602(s) of The Clean Air Act. A list of Class II ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances.

1.3.4 Contractor Generated Hazardous Waste

Contractor generated hazardous waste means materials that, if abandoned or disposed of, may meet the definition of a hazardous waste. These waste streams would typically consist of material brought on site by the Contractor to execute work, but are not fully consumed during the course of construction. Examples include, but are not limited to, excess paint thinners (i.e., methyl ethyl ketone, toluene etc.), waste thinners, excess paints, excess solvents, waste solvents, and excess pesticides, and contaminated pesticide equipment rinse water.

1.3.5 Cultural Resources

Cultural Resources covered in this section include but are not limited to:

any sites of Native American cultural or religious significance, human skeletal remains or burials; artifacts; shell, midden, bone, charcoal, or other deposits; rock alignments, pavings, wall, or other constructed features; and any indication of agricultural or other human activities.

1.3.6 Electronics Waste

Electronics waste is discarded electronic devices intended for salvage, recycling, or disposal.

1.3.7 Environmental Pollution and Damage

Environmental pollution and damage is the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances of importance to human life;

affect other species of importance to humankind; or degrade the environment aesthetically, culturally and/or historically.

1.3.8 Environmental Protection

Environmental protection is the prevention/control of pollution and habitat disruption or loss of habitat that may occur during construction. The control of environmental pollution, disruption or loss of habitat, and damage requires consideration of land, water, and air; biological and cultural resources; and includes management of visual aesthetics; noise;

solid, chemical, gaseous, and liquid waste; radiant energy and radioactive material as well as other pollutants.

SECTION 01 57 19 Page 10

1.3.9 Hazardous Debris

Debris, as defined in paragraph Solid Waste, that contains listed hazardous waste (either on the debris surface, or in its interstices, such as pore structure) in accordance with 40 CFR 261. Hazardous debris also includes debris that exhibits a characteristic of hazardous waste in accordance with

40 CFR 261.

1.3.10 Hazardous Materials

Hazardous materials as defined in 49 CFR 171 and listed in 49 CFR 172.

Hazardous material is any material that: Is regulated as a hazardous material in accordance with 49 CFR 173; or requires a Safety Data Sheet (SDS) in accordance with 29 CFR 1910.120; or during end use, treatment, handling, packaging, storage, transportation, or disposal meets or has components that meet or have potential to meet the definition of a hazardous waste as defined by 40 CFR 261 Subparts A, B, C, or D.

Designation of a material by this definition, when separately regulated or controlled by other sections or directives, does not eliminate the need for adherence to that hazard-specific guidance which takes precedence over this section for "control" purposes. Such material includes ammunition, weapons, explosive actuated devices, propellants, pyrotechnics, chemical and biological warfare materials, medical and pharmaceutical supplies, medical waste and infectious materials, bulk fuels, radioactive materials, and other materials such as asbestos, mercury, and polychlorinated biphenyls (PCBs).

1.3.11 Hazardous Waste

Hazardous Waste is any material that meets the definition of a solid waste and exhibit a hazardous characteristic (ignitability, corrosivity, reactivity, or toxicity) as specified in 40 CFR 261, Subpart C, or contains a listed hazardous waste as identified in 40 CFR 261, Subpart D.

1.3.12 Historic Properties

A historic property is a cultural resource that is listed or is eligible for listing on the National Register of Historic Places (NRHP).

1.3.13 Inactive Nest

Inactive nest refers to any bird nest without eggs or chicks present.

1.3.14 Land Application for Discharge Water

Land Application means spreading or spraying discharge water at a rate that allows the water to percolate into the soil. No sheeting action, soil erosion, discharge into storm sewers, discharge into defined drainage areas, or discharge into the "waters of the United States" is allowed.

Comply with Federal, State, and local laws and regulations.

1.3.15 Listed Bird Species

Listed bird species or "listed species" refers to any species of bird classified as threatened or endangered by the Federal government or by the State of California. It also refers to any species of bird classified as a Species of Special Concern by the State of California.

SECTION 01 57 19 Page 11

1.3.16 Non-Nesting Season

Non-nesting season refers to the period beginning on September 2 and continuing through February 14.

1.3.17 Municipal Separate Storm Sewer System (MS4) Permit

MS4 permits are those held by the Government to obtain NPDES permit coverage for their storm water discharges.

1.3.18 National Pollutant Discharge Elimination System (NPDES)

The NPDES permit program controls water pollution by regulating point sources that discharge pollutants into waters of the United States. Note:

the U.S. EPA delegates NPDES permitting authority to the State of California under the California pollutant Discharge Elimination System (UPDES) Program. See SECTION 01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL.

1.3.19 Oily Waste

Oily waste are those materials that are, or were, mixed with Petroleum, Oils, and Lubricants (POLs) and have become separated from that POLs. Oily wastes also means materials, including wastewaters, centrifuge solids, filter residues or sludges, bottom sediments, tank bottoms, and sorbents which have come into contact with and have been contaminated by, POLs and may be appropriately tested and discarded in a manner which is in compliance with other state and local requirements.

This definition includes materials such as oily rags, "kitty litter" sorbent clay and organic sorbent material. These materials may be land filled provided that: It is not prohibited in other state regulations or local ordinances; the amount generated is "de minimus" (a small amount); it is the result of minor leaks or spills resulting from normal process operations; and free-flowing oil has been removed to the practicable extent possible. Large quantities of this material, generated as a result of a major spill or in lieu of proper maintenance of the processing equipment, are a solid waste. As a solid waste, perform a hazardous waste determination prior to disposal. As this can be an expensive process, it is recommended that this type of waste be minimized through good housekeeping practices and employee education.

1.3.20 Pesticide

Pesticide is any substance or mixture of substances intended for preventing, destroying, repelling, or mitigating any pest, or intended for use as a plant regulator, defoliant or desiccant.

1.3.21 Pesticide Treatment Plan

A plan for the prevention, monitoring, and control to eliminate pest infestation.

1.3.22 Pests

Pests are arthropods, birds, rodents, nematodes, fungi, bacteria, viruses, algae, snails, marine borers, snakes, weeds and other organisms (except for human or animal disease-causing organisms) that adversely affect the well-being of personnel and animals; attack or damage real property, supplies, equipment, or vegetation; or are otherwise undesirable.

SECTION 01 57 19 Page 12

1.3.23 Regulated Waste

Regulated waste are solid wastes that have specific additional federal, state, or local controls for handling, storage, or disposal.

1.3.24 Sediment

Sediment is soil and other debris that have eroded and have been transported by runoff water or wind.

1.3.25 Solid Waste

Solid waste is a solid, liquid, semi-solid or contained gaseous waste. A solid waste can be a hazardous waste, non-hazardous waste, or non-Resource Conservation and Recovery Act (RCRA) regulated waste. Types of solid waste typically generated at construction sites may include:

1.3.25.1 Debris

Debris is non-hazardous solid material generated during the construction, demolition, or renovation of a structure that exceeds 2.5-inch particle size that is: a manufactured object; plant or animal matter; or natural geologic material (for example, cobbles and boulders), broken or removed concrete, masonry, and rock asphalt paving; ceramics; roofing paper and shingles. Reinforced inert materials with or containing ferrous wire, rods, accessories and weldments. A mixture of debris and other material such as soil or sludge is also subject to regulation as debris if the mixture is comprised primarily of debris by volume, based on visual inspection.

1.3.25.2 Green Waste

Green waste is the vegetative matter from landscaping, land clearing and grubbing, including, but not limited to, grass, bushes, scrubs, small trees and saplings, tree stumps and plant roots. Marketable trees, grasses and plants that are indicated to remain, be re-located, or be re-used are not included.

1.3.25.3 Material Not Regulated As Solid Waste

Material not regulated as solid waste is nuclear source or byproduct materials regulated under the Federal Atomic Energy Act of 1954 as amended;

suspended or dissolved materials in domestic sewage effluent or irrigation return flows, or other regulated point source discharges; regulated air emissions; and fluids or wastes associated with natural gas or crude oil exploration or production.

1.3.25.4 Non-Hazardous Waste

Non-hazardous waste is waste that is excluded from, or does not meet, hazardous waste criteria in accordance with 40 CFR 263.

1.3.25.5 Recyclables

Recyclables are materials, equipment and assemblies such as doors, windows, door and window frames, plumbing fixtures, glazing and mirrors that are recovered and sold as recyclable,wiring, insulated/non-insulated copper wire cable, wire rope, and structural components. It also includes

SECTION 01 57 19 Page 13 commercial-grade refrigeration equipment with Freon removed, household appliances where the basic material content is metal, clean polyethylene terephthalate bottles, cooking oil, used fuel oil, textiles, high-grade paper products and corrugated cardboard, stackable pallets in good condition, clean crating material, and clean rubber/vehicle tires. Metal meeting the definition of lead contaminated or lead based paint contaminated may not be included as recyclable if sold to a scrap metal company. Paint cans that meet the definition of empty containers in accordance with 40 CFR 261.7 may be included as recyclable if sold to a scrap metal company.

1.3.25.6 Surplus Soil

Surplus soil is existing soil that is in excess of what is required for this work, including aggregates intended, but not used, for on-site mixing of concrete, mortars, and paving. Contaminated soil meeting the definition of hazardous material or hazardous waste is not included and must be managed in accordance with paragraph HAZARDOUS MATERIAL MANAGEMENT.

1.3.25.7 Scrap Metal

This includes scrap and excess ferrous and non-ferrous metals such as reinforcing steel, structural shapes, pipe, and wire that are recovered or collected and disposed of as scrap. Scrap metal meeting the definition of hazardous material or hazardous waste is not included.

1.3.25.8 Wood

Wood is dimension and non-dimension lumber, plywood, chipboard, hardboard.

Treated or painted wood that meets the definition of lead contaminated or lead based contaminated paint is not included. Treated wood includes, but is not limited to, lumber, utility poles, crossties, and other wood products with chemical treatment.

1.3.26 Surface Discharge

Surface discharge means discharge of water into drainage ditches, storm sewers, creeks or "waters of the United States." Surface discharges are discrete, identifiable sources and require a permit from the governing agency. Comply with federal, state, and local laws and regulations.

1.3.27 Tribal Cultural Resources

Tribal cultural resources are defined as sites, features, places, cultural landscapes, sacred places, and objects with cultural value to a California Native American tribe that are either included or determined to be eligible for inclusion in the California Register of Historical Resources.

1.3.28 Trees

Unless otherwise indicated, the terms "tree" or "trees" refers to any native woody plant species having a diameter at breast height (DBH) equal to or greater than 1-inch.

1.3.29 Wastewater

Wastewater is the used water and solids from a community that flow to a treatment plant.

SECTION 01 57 19 Page 14

1.3.29.1 Storm Water

Storm Water is any precipitation in an urban or suburban area that does not evaporate or soak into the ground, but instead collects and flows into storm drains, rivers, and streams. See SECTION 01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL for construction storm water management requirements.

1.3.30 Waters of the United States

Waters of the United States means Federally jurisdictional waters, including wetlands, that are subject to regulation under Section 404 of the Clean Water Act or navigable waters, as defined under the Rivers and Harbors Act and 33 CFR 328.

1.3.31 Wetlands

Wetlands are those areas that are inundated or saturated by surface or ground water at a frequency and duration sufficient to support, and that under normal circumstances do support, a prevalence of vegetation typically adapted for life in saturated soil conditions. Wetlands generally include swamps, seasonal, semi-permanent, and permanent marshes, and bogs, and thereby, are considered as waters of the United States. Official determination of whether or not an area is classified as a wetland must be done in accordance with TR Y-87-1 and the ERDC/EL TR-08-28. Use these documents to determine the limits or boundaries of jurisdictional Waters of the United States (which include wetlands).

1.3.32 Universal Waste

The universal waste regulations streamline collection requirements for certain hazardous wastes in the following categories: batteries, pesticides, mercury-containing equipment (for example, thermostats), and lamps (for example, fluorescent bulbs). The rule is designed to reduce hazardous waste in the municipal solid waste (MSW) stream by making it easier for universal waste handlers to collect these items and send them for recycling or proper disposal. These regulations can be found at

40 CFR 273.

1.4 GENERAL REQUIREMENTS

Minimize environmental pollution and damage that may occur as the result of construction operations. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work during the entire duration of this contract. Comply with all applicable environmental Federal, State, local laws, regulations, and mitigation requirements, including but not limited to authorized project permits and biological opinions (BO). Any delays resulting from failure to comply with environmental laws and regulations are the Contractor's responsibility.

1.4.1 Subcontractors

Ensure compliance with this section by subcontractors.

1.5 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for When used, a designation following the "G" designation identifies the office that will review the

SECTION 01 57 19 Page 15 submittal for the Government. Submittals with the "DO" designation are for Sacramento District Office approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Preconstruction Survey; G, DO

Solid Waste Management Permit; G

Regulatory Notifications; G, DO

Environmental Protection Plan; G, DO

Environmental Permit Application; G, DO

Dirt And Dust Control Plan; G

Air Quality Control Plan; G

Waste Water Management Plan; G

Asbestos Dust Mitigation Plan and Application; G, DO

Water Quality Management Plan; G, DO

Water Quality Monitoring Plan; G, DO

Pesticide Treatment Plan; G, DO

Historical Protection Plan; G

Archaeological Protection Plan; G

Cultural Resources Protection Plan; G

Biological Resources And Wetlands Protection Plan; G

Traffic Control Plan; G

Storm Water Notice Of Intent; G

Stormwater Pollution Prevention Plan; G

Inventory Of All Off-Road Construction Equipment; G

Archaeological Monitor Qualifications; G

Restoration Plan; G, DO

Archaeological Monitor

SD-06 Test Reports

Laboratory Analysis

Air Quality Control Plan Reports; G, DO

Water Quality Monitoring Results

SECTION 01 57 19 Page 16

Fish Take Reports; G, DO

Non-hazardous Solid Waste Diversion Report

Monthly Solid Waste Disposal Report

Project Solid Waste Disposal Documentation Report Inspection Reports

SD-07 Certificates

Employee Training Records; G

Erosion And Sediment Control Inspector

Biological Monitor; G

SD-11 Closeout Submittals

Waste Determination Documentation; G

Hazardous Waste/Debris Management; G

Disposal Documentation For Hazardous And Regulated Waste; G

Assembled Employee Training Records; G

Post-Construction Survey; G

Sales Documentation; G

Contractor Certification

Environmental Records Binder

Solid Waste Disposal Closeout Report

Project Solid Waste Disposal Documentation Report

Stormwater Pollution Prevention Plan Compliance Notebook; G

Stormwater Notice Of Termination; G

As-Built Topographic Survey

1.6 ENVIRONMENTAL PROTECTION REQUIREMENTS

Provide and maintain, during the life of the contract, environmental protection as defined. Plan for and provide environmental protective measures to control pollution that develops during construction practice.

Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work during the entire duration of this Contract. Comply with federal, state, and local regulations pertaining to the environment, including water, air, solid waste, hazardous waste and substances, oily substances, and noise pollution.

SECTION 01 57 19 Page 17

Tests and procedures assessing whether construction operations comply with Applicable Environmental Laws may be required. Qualified laboratories must perform the analytical work; and where required by law, the laboratories must be certified.

1.6.1 Protection Features

This paragraph supplements the Contract Clause PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS. Prior to start of any onsite construction activities, the Contractor and the Contracting Officer will make a joint condition survey. Immediately following the survey, prepare a brief report including a plan describing the features requiring protection under the provisions of the Contract Clauses, which are not specifically identified on the drawings as environmental features requiring protection along with the condition of trees, shrubs and grassed areas immediately adjacent to the site of work and adjacent to the assigned storage areas and access routes as applicable. Both the Contractor and the Contracting Officer will sign this survey report upon mutual agreement as to its accuracy and completeness.

Protect those environmental features included in the survey report and any indicated on the drawings, regardless of interference which their preservation may cause to the work under the contract.

1.7 QUALIFICATIONS

1.7.1 Archaeological Monitor

The Archaeological Monitor must have demonstrated staff capabilities including osteologists, historian(s), and other specialists as necessary;

excavation and testing equipment; and laboratory and storage facilities sufficient to accomplish all tasks specified in this section. Subject matter specialists such as osteologists and historians must be available to consult as needed to assist in identification of post-review discoveries.

The Archaeological Monitor must demonstrate experience conducting archaeological monitoring, archaeological site testing, site recordation, National Register of Historical Places evaluations, data recovery and analysis, and all aspects of report preparation, to include GIS mapping and analysis. The Archaeological Monitor must provide Field Monitors to observe all project-related ground disturbing activities.

The Archaeological Monitor must designate one or more Lead Field Monitors.

A Lead Field Monitor must be present whenever archaeological monitoring is required.

Submit evidence of the Archaeological Monitor qualifications, including the individual qualifications of all Archaeological Field Monitor(s), to the Contracting Officer for approval, no less than thirty days prior to starting ground disturbing activity.

1.7.1.1 Lead Field Monitors

Lead Field Monitors must have a graduate degree in archaeology, anthropology, or closely related field and meet the Secretary of the Interior's Professional Qualifications Standards for Archaeology, and additional requirements, as follows:

a. At least one year of full-time professional archaeological experience;

SECTION 01 57 19 Page 18

b. At least four months of supervised field and analytic experience in general North American archaeology;

c. Demonstrated ability to identify and assess subsurface and surface archaeological deposits;

d. Demonstrated ability to complete National Register of Historic Places (NRHP) evaluations for cultural resources;

e. Demonstrated ability to carry archaeological research to completion;

1.7.1.2 Other Field Monitors

Other Archaeological Field Monitors must hold the following standards:

a. Bachelor's degree in Archaeology, Anthropology, or closely related field;

b. At least four months of supervised field and analytic experience in general North American archaeology;

1.7.2 Biological Monitor

Contractor's Biological Monitor(s) must meet the following qualifications pertaining to sensitive species in the project area:

a. Demonstrates experience with construction level biological monitoring, and experience analyzing impacts of development on sensitive species in the project area and their habitats;

b. Able to recognize the sensitive species in the project area;

c. Familiar with the natural history, ecology, habitat, and behavior of those species;

d. Familiar with the appropriate state and federal statutes related to those species, scientific research, and conservation;

e. Bachelor's degree or has an equivalent professional experience in biological sciences and related natural resources management activities as it pertains to this project.

Biologists monitoring a given species (or group of species) described herein must also satisfy all requirements for biologists monitoring that particular species (or group of species), in accordance with the BIOLOGICAL RESOURCES paragraph.

1.8 SPECIAL ENVIRONMENTAL REQUIREMENTS

Avoid conflicts between construction operations and regular hunting seasons in the bypass from 1 September through 31 January, unless otherwise directed by the Contracting Officer, and in accordance with applicable hunting and safety regulations. Install and maintain safety barrier, signage, or other visible demarcation during construction, in accordance with Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and Section 01 50 00

TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS.

SECTION 01 57 19 Page 19

1.9 QUALITY ASSURANCE

1.9.1 Preconstruction Survey And Protection Of Features

This paragraph supplements the Contract Clause PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS. Prior to start of any onsite construction activities, perform a Preconstruction Survey of the project site with the Contracting Officer, and take photographs showing existing environmental conditions in and adjacent to the site. Submit a report for the record. Include in the report a plan describing the features requiring protection under the provisions of the Contract Clauses, which are not specifically identified on the drawings as environmental features requiring protection along with the condition of trees, shrubs and grassed areas immediately adjacent to the site of work and adjacent to the Contractor's assigned storage area and access route(s), as applicable. The Contractor and the Contracting Officer will sign this survey report upon mutual agreement regarding its accuracy and completeness. Protect those environmental features included in the survey report and any indicated on the drawings, regardless of interference that their preservation may cause to the work under the Contract.

1.9.2 Regulatory Notifications

Provide regulatory notification requirements in accordance with federal, state and local regulations. In cases where the Government will also provide public notification (such as storm water permitting), coordinate with the Contracting Officer and Government Environmental Office. Submit copies of regulatory notifications to the Contracting Officer within 14 days prior to commencement of work activities, unless otherwise directed by the Contracting Officer. Typically, provide regulatory notifications for the following (this listing is not all-inclusive): demolition, renovation, NPDES defined site work, construction, removal or use of a permitted air emissions source, and remediation of controlled substances (asbestos, hazardous waste, lead paint).

1.9.3 Environmental Brief

Attend an environmental brief included in the preconstruction meeting.

Discuss the results of the Preconstruction Survey at this time.

Prior to initiating any work on site, meet with the Contracting Officer to discuss the proposed Environmental Protection Plan (EPP). Develop a mutual understanding relative to the details of environmental protection, including measures for protecting natural and cultural resources, required reports, required permits, permit requirements (such as mitigation measures), and other measures to be taken.

1.9.4 Environmental Manager

The Government's Environmental Manager will be designated for the project, in addition to the Contractor's QC. The Environmental Manager will provide direct guidance to the Contracting Officer and Contracting Office Representative related to compliance with federal, state, and local, requirements. The Environmental Manager must ensure that the Contractor is in compliance with all environmental commitments, including avoidance and minimization measures; implementation of the EPP; Storm Water Program requirements; and will ensure that all environmental permits are obtained, complied with, maintained, and closed out. The Environmental Manager can request that the Contracting Officer issue a stop work order if the

SECTION 01 57 19 Page 20

Contractor is in noncompliance with any environmental commitments or compliance with federal, state, and local requirements.

1.9.5 Employee Training Records

Prepare and maintain Employee Training Records throughout the term of the contract meeting applicable 40 CFR requirements. Provide Employee Training Records in the Environmental Records Binder. Provide a Position Description for each employee, by subcontractor, based on the Davis-Bacon Wage Rate designation or other equivalent method, evaluating the employee's association with hazardous and regulated wastes. Submit these Assembled Employee Training Records to the Contracting Officer at the conclusion of the project, unless otherwise directed.

Train personnel to meet federal, state, and local requirements. Attend environmental protection and applicable pollution control meetings for personnel prior to commencing construction activities. Contact the Government's Environmental Manager to arrange additional meetings for new personnel and when site conditions change. Provide copy of the Erosion and Sediment Control Inspector Qualifications as defined by EPA Certification as required by California.

1.9.6 Non-Compliance Notifications

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with federal, state or local environmental laws or regulations, permits, and other elements of the Contractor's EPP, Environmental Protection Plan. After receipt of such notice, inform the Contracting Officer of the proposed corrective action and take such action when approved by the Contracting Officer. The Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. FAR 52.242-14 Suspension of Work provides that a suspension, delay, or interruption of work due to the fault or negligence of the Contractor allows for no adjustments to the contract for time extensions or equitable adjustments. Any additional time that occurs due to noncompliance with environmental laws and regulations must be at the Contractor's expense. In addition to a suspension of work, the Contracting Officer may use additional authorities under the contract or law.

1.10 ENVIRONMENTAL PROTECTION PLAN

The purpose of the Environmental Protection Plan (EPP) is to present an overview of known or potential environmental issues that must be considered and addressed during construction. Include in the EPP measures for protecting natural and cultural resources, required reports, and other measures to be taken to ensure compliance with environmental laws and regulations. Meet with the Contracting Officer and the Government's Environmental Manager to discuss the EPP and develop a mutual understanding relative to the details for environmental protection including measures for protecting natural resources, required reports, and other measures to be taken. Submit the EPP within 15 days after execution of notice to proceed and not less than 10 days before the preconstruction meeting. Define issues of concern within the EPP as outlined in this section. Address each topic at a level of detail commensurate with the environmental issue and required construction task(s). Identify and discuss topics or issues which are not identified in this section, but are considered necessary after those items formally identified in this section. The Environmental Engineer must meet the respective Experience Matrix requirements of SECTION

SECTION 01 57 19 Page 21

01 45 00 CONTRACTOR QUALITY CONTROL. Develop, enforce, and revise the EPP throughout the project to include any reporting requirements, changes in site conditions, or contract modifications that change the project scope of work in a way that could have an environmental impact. No requirement in this section relieves the Contractor of any applicable federal, state, and local environmental protection laws and regulations.

Conduct an EPP meeting one week after NTP is executed by the Contracting Officer. Request and schedule the meeting to be held at the Resident Office. The following contractor representatives must be present: the Project Manager (or appropriate technical person), and the environmental staff. Prepare to discuss implementation of the initial EPP; the process for future subsequent additions and revisions to the plan as necessary, including any reporting requirements; and methods for administration of the Environmental Plans. This meeting is required prior to Government approval of the EPP submittal.

The EPP includes, but is not limited to, the following elements:

1.10.1 General Overview and Purpose

1.10.1.1 Descriptions

A brief description of each specific plan required by environmental permit or elsewhere in this Contract such as storm water pollution prevention plan, spill control plan, solid waste management plan, wastewater management plan, air pollution control plan, contaminant prevention plan, a historical, archaeological, cultural resources, biological resources and wetlands protection plan, traffic control plan Hazardous, Toxic and Radioactive Waste (HTRW) Plan Non-Hazardous Solid Waste Disposal Plan borrowing material plan.

1.10.1.2 Duties

The duties and level of authority assigned to the person(s) on the job site who oversee environmental compliance, including the following, if applicable:

a. Name(s) and qualifications of person(s) within the Contractor's organization who is(are) responsible for ensuring adherence to the EPP.

b. Name(s) and qualifications of person(s) responsible for manifesting hazardous waste to be removed from the site, if applicable.

c. Name(s) and qualifications of person(s) responsible for training the Contractor's environmental protection personnel.

d. Name(s) and qualifications of person(s) responsible for spill cleanup and training personnnel on spill response procedures.

e. Description of the Contractor's environmental protection personnel training program.

1.10.1.3 Procedures

A copy of any standard or project-specific operating procedures that will be used to effectively manage and protect the environment on the project site.

SECTION 01 57 19 Page 22

1.10.1.4 Communications

Communication and training procedures that are used to convey environmental management requirements to Contractor employees and subcontractors.

1.10.1.5 Contact Information

Emergency contact information (office phone number, cell phone number, and e-mail address).

1.10.2 General Site Information

1.10.2.1 Drawings

Drawings showing locations of proposed temporary excavations or embankments for haul roads, stream crossings, jurisdictional wetlands, material storage areas, structures, sanitary facilities, dewatering features,storm drains and conveyances, and stockpiles of excess soil or spoil materials including methods to control runoff and to contain materials on the site. Drawings showing in-water structures, equipment locations, and material placement and disposal sites. Also, drawing showing the location of borrow areas.

1.10.2.2 Work Area

Work area plan showing the proposed activity in each portion of the area and identify the areas of limited use or nonuse. Include measures for marking the limits of use areas, including methods for protection of features to be preserved within authorized work areas and methods to control runoff and to contain materials on site, and a traffic control plan.

1.10.2.3 Traffic Control Plan

Develop a Traffic Control Plan before start of construction activities and submit for approval. Include measures to reduce erosion of temporary roadbeds by construction traffic, especially during wet weather. Also include measures to minimize the amount of mud transported onto paved public roads by vehicles or runoff. Provide temporary traffic control devices as required with the CDT MUTCD in accordance with Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS. As appropriate, include slow-moving-vehicle warning signs, barriers for separating construction and non-construction traffic, use of traffic-control flagmen, and any additional measures required for the sole convenience of non-construction traffic to safely pass through and around construction areas and access points thereto. The Traffic Control Plan must include recreational traffic such as bicycles and pedestrians.

Implement the following measures:

1)…