W9123819B0018.pdf

MOTCO Roads Renovation, Military Ocean Terminal, Concord, CA.

Estimated Magnitude of Construction IAW FAR 36.204(h) more than $10,000,000 NAICS Code: 237310 - Highw ay, Street, and Bridge Construction Small Business Size Standard: $36,500,000 This requirement is set-aside for Small Businesses

The Contractor shall provide all labor, materials, tools and equipment necessary for construction of this project titled MOTCO Roads Renovation, Military Ocean Terminal, Concord, CA. Work includes demolition and full depth replacement of existing White Road West and Center (broken into White Road West and White Road Center design packages) and existing Johnson Road. See project specif ications and draw ings for more details.

Per FAR 3.101, 15.201(f) and 15.303(c), to preserve procurement integrity, all contacts shall go to either the Contracting Off icer and/or Contract Specialist. Contacts to others regarding this solicitation may result in the disqualif ication of the offeror or cancellation of the solicitation. Disqualif ication w ill be the result of any communication that explicitly or implicitly, intentionally or unintentionally gives one prospective offeror a competitive advantage or the mere appearance of a competitive advantage over that of another.

X

KENLEY LOTT 916-557-5326

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

31-Jul-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________03 Sep 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USACE SACRAMENTO DISTRICT

ATTN: CONTRACTING DIVISION

1325 J STREET

SACRAMENTO CA 95814-2922

W91238

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9123819B0018 49

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W9123819B0018

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 01 Attachment 01 -

Statement of Work

2 27-JUN-2019

Attachment 02 Attachment 02 - Specifications Section 01 11 00

5 27-JUN-2019

Attachment 03 Attachment 03 - Specifications

702 27-JUN-2019

Attachment 04 Attachment 04 - White Road West Drawings

37 15-MAR-2019

Attachment 05 Attachment 05 - White Road Center Drawings

16 15-MAR-2019

Attachment 06 Attachment 06 - Johnson Road Drawings

49 15-MAR-2019

Attachment 07 Attachment 07 - Davis Bacon Act Wage Determinations

122 03-MAY-2019

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job White Road West

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct White Road West Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

FOB: Destination

SIGNAL CODE: A

NET AMT

0002 1 Job White Road Center

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct White Road Center Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

0003 1 Job Johnson Road

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct Johnson Road Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications. Exclude work to be included in optional bid items.

1001 1 Job OPTION Johnson Road Elect, Comm, Lighting

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation to construct all new electrical, communications, and lighting tasks identified as "OPTION" on contract plan sheets E101, E102, E103, E104, E105, E106, and E107 for Johnson Road Repair, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

1002 1 Job OPTION Johnson Road Demolition

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation for all demolition tasks identified on contract plan sheets ED101, ED102, ED103, ED104, ED105, and ED106, for Johnson Road Repair, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all ssociated documents, drawings, and specifications.

1003 10 Days OPTION Delay of Construction (NTE 10 days)

FFP

Delay of Construction - Demobilization and remobilization during stand down at Military Ocean Terminal, Concord, CA (NTE 10 days in duration).

1004 45 Days OPTION Delay of Constructon (NTE 45 days)

FFP

Delay of Construction - Demobilization and remobilization during stand down at Military Ocean Terminal, Concord, CA (NTE 45 days in duration).

1005 1 Job OPTION UXO/MEC Removal/Disposal

FFP

Provide all labor, management, supervision, tools, materials, equipment, and transportation to remove and dispose of UXO/MEC discovered during construction at Military Ocean Terminal, Concord, CA, in accordance with all this contract and all associated documents, drawings, and specifications.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 365 dys. ANP 1 MOTCO RESIDENT OFFICE

CHELAN SCHREIFELS

410 NORMAN AVENUE, BLDG 901

CONCORD CA 94520

916-557-6684

W91238

0002 365 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 365 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1001 365 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1002 365 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1003 365 dys. ANP 10 (SAME AS PREVIOUS LOCATION)

1004 365 dys. ANP 45 (SAME AS PREVIOUS LOCATION)

1005 365 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section 00 20 00 - Instructions for Procurement

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.215-16 Facilities Capital Cost of Money JUN 2003 52.217-5 Evaluation Of Options JUL 1990 52.225-12 Notice of Buy American Requirement - Construction

Materials Under Trade Agreements

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.215-7008 Only One Offer OCT 2013

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

U.S. Army Corps of Engineers, Sacramento District ATTN: Construction Contracting Officer, Room 878

1325 J Street Sacramento, CA 95814

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

www. acquisition.gov

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

None

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Department of Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 21 13 - Instructions to Bidders

INSTRUCTIONS TO BIDDERS

GENERAL INSTRUCTIONS

INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDER

The following documents must be returned with your bid.

--The completed Standard Form 1442 with continuation pages, duly executed with an original signature by an official authorized to bind the company. Ensure that the firm’s DUNS or DUNS+4 Number is entered in the block with its name and address.

--Your acknowledgement of any and all Amendments to the solicitation in accordance with the instructions on the Standard Form 30 Amendment.

Note: If the SF 1442 and/or the pricing schedule was changed by amendment, be sure to use the amended pages when submitting your quote, bid, or offer.

--Your completed Representations, Certifications, and Other Statements of Offerors (Section 00 45 00).

--The completed CLIN Schedule with your proposed contract line item prices inserted in the appropriate spaces.

Prices must be proposed for all contract line items. Unit prices are to be extended to the actual “dollar and cents” amounts (i.e., to two decimal places). Do not round off extended prices to the nearest dollar. Check your pricing submission very carefully for mathematical and clerical errors prior to submission.

--Your Bid Guarantee (e.g., Standard Form 24, “Bid Bond”)

-- Any other documents required by the solicitation (see Attachments and/or Section 00 22 13)

DIRECTIONS FOR SUBMITTING BIDS:

Bids shall be mailed to the address below no later than the date and time identified in Block 13A of the SF1442.

Bids shall include the original, one copy, and electronic bid copy in PDF format on a CD-ROM.

US Army Corps of Engineers, Sacramento District Attn: Kenley Lott, Contracting Division, Room 878

1325 J Street Sacramento, CA 95814

Please clearly mark all envelopes/packages with the Solicitation Number W9123819B0018

SPECIAL INSTRUCTION PERTAINING TO HAND-CARRIED BIDS:

Hand-carried offers must be delivered to 1325 J Street, Sacramento, CA.

Due to security precautions, bidders may no longer hand-carry their bids directly to the Contracting Division. Bids may NOT be turned-in at the Security Desk or left unattended elsewhere in the building lobby. Additionally, you are advised that there is no public parking in the Building.

The contract specialist will be in the Building Lobby 20 minutes prior to the closing time to accept hand-carried offers.

Offerors who desire to hand-deliver their bids at an earlier time must coordinate with the contract specialist in advance in order to arrange to be met in the Building Lobby by a Contracting Division personnel.

Please ensure that all courier and delivery personnel are aware of these procedures.

CONTRACTOR RESPONSIBILITY, PREAWARD SURVEY:

In order to determine a contractor's responsibility for purposes of contract award in accordance with FAR Part 9, the contractor is required to provide a statement regarding previous experience and past performance in performing comparable work, information related to the business organization, financial resources, and/or plant to be used in performing the work (see Section 00 22 13 for a sample Pre-award Survey, including Schedules A-C). All bidders will complete and return the Preaward Survey as part of the Price/Cost proposal. Failure to submit the Pre-award Survey in conjunction with the price proposal will not of itself render the offer unacceptable.

In order to be determined to be responsible a prospective contractor must be determined responsible in accordance with FAR 9.104-1.

The Pre-Award Survey is a tool used by the Government to help determine an bidder’s responsibility.

If a bidder’s Pre-Award Survey demonstrates a lack of sufficient resources, acceptable evidence of "the ability to obtain" the required, adequate resources (all of the resources discussed in FAR 9.104-1) may be shown by submission of evidence with the Pre-Award Survey of a commitment or explicit arrangement to rent, purchase or otherwise acquire the needed facilities, equipment, other resources, or personnel as of the date of contract award.

AVAILABILITY OF CORPS OF ENGINEERS PUBLICATIONS DESCRIPTIONS:

a. The internet URL for Corps of Engineers publications is:

http://www.publications.usace.army.mil/

b. Construction Criteria Base (CCB). The Construction Criteria Base (CCB) system available through the National Institute of Building Sciences includes copies of Corps of Engineers methods and specifications. Information about the CCB can be obtained from: http://www.wbdg.org/ccb/ccb.php

PERFORMANCE AND PAYMENT BONDS:

The bidder/offeror whose bid/offer is accepted will, within the time established in the contract, furnish performance and payment bonds in accordance with FAR 52.228-15.

ACCEPTANCE OF OFFERS:

A written award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party.

System for Award Management (SAM) Registration:

It is a requirement that any and all contractors that intend to do business with the government must be registered in the System for Award Management (SAM) database. No contract may be awarded by the government to any contractor who is not registered in SAM. If your company is not registered in SAM, you must register in order to be eligible for any government award.

https://www.sam.gov/portal/public/SAM/

If you have difficulties with or questions regarding the SAM registration, the following link has been set up by the Defense Logistics Agency (DLA) to assist contractors registering for CAGE codes for enrollment and navigation within SAM:

https://www.logisticsinformationservice.dla.mil/CAGETier3/

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- August 15, 2019 at 10am.

(c) Participants will meet at-- Military Ocean Terminal Concord

5110 Port Chicago Hwy Concord, CA 94520

*** All intended attendees must submit the following documents no later than August 8, 2019 by COB to the following email inbox, MOTCO_CORRESPONDENCE@usace.army.mil and cc the Contract Specialist, Kenley Lott. Any late adds will be on a case by case basis. ***

1) Base Access Request

2) MOTCO Form 190-3-R1

3) NCIC Consent Form

Section 00 22 13 - Supplementary Instructions to Bidders

PRE-AWARD SURVEY

PRE-AWARD SURVEY

CONSTRUCTION CONTRACTOR DATA DATE:

Firm Name and Telephone Number Main Office Address (Street, City, and State)

Branch Offices Services Rendered Construction Design Consultant

Organization Individual Joint Venture Partnership Corporation

Date Organized Date Incorporated:

State:

Names of Officers and Other Key Personnel

I – PRESENT PAYROLL PERSONNEL (List Number of Each Category Below) Partners:

Officers:

Other Key:

Remainder: Subtotal Permanent:

Maximum Personnel at Any Time:

Date:

Total:

II—EQUIPMENT OWNED III—FINANCIAL DATA AS OF

(DATE): Present Value ($)

Current Assets:

Acquisition Cost ($) Current Liabilities:

Net Worth:

IV—TOTAL VALUE OF CONSTRUCTION AND DEMOLITION WORK

IN PAST 6 YRS EXCLUSIVE OF JOINT VENTURE (LIST MOST

RECENT FIRST)

V—LARGEST JOB EVER

CONTRACTED

(If Other Than in Past Six Years)

$ LARGEST JOB IN PAST 6 YRS Contract Amount:

Date:

Description:

Owner:

$ Contract Amount:

Date:

Description:

Owner:

Avg. Annual Income

VI—TYPE OF WORK IN WHICH FIRM SPECIALIZES

NAME AND POSITION/TITLE OF PERSON SIGNING SIGNATURE

See attachment for explanations or detailed description of item(s) reported above.

CONSTRUCTION CONTRACTOR DATA – SCHEDULE A – EXISTING COMMITMENTS

List below the construction projects your firm currently has under way, including recent awards. Also list construction projects for which your firm is the apparent successful offeror/bidder, but for which a contract has not yet been awarded.

CONTRACT

NUMBER

AMOUNT

DESCRIPTION/

LOCATION

ORGANIZATION/

CONTACT PERSON/

PHONE NUMBER

PERCENT

COMPLETE

CONSTRUCTION CONTRACTOR DATA – SCHEDULE B – COMPLETED PROJECTS

List below the principal construction projects your firm has completed within the past five years, including all DoD contracts with a total value exceeding $10,00,000.00.

NUMBER

AMOUNT

DESCRIPTION/

LOCATION

ORGANIZATION/

CONTACT PERSON/

PHONE NUMBER

PERCENT

SUBLET

CONSTRUCTION CONTRACTOR DATA – SCHEDULE C –

CONSTRUCTION AND/OR TECHNICAL EQUIPMENT

List total equipment and facilities owned for performing the prospective contract and present status as to whether or not it is currently committed to existing contracts.

QUANTITY

DESCRIPTION

CONDITION

YEARS OF

SERVICE

PRESENT

STATUS

SUPPLEMENTARY INSTRUCTIONS

INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

INQUIRIES:

Prospective offerors should submit inquiries related to this solicitation in accordance with the following (collect calls will not be accepted):

a. For information related to amendments, and the dates set for receipt of bids, please check http://www.fedbizopps.gov

b. Contractual and Technical inquiries and questions relating to bidding procedures are to be submitted via Bidder Inquiry in ProjNet at https://www.projnet.org/projnet.

1. To submit and review bid inquiry items, offerors will need to be a current registered user or self-register into the system. To self-register go to the aforementioned web page and click on the QUICK ADD link. Select agency as USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your e-mail address, and then click continue. Fill in all required information and click Add User.

2. From this page you may view all bidder inquiries or add an inquiry.

3. Bidders will receive an acknowledgement of their question via e-mail, followed by an answer to their question after it has been processed.

4. The Solicitation Number is: W9123819B0019 The Bidder Inquiry Key is: FKIC8M-864747

c. The Bidder Inquiry System will be available until close of business 23 August 2019, prior to bid submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary.

d. Offerors are requested to review the specification in its entirety, and review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

e. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

f. Offers will WILL be publicly opened. Information concerning the status of the evaluation and/or award will NOT be available after receipt of bids.

g. The point of contact for this solicitation is:

Contract Specialist: Kenley Lott Telephone: (916) 557-5326 E-MAIL: Kenley.Lott@usace.army.mil

Section 00 45 00 - Representations and Certifications

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.222-25 Affirmative Action Compliance APR 1984 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

X (i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-12 CERTIFICATION REGARDING TAX MATTERS (FEB 2016)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5,000,000 (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of 1986; and

(3) Has not [ ], more than 90 days prior to certification, been notified of any unpaid Federal tax assessment for which the liability remains unsatisfied, unless the assessment is the subject of an installment agreement or offer in compromise that has been approved by the Internal Revenue Service and is not in default, or the assessment is the subject of a non-frivolous administrative or judicial proceeding.

252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (NOV 2011)

(a) Definition. Covered DoD official is defined in the clause at 252.203-7000, Requirements Relating to Compensation of Former DoD Officials.

(b) By submission of this offer, the offeror represents, to the best of its knowledge and belief, that all covered DoD officials employed by or otherwise receiving compensation from the offeror, and who are expected to undertake activities on behalf of the offeror for any resulting contract, are presently in compliance with all post-employment restrictions covered by 18 U.S.C. 207, 41 U.S.C. 2101-2107, and 5 CFR parts 2637 and 2641, including Federal Acquisition Regulation 3.104-2.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2019)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

252.223-7001 HAZARD WARNING LABELS (DEC 1991)

(a) "Hazardous material," as used in this clause, is defined in the Hazardous Material Identification and Material Safety Data clause of this contract.

(b) The Contractor shall label the item package (unit container) of any hazardous material to be delivered under this contract in accordance with the Hazard Communication Standard (29 CFR 1910.1200 et seq). The Standard requires that the hazard warning label conform to the requirements of the standard unless the material is otherwise subject to the labeling requirements of one of the following statutes:

(1) Federal Insecticide, Fungicide and Rodenticide Act;

(2) Federal Food, Drug and Cosmetics Act;

(3) Consumer Product Safety Act;

(4) Federal Hazardous Substances Act; or

(5) Federal Alcohol Administration Act.

(c) The Offeror shall list which hazardous material listed in the Hazardous Material Identification and Material Safety Data clause of this contract will be labeled in accordance with one of the Acts in paragraphs (b)(1) through

(5) of this clause instead of the Hazard Communication Standard. Any hazardous material not listed will be interpreted to mean that a label is required in accordance with the Hazard Communication Standard.

MATERIAL (If None, Insert "None.") ACT

(d) The apparently successful Offeror agrees to submit, before award, a copy of the hazard warning label for all hazardous materials not listed in paragraph (c) of this clause. The Offeror shall submit the label with the Material Safety Data Sheet being furnished under the Hazardous Material Identification and Material Safety Data clause of this contract.

(e) The Contractor shall also comply with MIL-STD-129, Marking for Shipment and Storage (including revisions adopted during the term of this contract).

(End of clause)

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government 1003 Destination Government Destination Government 1004 Destination Government Destination Government 1005 Destination Government Destination Government

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-2 Security Requirements AUG 1996 52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-18 Variation in Estimated Quantity APR 1984

52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.215-13 (Dev) Subcontractor Certified Cost or Pricing Data - Modifications

(Deviation 2018-O0015)

JUL 2018

52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION 2019-O0003).

JAN 2019

52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-9 Alt I (Dev) Small Business Subcontracting Plan (Deviation 2018-O0018)

- Alternate I

AUG 2018

52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons JAN 2019 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.226-1 Utilization Of Indian Organizations And Indian-Owned

Economic Enterprises

JUN 2000

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable…