A07.23_-_Attachment_02_-_Specifications_Section_01_11_00.pdf

MOTCO ROAD REPAIRS

CONCORD, CALIFORNIA

Section 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes demolition and reconstruction for White Road West Repair, White Road Center Repair, Johnson Road Repair and incidental related work.

1.1.2 Location

The work is located at Military Ocean Terminal, Concord, California as indicated on the contract drawings.

1.2 OCCUPANCY OF PREMISES

Adjacent building(s) and facilities will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Verify the elevations of existing piping, utilities, and any type of underground or encased obstruction not indicated, or specified to be removed. Verify elevations before installing new work closer than

Section 01 11 00 Page 2 nearest manhole or other structure at which an adjustment in grade can be made.

1.4.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.5 CLIN BREAKDOWN SCHEDULE

BASE CLIN 0001: Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct White Road West Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

BASE CLIN 0002: Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct White Road Center Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

BASE CLIN 0003: Provide all labor, management, supervision, tools, materials, equipment, and transportation to demolish and reconstruct Johnson Road Repair, including electrical manholes, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications. Exclude work to be included in optional bid items.

a. The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including subcontractor manpower) required for performance of this contract. The Contractor shall verify information input by the Government and completely fill in all other required fields in the reporting system using the following web address:

www.ecmra.mil.

b. The required information includes but is not limited to: (1) Contracting Organization, Contracting Officer, Contracting Officer's Technical Representative (COR/COTR); (2) Contract number, including task and delivery order number; (3) Fiscal year covered by reporting period; (4) Contractor name, address, phone number, e-mail address, identity of contractor employee entering data; (5) Direct labor hours (including Subcontractors); (6) Direct labor dollars paid this reporting period (including Subcontractors); (7) Total invoiced amount (including Subcontractors); (8) Predominant Federal Service Code (FSC) reflecting services provided by Contractor (and separate predominant FSC for each Subcontractor if different); (9) Organizational title associated with the Unit Identification Code (UIC) for the Army Requiring Activity (the Army Requiring Activity is responsible for providing the contractor with its UIC for the purposes of reporting this information;

and (10) Locations where Contractor and Subcontractors perform the work (specified by zip code in the United States and nearest city, country, when in an overseas location, using standardized nomenclature provided on website). As part of its submission, the Contractor will also provide the estimated total cost (if any) incurred to comply with this reporting requirement.

Section 01 11 00 Page 3

c. Reporting period will be the period of performance not to exceed 12 months ending September 30 of each Government fiscal year and must be reported by 31 October of each calendar year. Contractors may use a direct XML data transfer to the database server or fill in the fields on the website. The XML direct transfer is a format for transferring files from a Contractor's systems to the secure website without the need for separate data entries for each required data element at the website. The specific formats for the XML direct transfer may be downloaded from the website.

Information from the secure website is considered to be proprietary in nature when the contract number and Contractor identity are associated with the direct labor hours and direct labor dollars. At no time will any data be released to the public with the Contractor name and contract number associated with the data. For internal Army analysis, the reports and queries from the database shall not contain proprietary data.

OPTIONAL ITEM CLIN 1001: Provide all labor, management, supervision, tools, materials, equipment, and transportation to construct all new electrical, communications, and lighting tasks identified as "OPTION" on contract plan sheets E101, E102. E103. E104, E105, E106, and E107 for Johnson Road Repair, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

OPTIONAL ITEM CLIN 1002: Provide all labor, management, supervision, tools, materials, equipment, and transportation for all demolition tasks identified on contract plan sheets ED101, ED102. ED103. ED104, ED105, and ED106, for Johnson Road Repair, at Military Ocean Terminal, Concord, CA, in accordance with this contract and all associated documents, drawings, and specifications.

OPTIONAL ITEM CLIN 1003: Delay of Construction - Demobilization and remobilization during stand down at Military Ocean Terminal, Concord, CA (NTE 10 days in duration).

OPTIONAL ITEM CLIN 1004: Delay of Construction - Demobilization and remobilization during stand down at Military Ocean Terminal, Concord, CA (NTE 45 days in duration).

OPTIONAL ITEM CLIN 1005: UXO/MEC

Provide all labor, management, supervision, tools, materials, equipment, and transportation to remove and dispose of UXO/MEC discovered during construction at Military Ocean Terminal, Concord, CA, in accordance with all this contract and all associated documents, drawings, and specifications.

1.6 PERIOD OF PERFORMANCE

The time duration of performance period is 365 calendar days after Notice to Proceed date.

1.7 LIQUIDATED DAMAGES

Liquidated damages for this work are $2,037 for each day of delay.

1.8 WAGE DETERMINATION

General Decision Number CA20190018, dated 05/03/2019, Contra Costa County, in the State of California, or its most current modification at the time of award are hereby applicable to work performed under this contract. The most

Section 01 11 00 Page 4 current decision or its modification can be found by clicking on hyperlink https://beta.sam.gov/wage-determination for such information.

https://beta.sam.gov/wage-determination/CA20190018/4/document

1.9 PRECONSTRUCTION CONFERENCE

Prior to the initiation of work, a meeting will be held with the Contractor and USACE to discuss matters of mutual interest concerning the contract.

General conditions, work schedule, phasing and coordination, security, safety, permits, and other matters pertinent to work accomplishments will be discussed in this meeting.

1.10 AUTHORITIES

Only a warranted Contracting Officer (either PCO or ACO) acting within his or her delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

1.11 CODES AND REFERENCES

References within the RFP are mandatory and shall be used as the basis of construction. References to specific codes and standards within the Specifications may be out of date. However, Contractor shall comply with all current edition of the codes and standards as of the date of contract award.

References may not be all inclusive, and it is the Contractor's responsibility to meet all applicable codes.

1.12 SUSTAINABLE ACQUISITION

EPA Designated. Under the Comprehensive Procurement Guidelines (CPG) program, the Environmental Protection Agency (EPA) designates products that are or can be made with recovered materials, and recommends practices for buying these products. Any designated product that is being offered or supplied under this contract shall meet the minimum recommended content levels as identified under the CPG program. Visit http://www.epa.gov/epawaste/conserve/tools/cpg/products for a complete list of designated products and the associated recommended content levels.

Offerors must be able to demonstrate that each offered product meets minimum content levels upon request.

Safer Choice. The contractor shall provide Safer Choice labeled products under this contract, as applicable. The contractor is encouraged to visit http://www2.epa.gov/saferchoice/products for updated lists of qualifying products.

Bio-based. The United States Department of Agriculture (USDA) designates certain biobased products for federal procurement and specifies minimum biobased content levels for those products. Any designated product that is being offered or supplied under this contract shall meet USDA BioPreferred's minimum biobased content level. Visit the BioPreferred web site for the complete list of designated products and the associated minimum biobased content level requirements.

Section 01 11 00 Page 5

Energy Star. As required in clause 52.223-15 Energy Efficiency in Energy- Consuming Products, the contractor shall only provide products that earn the ENERGY STAR label and meet ENERGY STAR specifications for energy efficiency.

The contractor is encouraged to visit http://www.energystar.gov for complete product specifications and updated lists of qualifying products.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --