A07.23_-_Attachment_01-_Statement_of_Work.pdf

STATEMENT OF WORK

MOTCO Roads Renovation

Military Ocean Terminal, Concord, CA

1. SUMMARY

The objective of this Contract is to repair and reconstruct portions of White Road and Johnson Road at Military Ocean Terminal, Concord, California, as described in this contract and to meet the operational requirements of the Army. The project will be constructed in a 365 calendar-day period of performance. Contractor is encouraged to attend the proposal conference and visit the site before submitting their proposal.

2. SCOPE OF WORK

Contractor shall provide all labor, materials, tools and equipment necessary for construction of this project titled MOTCO Roads Renovation, Military Ocean Terminal, Concord, CA. Work includes demolition and full depth replacement of existing White Road West and Center (broken into White Road West and White Road Center design packages) and existing Johnson Road. See project specifications and drawings for more details.

3. SAFETY REQUIREMENTS

In addition to Section 01 35 26 of the specifications, all installation safety regulations shall be followed. Comply with the most current edition of USACE EM 385-1-1, and all applicable federal, state, and local laws, ordinances, criteria, rules and regulations including but not limited to 29 CFR 1910 and 29 CFR 1926.

4. AUTHORITIES STATEMENT

Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

5. PROJECT SCHEDULE

Normal Work Days consist of 8 ½ hours, Monday through Friday, 0700 – 1700 hours, except federal holidays. All work shall occur during Normal Work Days/Hours unless previously approved by the Contracting Officer. See specification 01 14 00 WORK RESTRICTIONS for more information.

Contractor shall hold Periodic Schedule Update Meetings and Weekly Progress Meetings in accordance with Specification 01 32 01 PROJECT SCHEDULE.

6. UNSCHEDULED INTERRUPTIONS

Work operations are subject to delay by unscheduled interruptions and contractor personnel may be required to immediately leave the designated work area or be denied access due to security operations. Mission requirements may necessitate suspension or cancellation of custodial operations for a period of 10 days or 45 days, dependent on which delay option in this contract is exercised. All incomplete work shall be rescheduled for completion at a later time and date mutually agreed upon by the ACO, COR, POC, QA personnel, and the Contractor. The Period of Performance will also be adjusted accordingly.

The contractor will be compensated for unscheduled interruptions in the amount provided by the contractor in CLINs 1001 and 1002. These options may be exercised more than once during the Period of Performance. If either option are exercised more than 6 times cumulatively during the Period of Performance, the Government reserves the right to Terminate for Convenience.

7. SECURITY REQUIREMENTS

Contractor is responsible for maintaining the site and all other Contractor controlled areas in such a manner as to minimize the risk of injury or accident to site personnel or others who may be in the area. Contractor is also responsible for furnishing an identification badge/card to each individual working on the site.

See specification 01 14 00 WORK RESTRICTIONS for more details regarding security requirements.

8. WARRANTY

See contract award documents.

9. LIQUIDATED DAMAGES

See contract award documents.

10. POST-AWARD POINTS OF CONTACT

The Administrative US Army COE POC & ACO will be designated at the time of award. They will be responsible for verifying that the Contractors’ performance and completion of work is in accordance with applicable requirements.