4-Atch_2_Supplemental_Contract_Requirements_MOTCO_Repair_Pier_3-Phases_II-III.docx

Attachment 2 Repair Pier 3 – Phases II-III April 18, 2018 Military Ocean Terminal, Concord, CA

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 210 (Base Bid) + 60 (Option 3) + 30 (Option 4) = 300 (Total if Options 3-4 exercised) calendar days after Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work are $2,140 for each day of delay.

3. Authorities. Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer. The Government Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer to the Contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision Number CA180029, 04/13/2018, Contra Costa County, California, or its most current modification at the time of award are hereby applicable to work performed under this contract. The most current decision or its modification can be found by clicking on hyperlink http://www.wdol.gov/dba.aspx for such information.