Atch_2_Supplemental_Contract_Requirements_Standard_Magazine_Rehab.pdf

Attachment 2 Standard Magazine Rehabilitation Sierra Army Depot, Herlong, CA April 28, 2017

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 365 calendar days after Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.

Liquidated damages for this work are $1,490 for each day of delay.

3. Evaluation of Options. Refer to FAR 52.217-5, Evaluation of Options. Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

4. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer. The Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

5. Wage Determination. General Decision Number CA170009, 06/02/2017, Lassen County, California, or its most current modification at the time of award are hereby applicable to work performed under this contract. The most current decision or its modification can be found by clicking on hyperlink http://www.wdol.gov/dba.aspx for such information.

6. Time Extensions For Unusually Severe Weather. Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delays will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(20) (17) (17) (13) (06) (03) (01) (01) (04) (10) (15) (20)