10-R-0038 Supplemental Contract Requirements.pdf

Amendment 0002 2 September 2010

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. The performance period for the work stated above shall be 180 calendar days.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.

Liquidated damages for this work is $1436.00 for each day of delay.

3. Authorities. No person other than the Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision No. UT100061 07/16/2010, or its most current modification at the time of award is hereby applicable to work performed under this task order.

The most current decision or its modification can be found at

County: Tooele State: Utah Construction type: Heavy

5. Time Extensions For Unusually Severe Weather. Refer to Default (Fixed-Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.

TOOELE AD/TOOLE

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(20) (16) (14) (08) (05) (03) (02) (02) (02) (05) (13) (21)