Solicitation W91236-20-B-0009 Bradford Bay.pdf

W91236-20-B-0009 - Maintenance Dredging of Waterw ay on the Cost of Virginia, Bradford Bay, Accomack County, Virginia.

Period of Performance: 135 Calendar Days after Notice to Proceed.

This acquisition is a Total Small Business Set Aside Procurement using FAR Part 14.

NAICS Code: 237990, other Heavy and Civil Engineering Construction is applicable to this Procurement.

Size Standard $30,000,000.00.

Magnitude of Construction: Betw een $1,000,000.00 and $5,000,000.00

DUNS:_______________

CAGE CODE:___________

TAX ID:____________________

Contracting POC: Loretta Parris, Contract Specialist, 470-253-8309, loretta.e.parris@usace.army.mil.

X

LORETTA E PARRIS 757-201-7136

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

09-Dec-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______20 calendar days and complete it w ithin ________135 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________14 Jan 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USA ENGINEER DISTRICT, NORFOLK

803 FRONT STREET

NORFOLK VA 23510-1096

W91236

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

757-201-7183FAX:TEL: TEL: FAX:

W9123620B0009 47

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Base Item: Mobilization & Demobolization

FFP

Mobilization and Demobilization

FOB: Destination

NET AMT

0002 51,900 Cubic

Yard

Base Item: Lower Bradford Bay Channel

FFP

Lower Bradford Bay Channel Dredging. Maintenance Dredging of Bradford Bay

Channel from Station 112+00 to 22+90, to a required depth of -6 feet MLLW with one foot of allowable overdepth, and placement of the dredged material within the overboard disposal site in Bradford Bay, complete, including all work as indicated and specified.

0003 24,000 Cubic

Base Item: Upper Bradford Bay Channel

Upper Bradford Bay Channel and Finney Creek Dredging. Maintenance Dredging of Bradford Bay Channel from Station -54+18 to 22+90, and Finney Creek from

Station 22+90 to 32+90, to a depth of -6 feet MLLW with one foot of allowable overdepth, and placement of the dredged material within the overboard disposal site in Bradford Bay, complete, including all work as indicated and specified.

0004 21,500 Cubic

OPTION Option Item: Lower Bradford Bay Channel

Lower Bradford Channel Dredging. Maintenance Dredging of Bradford Bay

Channel from Station 112+00 to 22+90, to a required depth of -7 feet MLLW with one foot of allowable overdepth, and placement of the dredged material within the overboard disposal site in Bradford Bay, complete, including all work as indicated and specified.

0005 20,600 Cubic

OPTION Option Item: Upper Bradford Bay Channel

Upper Bradford Bay Channel and Finney Creek Dredging. Maintenance Dredging of Bradford Bay Channel from Station -54+18 to 22+90, and Finney Creek from

Station 22+90 to 32+90, to a depth of -7 feet MLLW with one foot of allowable overdepth, and placement of the dredged material within the overboard disposal site in Bradford Bay, complete, including all work as indicated and specified.

TOTAL EVALUATED PRICE

Total Base CLINS: CLINS 0001 - 0003 $______________________

Total Options CLINS: CLINS 0004 – 0005 $_______________________

Total Evaluated Price: Total Base + CLINS 0001 – 0005 $_______________________

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 135 dys. ANP 1 OPERATIONS BRANCH

JASON FLOWERS

US ARMY ENGR DIST NORFOLK

803 FRONT STREET

NORFOLK VA 23510

(757) 201 7017

W91236

0002 135 dys. ANP 51,900 (SAME AS PREVIOUS LOCATION)

0003 135 dys. ANP 24,000 (SAME AS PREVIOUS LOCATION)

0004 135 dys. ANP 21,500 OPERATIONS BRANCH

JASON FLOWERS

US ARMY ENGR DIST NORFOLK

803 FRONT STREET

NORFOLK VA 23510

(757) 201-7017

0005 135 dys. ANP 20,600 (SAME AS PREVIOUS LOCATION)

Section 00 21 00 - Instructions

BIDS

Offerors may hand deliver sealed bids to the Waterfield Building located at 803 Front Street, Norfolk, VA 23510.

You may place your sealed bid in the secured bid box that is located directly in front of the Security Desk on the 1st floor prior to the submission date and time listed in the solicitation. All couriers may deliver to the bid box, however; no signed receipt will be provided.

INSTRUCTIONS

1. PROJECT DESCRIPTION

Maintenance Dredging of Water on the Coast of Virginia (WCV) Bradford Bay, involves dredging approximately 118,000 cubic yards of material from Bradford Bay Channel and Finney Creek, and placement of the material within the 1000’ by 1000’ overboard placement site within Bradford Bay. A hydraulic cutter head dredge will be used to accomplish this work. Maximum pay depth (required + allowable), including optional work, will be -8 feet MLLW.

2. BIDDERS QUESTIONS AND COMMENTS:

All questions and/or comments shall be submitted via Projnet no later than 7 January 2020 at

02:00 PM Eastern Standard Time (EST).

The Government reserve the right not to respond after the deadline. Responses to questions and/or comments will be posted to www.Beta.SAM.gov.

The Bidder Inquiry System will be available the same day as the solicitation and unavailable for new inquires 7 days prior to bid opening in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary. Therefore, all questions and/or comments should reach the above referenced Contracting Office via ProjNet no later than 7 January 2020.

Technical inquiries and questions relating to Invitation for Bid (IFB) procedures or bonds are to be submitted via Bidder Inquiry in ProjNet at http://www.projnet.org/projnet. To submit and review bid inquiry items, bidders will need to be a current registered user or self-register into system. To self-register go to web page, click BID tab select Bidder Inquiry, select agency USACE, enter Key for this solicitation listed below, and your e-mail address, click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue. From this page you may view all bidder inquiries or add inquiry.

Bidders will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team. The Solicitation Number is W91236-20-B-0009. The

Bidder Inquiry Key is: AHHJYB-79ZM54

The Bidder Inquiry System will be unavailable for new inquires 7 days prior to bid opening in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary. Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

3. BID EVALUATION AND AWARD

The Government will evaluate bids in response to this solicitation based upon the Total

Evaluated Price without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government considering only price and the price-related factors specified elsewhere in the solicitation. The Government may reject any or all bids and accept other than the lowest bid; and/or waive informalities or file:///C:/Users/e4brceg9/AppData/Local/Temp/32/t%20at%20http:/www.projnet.org/projnet minor irregularities in bids received.

4. AWARD TO RESPONSIBLE OFFEROR

To be determined responsible, a bidder must –

a) Have adequate financial resources to perform the contract, or the ability to obtain them;

b) Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and governmental business commitments;

c) Have a satisfactory performance record. A prospective contractor shall not be determined responsible or non-responsible solely on the basis of a lack of relevant performance history;

d) Have a satisfactory record of integrity and business ethics;

e) Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them (including, as appropriate, such elements as production control procedures, property control systems, quality assurance measures, and safety programs applicable to materials to be produced or services to be performed by the prospective contractor and subcontractors);

f) Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

g) Be otherwise qualified and eligible to receive an award under applicable laws and regulations

In accordance with FAR Part 9.1, responsibility will be determined, prior to award, by the Contracting

Officer through the performance of a pre-award survey or utilizing information from a previous pre-award survey and/or any performance data available. The apparent low bidder may be required to show that he has the necessary capital, experience, and owns or can procure the necessary plant or other resources to commence the work at the time prescribed in the specifications and thereafter to prosecute and complete the work safely and satisfactorily within the time specified. The below information will be requested of the apparent low offeror. This information is not required to be responsive to the invitation for bid.

h) Banking Information to include Branch/Location, Point of Contact and Telephone Number. Please insure the Bank is prepared to provide necessary information regarding average balances in your operating accounts, lines of credit and credit history.

i) Current commitments and expected dates of completion

j) Award to Responsible Offerors, Evidence of Authority to Sign Offers, Pre-Award Safety Conference, Incurring Costs, Agents, Unbalanced Bids, Unauthorized Instruction From Government or Other Personnel.

5. CONSTRUCTION TIME

* For the contract bid items, begin performance within 20 calendar days and complete all work within 135 calendar days of receipt of Notice to Proceed (NTP). It is the Government’s intent that the successful bidder will dredge to the optional depth, if so exercised by the Government, concurrent with dredging to the depth required in the base scope of work. Thus, optional items will be awarded with the base award. If optional items are exercised, additional performance time will be added to the contract based of one additional day per 1,000 cubic yards of dredged material added.

* Should the total quantity of material to be paid for and actually dredged under this contract exceed the estimated quantity from the Bidding Schedule, including optional work, additional time will be allowed at the rate of one day for each 1,000 cubic yards in excess of the estimated base contract quantity.

6. INVOICES SHALL BE SENT TO THE FOLLOWING:

U.S. ARMY CORPS OF ENGINEERS

ATTN: Daria Walker

Contracting Division

803 FRONT STREET

NORFOLK, VA 23510-1096

EMAIL: cenao.ecaeinvoicing@usace.army.mil

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.209-7 Information Regarding Responsibility Matters OCT 2018

52.214-3 Amendments To Invitations For Bids DEC 2016

52.214-4 False Statements In Bids APR 1984

52.214-5 Submission Of Bids DEC 2016

52.214-6 Explanation To Prospective Bidders APR 1984

52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999

52.214-18 Preparation of Bids-Construction APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 60 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a FIRM FIXED PRICE contract resulting from this solicitation.

mailto:cenao.ecaeinvoicing@usace.army.mil

(End of provision)

Section 00 45 00 - Representations and Certifications

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.204-7 System for Award Management OCT 2018

52.222-56 Certification Regarding Trafficking in Persons Compliance

Plan.

MAR 2015

252.247-7022 Representation of Extent of Transportation by Sea. JUN 2019

Section 00 72 00 - General Conditions

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-2 Security Requirements AUG 1996

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.214-4 False Statements In Bids APR 1984

52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996

52.214-26 Audit and Records--Sealed Bidding OCT 2010

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data--

Modifications--Sealed Bidding

OCT 2010

52.217-4 Evaluation Of Options Exercised At The Time Of Contract

Award

JUN 1988

52.217-5 Evaluation Of Options JUL 1990

52.219-2 Equal Low Bids OCT 1995

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-9 Alt I Small Business Subcontracting Plan (AUG 2018) Alternate I NOV 2016

52.219-14 Limitations On Subcontracting JAN 2017

52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records AUG 2018

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014

52.223-6 Drug-Free Workplace MAY 2001

52.232-2 Payments Under Fixed-Price Research And Development

Contracts

APR 1984

52.236-2 Differing Site Conditions APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-16 Quantity Surveys APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.236-26 Preconstruction Conference FEB 1995

52.242-5 Payments to Small Business Subcontractors JAN 2017

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-2 Subcontracts OCT 2010

52.244-6 Subcontracts for Commercial Items AUG 2019

52.245-9 Use And Charges APR 2012

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2015

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7004 Drug Free Work Force SEP 1988

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.227-7033 Rights in Shop Drawings APR 1966

252.231-7000 Supplemental Cost Principles DEC 1991

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7002 Obstruction of Navigable Waterways DEC 1991

252.236-7003 Payment for Mobilization and Preparatory Work JAN 1997

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $30,000,000.00

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(X) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or

Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-

5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, https://www.sam.gov/ complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR

4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 20 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 135 calendar days from notice to proceed. * The time stated for completion shall include final cleanup of the premises.

* Should the total quantity of material to be paid for and actually dredged under this contract exceed the estimated quantity from the Bidding Schedule, including optional work, additional time will be allowed at the rate of one day for each 1,000 cubic yards in excess of the estimated base contract quantity.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,000.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within AT TIME OF CONTRACT AWARD . Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT 2018)

(a) Definitions. As used in this contract--

HUBZone small business concern means a small business concern, certified by the Small Business Administration, that appears on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business

Administration.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern means a small business as defined pursuant to Section 3 of the Small Business Act and relevant regulations promulgated pursuant thereto.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women, or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

(b) It is the policy of the United States that small business concerns, veteran-owned small business concerns, service-disabled veteran-owned small business concerns, HUBZone small business concerns, small disadvantaged business concerns, and women-owned small business concerns shall have the maximum practicable opportunity to participate in performing contracts let by any Federal agency, including contracts and subcontracts for subsystems, assemblies, components, and related services for major systems. It is further the policy of the United States that its prime contractors establish procedures to ensure the timely payment of amounts due pursuant to the terms of their subcontracts with small business concerns, veteran-owned small business concerns, service-disabled veteran-owned small business concerns, HUBZone small business concerns, small disadvantaged business concerns, and women-owned small business concerns.

(c) The Contractor hereby agrees to carry out this policy in the awarding of subcontracts to the fullest extent consistent with efficient contract performance. The Contractor further agrees to cooperate in any studies or surveys as may be conducted by the United States Small Business Administration or the awarding agency of the United

States as may be necessary to determine the extent of the Contractor's compliance with this clause.

(d)(1) The Contractor may accept a subcontractor's written representations of its size and socioeconomic status as a small business, small disadvantaged business, veteran-owned small business, service-disabled veteran-owned small business, or a women-owned small business if the subcontractor represents that the size and socioeconomic status representations with its offer are current, accurate, and complete as of the date of the offer for the subcontract.

(2) The Contractor may accept a subcontractor's representations of its size and socioeconomic status as a small business, small disadvantaged business, veteran-owned small business, service-disabled veteran-owned small business, or a women-owned small business in the System for Award Management (SAM) if--

(i) The subcontractor is registered in SAM; and

(ii) The subcontractor represents that the size and socioeconomic status representations made in SAM are current, accurate and complete as of the date of the offer for the subcontract.

(3) The Contractor may not require the use of SAM for the purposes of representing size or socioeconomic status in connection with a subcontract.

(4) In accordance with 13 CFR 121.411, 124.1015, 125.29, 126.900, and 127.700, a contractor acting in good faith is not liable for misrepresentations made by its subcontractors regarding the subcontractor's size or socioeconomic status.

(5) The Contractor shall confirm that a subcontractor representing itself as a HUBZone small business concern is certified by SBA as a HUBZone small business concern by accessing the System for Award Management or by contacting the SBA. Options for contacting the SBA include--

(i) HUBZone small business database search application Web page at http://dsbs.sba.gov/dsbs/search/dsp_searchhubzone.cfm; or http://www.sba.gov/hubzone;

(ii) In writing to the Director/HUB, U.S. Small Business Administration, 409 3rd Street, SW., Washington DC

20416; or

(iii) The SBA HUBZone Help Desk at hubzone@sba.gov.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The

Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in

SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

26.6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract

Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract

Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Accomack

County, Virginia

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2017)

(a) Definitions. As used in this clause (in accordance with 29 CFR 13.2)--

Child, domestic partner, and domestic violence have the meaning given in 29 CFR 13.2.

Employee--(1)(i) Means any person engaged in performing work on or in connection with a contract covered by

Executive Order (E.O.) 13706; and

(A) Whose wages under such contract are governed by the Service Contract Labor Standards statute (41 U.S.C.

chapter 67), the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV), or the Fair

Labor Standards Act (29 U.S.C. chapter 8);

(B) Including employees who qualify for an exemption from the Fair Labor Standards Act's minimum wage and overtime provisions;

(C) Regardless of the contractual relationship alleged to exist between the individual and the employer; and

(ii) Includes any person performing work on or in connection with the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor's Employment and Training

Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of

Apprenticeship.

(2)(i) An employee performs ``on'' a contract if the employee directly performs the specific services called for by the contract; and

(ii) An employee performs ``in connection with'' a contract if the employee's work activities are necessary to the performance of a contract but are not the specific services called for by the contract.

Individual related by blood or affinity whose close association with the employee is the equivalent of a family relationship has the meaning given in 29 CFR 13.2.

Multiemployer plan means a plan to which more than one employer is required to contribute and which is maintained pursuant to one or more collective bargaining agreements between one or more employee organizations and more than one employer.

Paid sick leave means compensated absence from employment that is required by E.O. 13706 and 29 CFR part 13.

Parent, sexual assault, spouse, and stalking have the meaning given in 29 CFR 13.2.

United States means the 50 States and the District of Columbia.

(b) Executive Order 13706. (1) This contract is subject to E.O. 13706 and the regulations issued by the Secretary of

Labor in 29 CFR part 13 pursuant to the E.O.

(2) If this contract is not performed wholly within the United States, this clause only applies with respect to that part of the contract that is performed within the United States.

(c) Paid sick leave. The Contractor shall--

(1) Permit each employee engaged in performing work on or in connection with this contract to earn not less than 1 hour of paid sick leave for every 30 hours worked;

(2) Allow accrual and use of paid sick leave as required by E.O. 13706 and 29 CFR part 13;

(3) Comply with the accrual, use, and other…