DESC_1909_-_Specifications_Volume_I_-_RTA.pdf

SPECIFICATIONS

Volume 1 of 2

CAS 0703 DESC 1909

REPLACE FLIGHT LINE AVIATION POL

Joint Base Langley-Eustis Newport News, Virginia

A/E Contract No. W91236-19-B-FAPY Delivery Order No. 0035

May 28, 2019

Submitted to:

U.S. Army Corps of Engineers, Omaha District 1616 Capital Avenue

Omaha, NE 68102

Submitted by:

1011 Boulder Springs Drive, Suite 200 Richmond, Virginia 23225

Phone: 804.592.3900 Fax: 804.592.3901 www.brockenbrough.com

Job No. 17-035.01

US Army Corps of Engineers

Replace Fuel Facilities - Felker Army Airfield DESC1909

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 50 SUMMARY OF WORK FOR NORFOLK DISTRICT PROJECTS

01 14 00 WORK RESTRICTIONS

01 22 00.00 10 PRICE AND PAYMENT PROCEDURES

01 30 00.00 50 ADMINISTRATIVE REQUIREMENTS FOR NORFOLK DISTRICT PROJECTS

01 32 01.00 10 PROJECT SCHEDULE

01 32 17.00 20 COST-LOADED NETWORK ANALYSIS SCHEDULES (NAS)

01 33 00 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

01 35 26.00 50 GOVERNMENTAL SAFETY REQUIREMENTS

01 35 29.13 HEALTH, SAFETY, AND EMERGENCY RESPONSE PROCEDURES FOR

CONTAMINATED SITES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 50 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 16 TEMPORARY PEST CONTROL

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 58 00 PROJECT IDENTIFICATION

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 75 00.00 40 STARTING AND ADJUSTING

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 61 13 EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL

02 82 00 ASBESTOS REMEDIATION

02 83 00 LEAD REMEDIATION

DIVISION 03 - CONCRETE

03 11 13.00 10 STRUCTURAL CAST-IN-PLACE CONCRETE FORMING

03 15 00.00 10 CONCRETE ACCESSORIES

03 20 00.00 10 CONCRETE REINFORCING

03 30 00.00 10 CAST-IN-PLACE CONCRETE

03 35 00.00 10 CONCRETE FINISHING

03 39 00.00 10 CONCRETE CURING

DIVISION 05 - METALS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 33 23 OVERHEAD COILING DOORS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

PROJECT TABLE OF CONTENTS Page 1

DIVISION 09 - FINISHES

09 29 00 GYPSUM BOARD

09 90 00 PAINTS AND COATINGS

09 97 13.15 LOW VOC POLYSULFIDE INTERIOR COATING OF WELDED STEEL

PETROLEUM FUEL TANKS

09 97 13.27 EXTERIOR COATING OF STEEL STRUCTURES

DIVISION 13 - SPECIAL CONSTRUCTION

13 34 19 METAL BUILDING SYSTEMS

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 26 - ELECTRICAL

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 28 00.00 10 MOTOR CONTROL CENTERS, SWITCHBOARDS AND PANELBOARDS

26 32 14.00 10 DIESEL-GENERATOR SET, STATIONARY 15-300 KW, STANDBY

APPLICATIONS

26 41 00 LIGHTNING PROTECTION SYSTEM

26 42 14.00 10 CATHODIC PROTECTION SYSTEM (SACRIFICIAL ANODE)

26 51 00 INTERIOR LIGHTING

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 20 BASE COURSE FOR RIGID AND SUBBASES FOR FLEXIBLE PAVING

32 11 23 AGGREGATE BASE COURSES

32 12 17 HOT MIX BITUMINOUS PAVEMENT

32 31 13.53 HIGH-SECURITY CHAIN LINK FENCES AND GATES

DIVISION 33 - UTILITIES

33 08 55 COMMISSIONING OF FUEL FACILITY SYSTEMS

33 40 00 STORM DRAINAGE UTILITIES

33 52 43 AVIATION FUEL DISTRIBUTION (NON-HYDRANT)

33 52 43.11 AVIATION FUEL MECHANICAL EQUIPMENT

33 52 43.14 AVIATION FUEL CONTROL VALVES

33 52 43.23 AVIATION FUEL PUMPS

33 52 43.28 FILTER SEPARATOR, AVIATION FUELING SYSTEM

33 52 80 LIQUID FUELS PIPELINE COATING SYSTEMS

33 52 90.00 20 WELDING FOR POL SERVICE PIPING

33 56 10 FACTORY-FABRICATED FUEL STORAGE TANKS

33 57 00 BULK FUEL RECEIVING/DISPENSING EQUIPMENT

33 65 00 CLEANING PETROLEUM STORAGE TANKS

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION 01 11 00.00 50

SUMMARY OF WORK FOR NORFOLK DISTRICT PROJECTS

2/2013

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submittals with an "S" are for inclusion in the Sustainability Notebook, in conformance with Section 01 33 29 SUSTAINABILITY REPORTING. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals Salvage Plan; G,

1.2 DEFINITIONS

a. Facility: The facility is located at a location to be specified by the Government within the Norfolk District Area of Operations:

CO: Contracting Officer or his authorized representative.

U.S. Army Corps of Engineers Norfolk District

1.3 WORK COVERED BY CONTRACT DOCUMENTS

1.3.1 Project Description

The work includes demolition of the existing POL Facilities at Felker Army Airfield and the construction of a new facility on an adjacent site. The new Fuel Facility will include two 20,000 gallon aboveground storage tanks, two 300 gpm packaged truck fillstands, one 300 gpm packaged truck off-loading station, and a pre-engineered metal storage building. Site improvements include paved road surfaces, perimeter fence, entrance and exit gates, site lighting and a secondary spill containment system.

Pre-engineered overhead canopies will protect equipment and incidental related work.

1.3.2 Location

The work shall be located at the location to be specified by the Government within the Norfolk District Area of Operations. The exact location will be shown by the Contracting Officer.

1.4 PERSONNEL RESTRICTIONS

Personnel are limited to the immediate site areas and shall not enter buildings or facilities not involved in the work. All employees of the Contractor will be subject to all rules and regulations of the Facility which pertain to personnel. The Contractor shall erect fences and signs as specified and be responsible for the restrictions of all personnel. The Contractor's plans for restricting personnel access to the project site shall be submitted for approval as a part of the Safety Plan (Accident Prevention Plan). Facility access shall be restricted. Contractor shall

SECTION 01 11 00.00 50 Page 1 comply with current security requirements. All vehicles shall be registered with the military police.

1.5 TRANSPORTATION FACILITIES

The Facility is served by an all weather surfaced road network and training road trails which are all deemed to be weight rated for road legal vehicles by the installation's Civil Engineering Division. Road(s) within the Facility and vicinity of the site are for construction activities such as materials delivery and hauling proposed to be used by the Contractor.

These roads shall be subject to prior approval of the Facility authorities and such roads, if used, shall be maintained throughout construction and shall be restored to as good condition as existed prior to their use. The Contractor shall also construct, subject to approval, such temporary haul roads and bridges (such as temporary causeway for construction of the taxiway bridge) as may be necessary for conducting his work. Any such temporary construction shall be removed and the affected area restored to its original condition. All costs for the use of existing transportation facilities, for the construction of temporary facilities, and for maintenance, repair, removal and restoration shall be borne by the Contractor.

1.5.1 Use of Roads

Hard-surfaced roads from major and primary municipal roads serve the Facility. The movement of all vehicles within the Facility shall be confined to the roads designated in the plans or as approved by the Contracting Officer and shall comply with traffic regulations within the Facility. The Contractor shall keep all roads clear of all obstructions and free of mud and other foreign materials resulting from operations. The Contractor's vehicles shall at no time follow a vehicle closer than 50 feet, and all vehicles shall pull off the road and come to a complete stop when meeting emergency vehicles, or vehicles with flashing lights. Facility speed limits and traffic controls shall be observed.

Trails and training roads paved with aggregate link the construction site to hard surfaced roads. Aggregrate surfaces shall be maintained in a manner where they can be used by military training vehicles throughout the construction period. Closure of roads for construction purposes shall only occur if a schedule for such closure is submitted and approved in advance by the Contracting Officer as outlined in Section 01 50 00 Paragraph 3.5.

1.5.2 Road Restrictions

The movement of all vehicles within the Facility shall be confined to the roads designated and shall comply with traffic regulations within the Facility. Other roads may be used only with the approval of the CO.

1.5.3 Cleated Vehicles

Cleated vehicles shall not be moved over surfaced roads except at the immediate site of the area where they are to be used.

1.6 SPECIAL CONTRACTOR REQUIREMENTS

1.6.1 NOTIFICATION OF WORK IN DOMINION VIRGINIA POWER (DVP) ZONE

It shall be the responsibility of the Contractor to submit a "Notification of Work" form prior to performance of work that may come into contact with

SECTION 01 11 00.00 50 Page 2 electrical distribution system components within DVP's zone of responsibility. Submission shall be required a minimum of 48 hours in advance of the scheduled work. DVP's zone of responsibility is defined as all primary lines (600 volts and above) and down to the first point of positive disconnection past the distribution transformer reducing the supply voltage below 600 volts. Provide copies of this notification to the COR, DVP Regional Operation Center (ROC)-757-857-2633(fax), DVP Kenneth Schutz-703-359-3210(fax) and the designated representative for the installation.

1.6.2 COORDINATION IN WORK AREAS

1.6.2.1 Occupied Work Area - Airfield Vicinity

The area where work is to be accomplished within vicinity of the airfield will be occupied during the work. Activities of the occupants of the scheduled work area shall not be interrupted or hampered in any way without prior written approval of the Contracting Officer and shall be subject to coordination and notification and approval requirements as specified by the Contracting Officer. It is expected than any closure or limitation of the operation of the airfield shall generally occur when the airfield is closed which would typically occur during nighttime hours.

1.6.2.2 Unoccupied Work Area - Main Development Site

The area where the Contractor is scheduled to perform the work for the main development site will not be occupied during the work, however, the Contractors work activities may affect other area(s) that are occupied. All work shall be in accordance with the approved Contractor's work plan.

1.6.2.3 Maintenance of Utilities

Any active utilities, including but not limited to electricity, gas, communications, water, sanitary sewer, storm sewer, heating, air conditioning, or any like service, that will require interruption or replacement in any occupied area affected as a result of the Contractors scheduled work activities, shall be temporarily provided by the Contractor at his own expense until the affected service is fully and permanently restored. All temporary method(s) of service replacement the Contractor proposes for use on this contract shall be approved by the CO prior to commencing the work.

1.6.2.4 Hours of Work

The normal work hours for construction shall be permitted to occur between 7AM and 7PM, Monday through Saturday, unless as established and approved by the Contracting Officer in the Contractor's Project Schedule. Any request to change these hours shall be made in writing to the Contracting Officer at least two calendar days prior to the desired day on which the change is to go into effect. The changed hours shall not go into effect until written permission has been received from the Contracting Officer.

1.6.2.5 Existing Utility Location

Existing utilities must be located before doing any digging work on Facility. The Contractor shall be responsible to contact Miss Utility, obtain all necessary existing utility locations, which may be necessary to accomplish his work, and mark any utility lines in the immediate vicinity of his work. It shall be the responsibility of the Contractor to contact

SECTION 01 11 00.00 50 Page 3

Miss Utilities at 1-800-552-7110 for locating commercial utilities 48 hours prior to digging operations.

1.6.2.6 Digging Permits

Contractor is responsible for obtaining all digging permits, including associated locating and marking services, in accordance with installation and local requirements, at no additional cost to the Government.

"Clearance Permits for Digging', must be obtained before doing any work on Facility. The Contractor shall be responsible to obtain all necessary digging permits and pay costs associated with the permit, which may be necessary to accomplish his work. All permits will be obtained through Miss Utilities at 1-800-552-7110.

1.6.2.7 Personnel Escort

An authorized Contractor representative must escort all personnel attempting to obtain a badge to Security. The representative shall sign documentation that the employee meets Security criteria and is suitable for a badge to be issued.

1.6.3 STRUCTURAL DRAWING DIMENSIONS

The building layout, including both horizontal and vertical dimensions, is shown on the Architectural sheets contained in the contract drawings.

The Contractor shall use the dimensions from the Architectural sheets to obtain dimensions for foundation layout and structural members as necessary to prepare all shop drawings and fabricate structural members. There may be some instances where the Contractor shall have to adjust actual dimensions to the submitted items that he will use, to finalize the location of a structural member. Any such adjustments shall be clearly identified on the submitted shop drawings for Government review.

1.7 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Contract .

In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

1.7.1 Schedule

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

SECTION 01 11 00.00 50 Page 4

BASED ON (5) DAY WORK WEEK AT PROJECT LOCATION

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

10 9 8 6 7 7 9 6 5 5 6 9

1.7.2 Records

Upon acknowledgement of the Notice to Proceed and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

1.7.3 Impacted Days

The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in the schedule of monthly anticipated adverse weather delays, above, the contracting officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Contract .

1.8 COOPERATION WITH USING AGENCY AND OTHER CONTRACTORS

During the period of this contract, other contracts may be in force for the construction of other features of work on or adjacent to the site of work being accomplished under this contract. It shall be the responsibility of the Contractor on this contract to be fully informed of the extent of the limits of work to be performed by other Contractors. Should there be any conflict between these limits, it shall be brought to the attention of the Contracting Officer(CO)and the CO's decision shall be final. Also, prior to completion of work under this contract, members of the Using Agency may be performing work or occupying facilities on or adjacent to the area. The Contractor shall arrange his plant and shall schedule and perform this work so as to effectively cooperate with all other Contractors and Government agencies.

1.9 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.10 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

SECTION 01 11 00.00 50 Page 5

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.11 LOCATION OF UNDERGROUND UTILITIES

Scan the construction site with electromagnetic or sonic equipment, and mark the surface of the ground, pier deck or paved surface where existing underground utilities or utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed.

Notify the Contracting Officer at least 15 days prior to starting excavation work.

1.12 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged,including trees to be removed from the site identified by the Government as suitable for harvest,shall remain the property of the Government. It is expected that the Government will have cleared the site of harvestable timber stock prior to commencement of construction. Clearing and grubbing shall be the responsibility of the Contractor.

The salvaged property shall be segregated, itemized, delivered, and off-loaded at the Government designated storage area located within the installation as designated and approved by the Contracting Officer.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

1.13 PHYSICAL DATA

The physical conditions indicated on the drawings and in the specifications are the result of site visits, and surveys and borings. See Drawings Sheets for boring logs and data.

1.14 SITE CONTAMINATION

No contaminated soils were found on the site during investigations performed as part of an Environmental Assessment (April 2014) prepared under the requirements of the National Environmental Policy Act.

1.14.1 Contamination Removal

In the event that contamination beyond that shown or specified is encountered, the Contracting Officer shall be advised immediately. The contamination shall be removed as directed and replaced with satisfactory material. Payment therefore will be made in conformance with the CHANGES clause of the CONTRACT CLAUSES.

SECTION 01 11 00.00 50 Page 6

1.14.2 Compliance Requirements

The Contractor shall comply with applicable Federal, state and local laws, codes, ordinances and regulations (including the obtaining of licenses and permits) in connection with any hazardous material, substance or waste.

1.14.3 Requirements

The requirements of this clause and any act or failure to act by the Government shall not relieve the Contractor of any responsibility or liability for the safety of Government, Contractor or subcontractor personnel or property.

1.15 WORK IN QUARANTINED AREA

The work called for by this contract involves activities in counties quarantined by the Department of Agriculture to prevent the spread of certain plant pests which may be present in the soil. The Contractor agrees that all construction equipment and tools to be moved from such counties shall be thoroughly cleaned of all soil residues at the construction site with water under pressure and that hand tools shall be thoroughly cleaned by brushing or other means to remove all soil. In addition, if this contract involves the identification, shipping, storage, testing, or disposal of soils from such a quarantined area, the Contractor agrees to comply with the provisions of ER 1110-1-5 and attachments, a copy of which will be made available by the Contracting Officer upon request.

The Contractor agrees to assure compliance with this obligation by all subcontractors.

1.16 HISTORICAL AND ARCHAEOLOGICAL FINDS

Federal legislation provides for the protection, preservation, and collection of scientific, prehistoric, historical, and archaeological data, including relics and specimens which might otherwise be lost due to alteration of the terrain or building features as a result of any Federal construction project. Should the Contractor, or any of the Contractor's employees, or parties operating or associated with the Contractor, in the performance of this contract discover evidence of possible scientific, prehistoric, historical, or archaeological data, the Contractor shall immediately cease work at that location, avoid further disturbance, and notify the Contracting Officer, giving the location and nature of the findings. The Contractor shall forward written confirmation to the Contracting Officer as directed. The Contractor shall exercise care so as not to disturb or damage artifacts or fossils uncovered during excavation operations, and shall provide such cooperation and assistance as may be necessary to preserve the findings for removal or other disposition. Any person who, without permission, injures, destroys, excavates, appropriates, or removes any historical or prehistoric artifact, object of antiquity, or archaeological resource on the public lands of the United States is subject to arrest and penalty of law. Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance or changes in the work, or both. If such delays or changes are ordered, an equitable adjustment will be made in the contract in accordance with the applicable clauses of the contract.

1.17 EQUIPMENT-IN-PLACE LIST:

The Contractor shall maintain a list of equipment installed under the terms

SECTION 01 11 00.00 50 Page 7 of the contract. In the event that the contract includes more than one building or facility, a list must be maintained for each and delivered to the Contracting Officer upon acceptance of each building or facility.

Forms to be used for this purpose shall be obtained from the Area Engineer's Office. The list shall include the following:

a. Contract number

b. Description of item

c. Model number

d. Serial number

e. Capacity

f. Name of manufacturer

g. Address of manufacturer

h. Condition of item

i. Replacement cost

j. Name of person who checked item

1.18 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.18.1 Allowable Costs

Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a Contractor or subcontractor at any tier shall be based on actual cost data when the Government can determine both ownership and operating costs for each piece of equipment or equipment groups of similar serial and series from the Contractor's accounting records. When both ownership and operating costs cannot be determined from the Contractor's accounting records, equipment costs shall be based upon the applicable provisions of EP 1110-1-8, "Construction Equipment Ownership and Operating Expense Schedule," Region I. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retrospective pricing, the schedule in effect at the time the work was performed shall apply.

1.18.2 Rental Costs

Equipment rental costs are allowable, subject to the applicable provisions of the Federal Acquisition Regulations, and shall be substantiated by certified copies of paid invoices. Rates for equipment rented from an organization under common control, lease-purchase or sale-leaseback arrangements will be determined using the schedule except that rental costs leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees are allowable. Costs for major repairs and overhaul are unallowable.

1.18.3 Equipment Costs

When actual equipment costs are proposed and the total amount of the pricing action is over $25,000, cost or pricing data shall be submitted on the Standard Form 1411, "Contract Pricing Proposal Cover Sheet". By submitting cost or pricing data, the Contractor grants to the Contracting Officer or an authorizing representative the right to examine those books, records, documents and other supporting data that will permit evaluation of the proposed equipment costs. After price agreement the Contractor shall certify that the equipment costs or pricing data submitted are accurate, SECTION 01 11 00.00 50 Page 8 complete and current.

1.18.4 Marine Equipment

In determining the ownership expense for marine equipment as described in the Schedule, the average use per year shall be 8 months.

1.19 SUBCONTRACTS AND WORK COORDINATION

Contract Clauses "SUBCONTRACTS", "PERMITS AND RESPONSIBILITIES", and "MATERIAL AND WORKMANSHIP" are supplemented as follows:

a. Divisions or sections of specifications are not intended to control the Contractor in dividing the work among subcontractor, or to limit work performed by any trade.

b. Contractor shall be responsible for coordination of the work of the trades, subcontractors, and materials.

c. The Government or its representative will not undertake to settle any difference between the Contractor and Contractor's subcontractors, or between subcontractors.

d. The Government reserves the right to refuse to permit employment on the work or require dismissal from the work of any subcontractor who, by reason of previous unsatisfactory work on Corps of Engineers projects, or for any other reason is considered by the Contracting Officer to be incompetent or otherwise objectionable.

1.20 CONSTRUCTION MANPOWER AND EQUIPMENT REPORT

The Contractor shall submit executed CENAO Form 987, Construction Manpower and Equipment Report daily. The report shall include manpower and equipment for the general and subcontractors. Forms are available from the Contracting Officer.

1.21 PURCHASE ORDERS

To ensure proper expediting of orders the Contractor and his subcontractors shall furnish to the Contracting Officer, one copy of each purchase order covering supplies or services required for performance of the work. Each purchase order shall clearly indicate the date of placement, the date delivery is required in order to avoid delay in the scheduled progress of the work, and the date delivery is promised by the supplier or producer.

Copies of purchase orders shall be forwarded on the date issued.

1.22 PROFIT

1.22.1 Weighted Guidelines

Weighted guidelines method of determining profit shall be used on any equitable adjustment change order or modification issued under this contract. The profit factors shall be as follows:

Factor Rate Weight Value

Degree of Risk 20

SECTION 01 11 00.00 50 Page 9

Factor Rate Weight Value Relative difficulty of work 15 Size of Job 15 Period of performance 15 Contractor's investment 05 Assistance by Government 05 Subcontracting 25

1.22.2 Value

Based on the circumstances of each procurement action, each of the above factors shall be weighted from .03 to .12 as indicated below. The value shall be obtained by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

1.22.2.1 Degree of Risk

Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12. Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider: the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

1.22.2.2 Relative Difficulty of Work

If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

1.22.2.3 Size of Job

All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

1.22.2.4 Periods of Performance

Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

1.22.2.5 Contractor's Investment

To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

1.22.2.6 Assistance by Government

To be weighted from .12 to .03 on the basis of average to above average.

Things to consider: use of Government owned property, equipment and

SECTION 01 11 00.00 50 Page 10 facilities, and expediting assistance.

1.22.2.7 Subcontracting

To be weighted inversely proportional to the amount of subcontracting.

Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

1.23 BLASTING

Blasting will not be permitted.

PART 2 PRODUCTS

Not Used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00.00 50 Page 11

SECTION 01 14 00

WORK RESTRICTIONS

11/11

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submittals with an "S" are for inclusion in the Sustainability Notebook, in conformance to Section 01 33 29 SUSTAINABILITY REPORTING.

SD-01 Preconstruction Submittals

Regulation Training Record

List Of Contact Personnel

1.2 SPECIAL SCHEDULING REQUIREMENTS

a. Permission to interrupt any Activity roads, railroads, and/or utility service must be requested in writing a minimum of 15 calendar days prior to the desired date of interruption.

FAR Part 77 requirements related to Crane Operations.

A. All crane locations on the jobsite require submittal of an FAA 7460-1 Airspace Study to FAA.

B. Use of a crane at a specific location requires a minimum 5 day notice to the COR to allow for flight data NOTAM requirements and notifications.

C. All Crane operations are to be coordinated with the COR and Airfield Manager on a daily basis.

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

Contractor shall refer to ANTITERRORISM SECURITY CHECKLIST table below to use as a quick checklist.

AT Level I Training Contractor and subcontractor employees requiring access to controlled installations. (Must be completed within 30 days)

CAC Card 1. Access to DoD facility and DoD networks, via logon.

2. Remote access, via logon, to DoD networks.

3. Phsical access to multiple DoD facilities for a period of 6 months or more.

SECTION 01 14 00 Page 1

AT Awareness Training - Overseas All US based contractor and subcontractor employees traveling overseas. (Must be provided to COR prior to departure)

Suspicious Activity Reporting Training Contractor and subcontractor employees requiring access to controlled installations. (Must be completed within 30 days)

Army Training Cert Tracking System

(ACTS)

Contractor employees who require access to government information systems.

DoD Information Assurance Awareness Training

Contractor employees who require access to government information systems.

OPSEC SOP/Plan Contractors performing classified contracts or has access to critical information. (Must be completed within 90 days of contract)

Level I OPSEC Training All contractor employees. (Must be completed within 30 days)

Escort required All contractor employees when not in possession of appropriate security clearances.

Facility Clearance Required by prime contractor.

Contractor personnel performing work under contract must have required security clearance prior to start of period of fE-verify Program Contractor must pre-screen candidates is E-verify Program website.

http://www.uscis.gov/e-verify

Threat Awareness Reporting Program

(TARP)

All contractors with security clearances.

Opsec Requirements

a. AT Level I training. This provision/contract text is for contractor employees with an area of performance within a controlled installation, facitliy or area. All contractor employees, to include subcontractor employees, requiring access to installations, facilities, controlled access areas, or require network access, shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Upon request, the contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer within 5 calendar days after completion of training by all employeees and subcontractor personnel. AT Level I awareness training is available at the following website: http://jko.jten.mil/courses/atl1/launch.html; or it can be provided by the RA ATO in presentation form which will be documented via memorandum.

b. Access and general protection/security policy and procedures. This standard language text is for contractor employees with an area of performance within a controlled installation, facility or area. All

SECTION 01 14 00 Page 2 contractor and all associated subcontractor's employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

c. Suspicious activity reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something). This standard language is for contractor employees with an area of performance within a controlled installation, facility or area. The contractor and all associated subcontractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

d. For contracts that require OPSEC Training. Per AR 530-1 (Operations Security), contractor employees must complete Level I OPSEC Training within 30 calendar days of contract award. All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the Contracting Officer within 5 calendar days after completion of training. OPSEC awareness training is available at the following websites: https://www.iad.gov/ioss/;

http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

1.3.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry.

The Contractor's equipment shall be conspicuously marked for identification. These site specific regulations will be discussed in more detail at the preconstruction conference. Information is also available upon request through the Contracting Officer's Representative and Owners Representative. Within seven (7) calendar days after the preconstruction meeting submit a regulation training record certifying all contractor employees have reviewed, understand, and agree to abide by the regulations listed.

SECTION 01 14 00 Page 3

1.3.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.3.1.2 Identification Badges and Installation Access

Application for and use of badges will be as directed. Obtain access to the installation by completing Fort Eustis defense biometric identification system (DBIDS) spread sheet for all personnel. Spreadsheets are due to resident office clerk 2 weeks prior to the day access is needed with all columns in light blue filled out. The spreadsheet can be found as an attachment.

a. One-Day Passes: Personnel may obtain one-day passes at the main visitor center but may be subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government will not be responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections.

1.3.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installations, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.3.2 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer.

1.3.3 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in the paragraph "Work Outside Regular Hours."

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, communications, electric service, air conditioning, heating, fire alarm, and compressed air, are considered utility cutovers pursuant to the paragraph entitled "Work Outside Regular Hours."

SECTION 01 14 00 Page 4

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 5

SECTION 01 22 00.00 10

PRICE AND PAYMENT PROCEDURES

08/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submittals with an "S" are for inclusion in the Sustainability Notebook, in conformance to Section 01 33 29 SUSTAINABILITY REPORTING.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-03 Product Data

Weight Certificates

1.2 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this contract on which the contract job payments will be made are listed in the BIDDING SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.2.1 BASE BID - 0001 TWO (2) 20,000 GALLON JET FUEL FACTORY FABRICATED

STORAGE TANKS (UL 2085), FILTER SEPARATORS, COLLECTION TANK, PLATFORMS AND

STAIRS

1.2.1.1 Payment

Payment will be made for costs associated with operations necessary for construction of the TWO (2) 20,000 GALLON JET FUEL FACTORY FABRICATED

STORAGE TANKS (UL 2085), FILTER SEPARATORS, COLLECTION TANK, PLATFORMS

AND STAIRS structures.

1.2.1.2 Unit of Measure

Unit of measure: job.

1.2.2 BASE BID - 0002 TRUCK OFF-LOAD STATIONS

1.2.2.1 Payment

Payment will be made for costs associated with operations necessary for construction of TRUCK OFF-LOAD STATIONS for project.

SECTION 01 22 00.00 10 Page 1

1.2.2.2 Unit of Measure

Unit of measure: job.

1.2.3 BASE BID - 0003 TWO (2) REFUELER TRUCK FILLSTANDS

1.2.3.1 Payment

Payment will be made for costs associated with operations necessary for construction of the TWO (2) REFUELER TRUCK FILLSTANDS for project.

1.2.3.2 Unit of Measure

Unit of measure: job.

1.2.4 BASE BID - 0004 STORAGE BUILDING

1.2.4.1 Payment

Payment will be made for costs associated with operations necessary for construction of the STORAGE BUILDING for project.

1.2.4.2 Unit of Measure

Unit of measure: job.

1.2.5 BASE BID - 0005 REFUELER TRUCK PARKING FIVE (5) STALL AREA

1.2.5.1 Payment

Payment will be made for costs associated with operations necessary for construction of the REFUELER TRUCK PARKING FIVE (5) STALL AREA for project.

1.2.5.2 Unit of Measure

Unit of measure: job.

1.2.6 BASE BID - 0006 SITE IMPROVEMENTS, DEMOLITION, AND SITE PREPARATIONS

1.2.6.1 Payment

Payment will be made for costs associated with operations necessary for construction of the SITE IMPROVEMENTS, DEMOLITION, AND SITE PREPARATIONS for project.

1.2.6.2 Unit of Measure

Unit of measure: job.

1.2.7 BID OPTION - 0007 STOCKPILING, HANDLING, AND DISPOSAL OF PETROLEUM

CONTAMINATED SOIL (CONTAMINATION LEVEL 50-500 PPM)

1.2.7.1 Payment

Payment will be made for costs associated with operations necessary for construction of the STOCKPILING, HANDLING, AND DISPOSAL OF PETROLEUM CONTAMINATED SOIL (CONTAMINATION LEVEL 50-500 PPM). This excludes testing to confirm contamination which is included in section 02 61 13 EXCAVATION

SECTION 01 22 00.00 10 Page 2

AND HANDLING OF CONTAMINATED MATERIAL.

Provide unit pricing as follows:

Total Quantity - 0 to 100 cubic yards.

Total Quantity - 101 to 200 cubic yards.

Total Quantity - in excess of 200 cubic yards.

1.2.7.2 Unit of Measure

Unit of measure: CUBIC YARD.

1.2.8 BID OPTION - 0008 STOCKPILING, HANDLING, AND DISPOSAL OF PETROLEUM

CONTAMINATED SOIL (CONTAMINATION LEVEL GREATER THAN 500 PPM)

1.2.8.1 Payment

Payment will be made for costs associated with operations necessary for construction of the STOCKPILING, HANDLING, AND DISPOSAL OF PETROLEUM CONTAMINATED SOIL (CONTAMINATION LEVEL GREATER THAN 500 PPM). This excludes testing to confirm contamination which is included in section 02

61 13 EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL.

Provide unit pricing as follows:

Total Quantity - 0 to 100 cubic yards.

Total Quantity - 101 to 200 cubic yards.

Total Quantity - in excess of 200 cubic yards.

1.2.8.2 Unit of Measure

Unit of measure: CUBIC YARD.

1.2.9 BID OPTION - 0009 DISPOSAL OF PETROLEUM CONTAMINATED GROUNDWATER

1.2.9.1 Payment

Payment will be made for costs associated with operations necessary for the DISPOSAL OF PETROLEUM CONTAMINATED GROUNDWATER. This excludes testing to confirm contamination which is included in sections 02 61 13 EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL and 02 65 00 UNDERGROUND STORAGE TANK

REMOVAL.

Provide unit pricing as follows:

Total Quantity - For the first ten (10) 5,000-gallon frac tanks.

Total Quantity - Over ten (10) 5,000-gallon frac tanks.

1.2.9.2 Unit of Measure

Unit of measure: FRAC TANK.

1.2.10 BID OPTION - 0010 DEMOLITION OF EXISTING FUELS FACILITY

1.2.10.1 Payment

Payment will be made for costs associated with operations necessary for

DEMOLITION OF EXISTING FUELS FACILITY.

1.2.10.2 Unit of Measure

Unit of measure: job.

SECTION 01 22 00.00 10 Page 3

1.2.11 BID OPTION - 0011 PROVIDE AND INSTALL THE AUTOMATIC TANK GAUGING

SYSTEMS

1.2.11.1 Payment

Payment will be made for costs associated with operations necessary for

PROVIDING AND INSTALLING THE AUTOMATIC TANK GAUGING SYSTEMS.

1.2.11.2 Unit of Measure

Unit of measure: job.

1.2.12 BID OPTION - 0012 CANOPY OVER THE TRUCK OFF-LOAD STATION WITH

INTEGRATED CANOPY LIGHTING

1.2.12.1 Payment

Payment will be made for costs associated with operations necessary for construction of the CANOPY OVER THE TRUCK OFF-LOAD STATION WITH INTEGRATED CANOPY LIGHTING in lieu of POLE MOUNTED TASK LIGHTING.

1.2.12.2 Unit of Measure

Unit of measure: job.

1.2.13 BID OPTION - 0013 CANOPY OVER EACH OF THE TWO (2) TRUCK FILLSTANDS

WITH INTEGRATED CANOPY LIGHTING

1.2.13.1 Payment

Payment will be made for costs associated with operations necessary for construction of the CANOPY OVER EACH OF THE TWO (2) TRUCK FILLSTANDS WITH INTEGRATED CANOPY LIGHTING in lieu of POLE MOUNTED TASK LIGHTING.

1.2.13.2 Unit of Measure

Unit of measure: job.

1.2.14 BID OPTION - 0014 CANOPY OVER THE FILTER/EQUIPMENT PAD WITH

INTEGRATED CANOPY LIGHTING

1.2.14.1 Payment

Payment will be made for costs associated with operations necessary for construction of the CANOPY OVER THE FILTER/EQUIPMENT PAD WITH INTEGRATED CANOPY LIGHTING in lieu of POLE MOUNTED TASK LIGHTING.

1.2.14.2 Unit of Measure

Unit of measure: job.

1.2.15 BID OPTION - 0015 FACILITY LABELING/STENCILING ON THE DD FORM 1354

1.2.15.1 Payment

Payment will be made for costs associated with operations necessary for FACILITY LABELING/STENCILING ON THE DD FORM 1354 section 01 78 00 CLOSEOUT

SUBMITTALS.

SECTION 01 22 00.00 10 Page 4

1.2.15.2 Unit of Measure

Unit of measure: job.

1.2.16 BID OPTION - 0016 BUILDER SCOPE OF SERVICES (SOS) REQUIREMENTS

1.2.16.1 Payment

Payment will be made for costs associated with operations necessary for providing the BUILDER SCOPE OF SERVICES (SOS) REQUIREMENTS section 01 78 00

CLOSEOUT SUBMITTALS.

1.2.16.2 Unit of Measure

Unit of measure: job.

1.2.16.2.1 GENERAL BID NOTES

The government reserves the right to exercise the Option Items 0007, 0008, and 0009 anytime during construction. The Government reserves the right to exercise Option Items 0010 and 0011 within 180 days after the Notice to Proceed. The Government reserves the right to exercise Option Items 0012, 0013, and 0014 within 90 days after the Notice to Proceed. The Government reserves the right to exercise Option Items 0015 and 0016 anytime during construction.

Prices must be entered for all line items on the Pricing Schedule.