W911XK20B0001_Invitation_for_Bid.pdf

W56MES90254683

New Soo Lock Upstream Channel Deepening

1. This is a full and open procurement. In accordance w ith Federal Acquisition Regulation (FAR) 19.1307, this project requires the HUBZone 10% price evaluation.

2. The estimated magnitude of this requirement is betw een $25,000,000 and $100,000,000.

3. The NAICS Code is 237990, w hich has a small business size standard of $39.5 million.

4. Bid or bid modifications received by electronic mail or facsimile (fax) w ill not be considered.

5. A Bid Bond is required. A Bid Bond must be an original. Photocopies w ill not be accepted. (see FAR 52.228-1)

6. Block 11 contains information w ith respect to commencement and completion of the contract. As indicated, FAR 52.211-10 Alt I identif ies the required completion date. The contractor shall NOT make any changes to this clause or to Block 11.

7. Central Contractor Registration and ORCA are now available through the System for Aw ard Management (SAM), available at w w w .sam.gov. Bidders must comply w ith the requirements of FAR 52.204-7 and 52.204-8, 52.232-33, and any other CCR/ORCA requirements in this solicitation through SAM.

X

JESSICA L BAKER 615.736.5640

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

04-Oct-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________630 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10 AltI

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________05 Nov 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U.S.ARMY ENGINEER DISTRICT, DETROIT

477 MICHIGAN AVENUE, 7TH FLOOR

DETROIT MI 48226-4523

W911XK

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: (313) 226-6819 TEL: FAX:

W911XK20B0001 66

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00 10 00 - Solicitation

BID SCHEDULE

BID SCHEDULE

ITEM SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE TOTAL

0001 MOBILIZATION & DEMOBILIZATION 1 JA

0002 SITE PREPARATION &

RESTORATION

1 JA

0003 INSTRUMENTATION INSTALLATION

& MONITORING

1 JA

0004 UNDERWATER BLAST SHOCK OR

IMPULSE STONE PROTECTION

13,800 NT

0005 UPSTREAM APPROACH CHANNEL

DEEPENING

0005AA FIRST 157,800 CY 157,800 CY

0005AB OVER 157,800 CY 122,600 CY

TOTAL AMOUNT OF BASE BID

0006 OPTION 1 - UPSTREAM APPROACH

CHANNEL DEEPENING

0006AA FIRST 13,100 CY 13,100 CY

0006AB OVER 13,100 CY 8,900 CY

TOTAL AMOUNT OF OPTION 1

TOTAL AMOUNT OF BID

SCOPE OF WORK

This project includes deepening of the upstream approach to the locks in the north canal at the Soo Locks complex in Sault Ste. Marie, Michigan in order to eventually accommodate the construction of a new Poe sized lock in the place of the existing Davis and Sabin Locks. The channel will be deepened to 29 feet below Low Water Datum plus 1 foot of required overdepth and 1 foot of allowable overdepth. The removal of both bedrock and overburden material will be required. The contractor will have the option to use mechanical means or blasting to remove the bedrock. Vibration monitoring will be required to ensure nearby structures such as the lock walls, highway and railroad bridges are not affected. Material will be taken by the contractor to an upland disposal site directly adjacent to the work area. Access to the deepening site is limited and is mainly accessible by water.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

BASE CONTRACT

FFP

THIS PAGE WILL BE USED FOR THE AWARDED CONTRACT ENTER

PRICING IN THE BID SCHEDULE

FOB: Destination

MILSTRIP: W56MES90254683

PURCHASE REQUEST NUMBER: W56MES90254683

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job

OPTION OPTION 1

FFP

THIS PAGE WILL BE USED FOR THE AWARDED CONTRACT ENTER

PRICING IN THE BID SCHEDULE

FOB: Destination

MILSTRIP: W56MES90254683

PURCHASE REQUEST NUMBER: W56MES90254683

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 30-SEP-2021 1 U.S.ARMY ENGINEER DISTRICT,

DETROIT

ROBERT W AUSTIN

477 MICHIGAN AVENUE, 7TH FLOOR

DETROIT MI 48226-4523

313.226.6819 FOB: Destination

W911XK

0002 30-SEP-2021 1 (SAME AS PREVIOUS LOCATION)

FOB: Destination

W911XK

Section 00 21 13 - Instructions to Bidders

INSTRUCTIONS

INSTRUCTIONS, CONDITIONS & NOTICES TO BIDDERS

1. INTENT

The intent of this solicitation is to award one (1) Firm Fixed-Price construction contract for the New Soo Lock Upstream Channel Deepening.

2. BASIS OF SELECTION OF AWARD

A. Award shall be made to the lowest priced bidder who is determined to be responsive and responsible.

See Federal Acquisition Regulation (FAR) clause 52.214-19, Contract Award—Sealed Bidding— Construction, for more information.

B. Pursuant to FAR 52.217-5, the Government will evaluate offers for award purposes by adding the price for the option to the total price for the basic requirement. Evaluation of the option will not obligate the Government to exercise the option. The option may be exercised within 120 calendar days after notice to proceed.

3. EVALUATION OF SUBDIVIDED ITEMS:

Item Nos. 0005 and 0006 are subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its subitems. See section 00 73 00 – Supplementary Conditions VARIATIONS IN ESTIMATED QUANTITIES-

SUBDIVIDED ITEMS.

4. SITE VISIT

As indicated in FAR 52.236-27 SITE VISIT (CONSTRUCTION) – ALTERNATE I, an organized site visit will be conducted on October 10, 2019 for the purpose of allowing prospective contractors to physically inspect and determine the characteristics at the project work area. Please refer to the FAR clause 52.236-27 Alt I, Site Visit (Construction) incorporated by full text in this solicitation, for information pertaining to the scheduled site visit.

5. REQUESTS FOR INFORMATION

A. Prospective Bidders should submit questions concerning this Solicitation through the Bidder Inquiry function in ProjNet at www.projnet.org/projnet October 22, 2019. This is the Corps of Engineers’ standard platform for receiving and responding to questions and requests for information.

B. All questions and all responses will be visible to all registered users who sign into the system for this solicitation.

C. To submit and review bid inquiry items, bidders will need to be a current registered user or self-register into the system. To self-register, go to the aforementioned web page and click on the BID tab.

Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

D. From this page, you may view all bidder inquiries or add inquiry.

E. Identification of this Solicitation:

The Solicitation Number is: W911XK20B0001

The Bidder Inquiry Key is: 2IX3P4-AKWVF9

F. Bidders will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

G. Bidders shall not include self-identifying information in any submitted inquiry.

H. Bidders shall submit no more than one question per inquiry that is entered in the system. Inquiries containing multiple questions may be rejected.

I. The Bidder Inquiry System will be stop receiving new inquires 5 business days prior to the required bid submission date in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

J. Bidders are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

K. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

6. SUBMISSION OF BIDS

A. All bidders are reminded to complete and submit with your bid all FAR and DFARS Provisions related to Representations and Certifications.

B. Bidders shall complete and submit any additional full text certifications that are included in the solicitation. An bidder may also complete the certifications at https://www.sam.gov in lieu of completing the representations and certifications in this solicitation provided that all the FAR and DFARS certifications contained in the solicitation have been completed on line.

C. To be considered for award, all bidders shall be registered at https://www.sam.gov with the NAICS code that is shown on the front page of the solicitation.

IMPORTANT NOTICE REGARDING REGISTRATION IN SAM

Effective June 29, 2018 vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) within 30 calendar days of activation or the vendor risks no longer being active in SAM.

Vendors can check whether an account is active by performing a query by their CAGE or Unique Entity Identifier (known as DUNS). The new registration process may now take several weeks, so vendors are highly encouraged to begin registering as soon as possible to avoid any possible delays in future contract awards. Remember, there is no cost to use SAM.

To find out additional information about the changes of the SAM registration process, contractors should visit the Frequently Asked Questions (FAQ) link located at the top of the SAM homepage (www.sam.gov For SAM Customer Service, contact:

Federal Service Desk URL: www.fsd.gov Hours: 8am - 8pm (Eastern Time)

US Calls: 866-606-8220 International Calls: 334-206-7828

DSN: 866-606-8220

D. Remember to fill in and sign the Standard Form 1442, from the front of the Solicitation, before submitting your bid.

E. Bid must be received at the address indicated in Block 8, at the front page of the Solicitation, by the date and time indicated in Block 13.

7. BID OPENING

A public Bid Opening will be conducted at the Contracting Office indicated in Box 7, at the date and time indicated for receipt of bids/offers in Box 13 of the Standard Form 1442 at the front of this solicitation. The Bid Opening will be broadcast via live audio telephone conference. Interested parties may access the conference by calling one of the following numbers and entering the access code when prompted. Callers may log into the conference up to 5 minutes before the stated time.

AUDIO CONFERENCE ACCESS INFORMATION:

USA Toll-Free: 888-675-2535

USA Caller Paid/International Toll : 215-446-0145

ACCESS CODE: 3071395

SECURITY CODE: 1234

8. ELECTRONIC BIDS NOT ACCEPTED

Submittal of bid information by electronic mail, website, text message, or similar means will not be accepted.

9. FACSIMILE BIDS/OFFERS NOT ACCEPTED

Facsimile bids/offers, modifications thereto, or cancellations of bid/offers will not be accepted.

10. AMENDMENTS

Acknowledgement of each amendment by the Bidder must be made in the space provided on the SF 1442, or by returning a signed copy of the amendment by the time set for receipt of bids. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding. Questions (on a non-attribution basis) and answers shall be furnished to all prospective bidders via the web site.

11. SMALL BUSINESS SUBCONTRACTING PLAN

As indicated in Clause 52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (DEVIATION 2018- O0018, and 2019-O0005)--ALTERNATE I, the apparent low bidder, if the company is not a small business concern, will be directed to submit a subcontracting plan for evaluation and approval as a condition of award of any contract pursuant to this solicitation. The goals and requirements of the approved plan shall be incorporated into the contract. Failure to submit a subcontracting plan that conforms with the requirements identified in the clause shall make the bidder ineligible for the award of a contract.

12. NOTICE TO BIDDER: Use of Class I Ozone-Depleting Substances

A. In accordance with Section 326 of P.L. 102-484, the Government is prohibited from awarding any contract which includes a specification or standard that requires the use of a Class I ozone-depleting substance (ODS) identified in Section 601(a) of the Clean Air Act, (42 U.S.C 767a(a)), or that can be met only through the use of such a substance unless such use has been approved, on an individual basis, by a senior acquisitions official who determines that there is no suitable substitute available.

B. To comply with this statute, the Government has conducted a best effort screening of the specifications and standards associated with this acquisition to determine whether they contain any ODS requirements. This requirement has no relationship to ODSs.

C. If the bidder possesses any special knowledge about any other ODSs required directly or indirectly at any level of contract performance, the U.S. Army would appreciate if such information were surfaced to the Contracting Officer for appropriate action. To preclude delay to the procurement, the bidder should provide any information as soon as possible after release of this IFB and prior to the submission of bids to the extent practicable. It should be understood that there is no obligation on the bidder to comply with the request and that no compensation can be provided for doing so.

NOTE: Failure to comply with the above instructions may result in an bidder not being eligible for award.

CONTRACTOR QUALIFICAITONS

A. In accordance with Federal Acquisition Regulation (FAR) Subpart 9.1—Responsible Prospective Contractors, no contract will be awarded unless the contracting officer makes an affirmative determination of responsibility. To be determined responsible, a prospective contractor must –

1. Have adequate financial resources to perform the contract, or the ability to obtain them;

2. Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and governmental business commitments;

3. Have a satisfactory performance record;

4. Have a satisfactory record of integrity and business ethics;

5. Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

6. Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

7. Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

B. In accordance with FAR 9.106 Preaward Surveys, the Government may request financial, organizational, and planning documentation from a prospective contract awardee as necessary to determine compliance with the project requirements, capability of performing the work, and general responsibility for award of a federal contract. Survey information may include equipment lists, banking records, references, preliminary schedules, naval architecture certifications, resumes, certifications and qualifications of personnel and suppliers, and other information as applicable to the project. Failure to respond to a pre-award survey may prevent the Government from awarding a contract to a prospective contractor.

C. SUBCONTRACTING PLAN: In accordance with FAR 19.702 any large business must agree that small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns will have the maximum practicable opportunity to participate in contract performance consistent with its efficient performance. It is further the policy of the United States that its prime contractors establish procedures to ensure the timely payment of amounts due pursuant to the terms of their subcontracts with small business, veteran-owned small business, servicedisabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns. The apparent low bidder, if a large business, shall submit a subcontracting plan within 10 calendar days of request.

W911XK20B0001

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

(End of provison)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a FIRM-FIXED PRICE CONSTRUCTION contract resulting from this solicitation.

(End of provision)

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

5.20% 6.90%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Chippewa County, Michigan.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be twenty (20) percent of the bid price or three million dollars ($3,000,000), whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from :

Mr. Robert Austin U.S. Army Corps of Engineers Detroit District Office 477Michigan Avenue, Suite 700 Detriot, MI 48226

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--

Date: October 10, 2019 Time: 8:00am Eastern Time.

(c) Participants will meet at--

Ramada Plaza Ojibway Soo Lock Confrence Room 240 W. Portage Ave.

Sault Ste. Marie, Michigan 49783

The pre-bid meeting will begin and end in the Soo Locks Conference Room at the Ramada Plaza Ojibway. A site visit to the Soo Locks Facility will be incorporated into the Pre Bid Meeting, please see registration requirements below.

Visitors to the site will have to provide their own Personal Protective Equipment including hard toe footwear, hard hats, safety glasses, reflective vests and HiVis Life Jackets that meet EM 385-1-1 standards. Contractors who do not have these items present at the Site Visit may not be able to participate in the visit. No bathrooms will be available during the site visit.

REGISTRATION: To register, individuals interested in attending the site visit must submit all planned attendeees Full Name(s) and Company Name(s) to USACE POCs Starr Gallegos and Aaron Miller by email to Starr.M.Gallegos@usace.army.mil and Aaron.C.Miller@usace.army.mil no later than 2:00 PM Eastern on October 9, 2019. Notification of approval or denial will be provided prior to the date of the site visit.

Please be sure to bring your Photo ID's with you, they will be checked at registration prior to the site vist.

POINT-OF-CONTACT: For questions and /or concerns regarding the site visit, please contact Contract Specialist Jessica Baker via jessica.l.baker@usace.army.mil.

This will be the only site visit for this project. If you miss the scheduled site visit, no other arrangements will be made due to personnel and time restrictions.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

www.acquisition.gov

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Department of Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

COMPANY INFO

COMPANY NAME AND ADDRESS: _______________________________________

PHONE NUMBER ________________ FAX NUMBER ________________

EMAIL ADDRESS ______________________________________________________

BUSINESS SIZE (select one)

Large Business _____ Small Business_____ HUBZone Business_____ 8A _____

Woman-Owned ____ Service-Disabled Veteran-Owned ____

Contractor is registered with SAM: _____ YES _____ NO (See FAR 52.204-7)

TAX ID # ______________________ CAGE NO. _________

INDICATE Unique Entity Identifier (previously DUNS NUMBER) ___________________ (Note: See FAR 52.204-7. Unique Entity Identifier is a 9 digit numeric code.)

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-19 Incorporation by Reference of Representations and Certifications.

DEC 2014

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS--CERTIFICATION (JUN 2018)

(a) This provision does not apply to acquisitions below the simplified acquisition threshold or to acquisitions of commercial items as defined at FAR 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

____ (1) The Offeror certifies that--

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/t/avc/rls/rpt/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C.