Solicitation Amendment 2 - W519TC25RA0060001.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section A - Solicitation/Contract Form

Repair Beck Avenue - Building 212 to Sylvan Drive

The purpose of this Amendment is the following:

1. To answer the submitted Contractor questions.

2. To incorporate the following documents:

a. Attachment 0007 - SHEET C.01 Amended 5-29-25

b. Attachment 0008 - Beck Avenue Site Visit Attendee list 5-14-25

c. Attachment 0009 - Solicitation Questions 6-3-25

3. To extend the Solicitation closing date from 12:00PM/CST June 4, 2025 to 12:00 PM/CST June 11, 2025.

4. All other terms and conditions remain unchanged.

W519TC25RA0060001

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Repair Beck Avenue - FFP All work is to be done in accordance with Scope of Work for Project #2024-0236.

This is a 160-day working day contract.

The 160 days will begin when Notice to Proceed is issued with completion date of March 7, 2026.

Product Service Code: Z2LB Pricing Arrangement: Firm Fixed Price

1 Job

Excavation T&M. All work is to be done in accordance with the Scope of Work for Project #2024-0236.

This is a 160-day working day contract.

The 160 days will begin when Notice to Proceed is issued with completion date of March 7, 2026.

See Attachment 0003 - Appendix C, sheet number C.01, Table "Estimated Project Quantities".

Product Service Code: Z2LB Pricing Arrangement: Time and Materials

2,207 Cubic Yard

Section C - Description/Specifications/Statement of Work

Requirements Repair Beck Avenue includes demolition of existing facilities, grading, subgrade, paving, storm and sanitary sewer construction and supporting requirements.

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-12 Inspection of Construction. Aug 1996

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: See attached SOW for more details.

DoDAAC: W91QFD CountryCode: USA

W6B9 USAG ROCK ISLAND ARSENAL

BLDG 90 1ST FLOOR, 1 ROCK ISLAND ARSENAL

ROCK ISLAND, IL 61299-5000

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: See attached SOW for more details.

DoDAAC: W91QFD CountryCode: USA

W6B9 USAG ROCK ISLAND ARSENAL

BLDG 90 1ST FLOOR, 1 ROCK ISLAND ARSENAL

ROCK ISLAND, IL 61299-5000

UNITED STATES

Section F - Deliveries or Performance

Overall Contract Delivery Period

From date of lead time event to beginning of performance 15 Calendar Days Date of Notice to Proceed Receipt

From date of lead time event to completion of performance 160 Calendar Days Date of Notice to Proceed Receipt

Line Item Delivery Schedule Quantity Address and POC

1 Job Place of Performance DoDAAC: W91QFD CountryCode: USA

W6B9 USAG ROCK ISLAND ARSENAL

BLDG 90 1ST FLOOR, 1 ROCK ISLAND ARSENAL

ROCK ISLAND, IL 61299-5000

UNITED STATES

2,207 Cubic Yard Place of Performance DoDAAC: W91QFD CountryCode: USA

W6B9 USAG ROCK ISLAND ARSENAL

BLDG 90 1ST FLOOR, 1 ROCK ISLAND ARSENAL

ROCK ISLAND, IL 61299-5000

UNITED STATES

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.236-7000 Modification Proposals--Price Breakdown. Dec 1991

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0490 Issue By DoDAAC W519TC Admin DoDAAC W519TC Inspect By DoDAAC W91QFD Ship To Code W91QFD Ship From Code NA Mark For Code NA Service Approver (DoDAAC) W91QFD Service Acceptor (DoDAAC) W91QFD Accept at Other DoDAAC NA LPO DoDAAC NA DCAA Auditor DoDAAC NA Other DoDAAC(s) NA (*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

rodell.l.reed.civ@army.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

AMC PROTEST

If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible Contracting Officer. However, you can also protest to Headquarters, AMC. The HQ, AMC-Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with General Accounting Office or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. To be timely, protests must be filed within the periods specified in FAR 33.103.

Send protests (other than protests to the Contracting Officer) to:

Headquarters U.S. Army Materiel Command

Office of Command Counsel-Deputy Command Counsel 4400 Martin Road

Rm: A6SE040.001

Redstone Arsenal, AL 35898-5000 Fax:(256) 450-8840 e-mail: usarmy.redstone.usamc.mbx.protests@mail.mil

The AMC-level protest procedures are found at:

http://www.amc.army.mil/amc/commandcounsel.html

If Internet access is not available, contact the Contracting Officer or HQ, AMC Office of Command Counsel to obtain the AMC-Level Protest Procedures.

ROCK ISLAND ARSENAL SECURITY, LAW ENFORCEMENT, FIRE PREVENTION, AND SAFETY REQUIREMENTS

Any contractor personnel entering Rock Island Arsenal (RIA) as the result of this order/contract are required to adhere to all regulations governing safety, law enforcement, security, and fire prevention in effect at the time of entrance. Failure to comply with said regulations may result in immediate removal from RIA. The contractor shall bear full responsibility of the consequences of said removal. Further clarifications of RIA regulations are available from the Contracting Officer for this order/contract.

Emergency Phone Number for Rock Island Arsenal. Dial 9-1-1 FOR POLICE, FIRE - AMBULANCE. State your name, location, nature of emergency and answer any questions the dispatcher may have. Stay on the line with the dispatcher until you are told you can hang up. If calling from a cell phone, tell the dispatcher that you are calling from the Rock Island Arsenal.

OPERATIONS SECURITY (OPSEC) REVIEW:

1. All contractor/sub-contractor employees will coordinate through the COR to insure an OPSEC review is conducted by a Level II certified, Operations Security Officer from the originating command and/or organization prior to the release of any of the following products; picture, map, blue print, memorandum, letter, article, academic paper, video, briefing, contract, news release, technical document, proposal, plan, order, response to Privacy Act requests, or other visual or electronic media. The obligation for prior OPSEC review applies to releases occurring both during and after completion of the contract. If the command/organization does not have a Level II certified OPSEC officer the review will be sent to the next higher headquarters.

2. The contractor/sub-contractor will be responsible for establishing and maintaining an OPSEC program to adequately manage, protect and control critical, sensitive and classified information that has been provided or generated under the contract.

SECURITY REQUIREMENTS:

1. Physical Security. The contractor shall be responsible for proper security and safeguarding of all property within designated work areas, to include all vehicles and storage areas. Loss or theft of property/equipment will be reported to RIA Police immediately upon discovery.

2. Installation Access. All personnel requesting access to Rock Island Arsenal will only enter through a manned and operational Access Control Point and present a United States National or State issued identification that is capable of being scanned for valid entry. All contractor and contractor employees' vehicles, equipment, and packages are subject to inspection or examination (search) at entry/exit of the Arsenal. Security personnel/police will conduct any inspection deemed necessary to enforce security requirements. The contractor shall comply with all installation and other applicable security regulations, requirements, and instructions.

3. Restricted Areas.

i. Contractor personnel requiring access to a restricted area are required to obtain proper identification and authorization. Access or escort with the owner/occupant of the restricted area shall be coordinated through the Contracting Officer's Representative (COR).

ii. Government Administrative Office Areas. Government personnel will be working in office areas during normal working hours. Contractor employees shall cooperate with personnel in the immediate area where any service or maintenance work is being performed. Work performed after normal duty hours shall be coordinated with the Contracting Officer or his designated representative.

4. Industrial Security:

i. Contractor personnel requiring issuance of a government Common Access Card (CAC) and/or require access to any government Automated Information System (AIS), must obtain a favorable National Agency Check with Inquiries (NACI) or equivalent personnel security investigation, initiated by the Garrison Security &Intelligence Division.

ii. Foreign Nationals must be escorted by a US Citizen at all times. This person must be a cleared government employee or a contractor employed on RIA.

iii. Access to the installation may be denied during increased readiness or Force Protection Conditions (FPCONs).

GENERAL SAFETY AND OCCUPATIONAL HEALTH GUIDANCE:

1. The Army has an overall goal of ensuring that contracted work is performed using procedures and risk controls that ensure workers, the public and the environment are not endangered.

2. Contractors must comply with applicable Federal, State, and local codes and standards, including Safety and Occupational Health (SOH) requirements, as well as any additional specific requirements invoked by the contract.

These requirements are listed in, but not limited to: (1) DoD Instruction 6055.01, "DoD Safety and Occupational Health (SOH) Program," (2) Army Regulation 385-10, "The Army Safety Program," (3) Department of the Army Pamphlet 385-10, "Army Safety Program," (4) Occupational Safety and Health Standards, 29 CFR1910, (5) Safety and Health Regulations for Construction, 29 CFR 1926, (6) U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, (7)Local Installation Safety and Health Regulations.

3. Army contractors will be required to have a Safety and Occupational Health Program implemented that is tailored to meet the safety requirements of each contract and the associated tasks and products of that contract. This program will be documented in the contractor's safety plan.

4. Contract activities will be conducted in a safe and healthful manner that minimizes accidents as well as impacts on Army operations and members of the public.

5. Contractors are responsible for the safety and health of their employees and protection of the public at contractor plants and work sites.

PHOTOGRAPHIC EQUIPMENT RESTRICTIONS:

1. There are restrictions on the use of photographic devices in all non-public areas of Arsenal Island. This includes, but is not limited to, digital cameras, cell phones, and personal data assistants (PDAs) with cameras. As stated in Army Regulation 360-1, taking or producing ground or aerial photographs, sketches, or graphic representations of classified military equipment or installations designated as restricted areas is punishable by law (18 USC 795). Reproducing, publishing, selling, or giving away this type of material is also punishable by law unless the photograph, sketch, or graphic representation indicates it has been reviewed and cleared for release by proper authority (18 USC 797). Video, still photos, digital photos, sketches, and graphic representations are for official use only and are not authorized for public release. The contractor must get permission from the Physical Security Office, Bldg 225, to use any type of photographic device at the Access Control Points or in any Restricted Area.

2. Upon completion of this contract, all critical and sensitive information (video, still photos, digital photos, sketches, graphic representations, etc.) that is no longer needed, must be destroyed (burned, shredded, etc.) to prevent the inadvertent disclosure and reconstruction of this material.

ELECTRONIC ACCESS:

1. The COR must coordinate, request, and issue electronic access keys for contractor personnel. Contractor personnel must report the loss of electronic keys immediately to the COR.

KEY CONTROL:

1. The Director, Public Works key custodian, thru the COR, is responsible for issuing keys to the contractor. The contractor shall establish a key control system IAW AR 190-11, Physical Security of Arms Ammunition and Explosives, and AR 190-51, Security of Unclassified Army Property (Sensitive and Non-sensitive), to ensure that none of the keys issued to the contractor are lost, misplaced, or used by unauthorized persons. Government keys shall not be duplicated by the contractor.

2. Replacement. The contractor shall be responsible for all costs incurred as a result of the contractor losing any key. The contractor shall reimburse the government for replacement of locks or keys required as a result of the contractor losing any key(s).

3. Entrance to Locked Areas. The contractor shall not permit entrance to locked areas to any person (other than employees of the contractors engaged in the performance of work in those areas) without authorization by the COR.

4. Lock Combinations. The contractors hall ensure that no lock combinations are made available to unauthorized persons.

AUTOMATED INFORMATION SYSTEMS (AIS) ACCESS:

1. The contractor will ensure that all automation systems are operated, used, maintained and disposed of IAW AR 25-1, AR 380- 5, AR 380-67, DoD M 5200.01-V1, DoDI 5200.01, and all other RIA and higher headquarters regulations.

2. Government Computer Access. The contractor will be responsible for the following items for personnel accessing government systems:

i. No contractor computer accessing a government system will be allowed to access a non- government system through any means.

ii. The contractor will support compliance with all Information Assurance Vulnerability Alerts (IAVA), Information Assurance Vulnerability Bulletins, and Tech. Tips.

iii. The contractor will ensure that all computers and devices are accredited prior to connection to any government network.

iv. The contractor will report information assurance (computer) incidents immediately to their Information Assurance Support Officer.

v. The contractor will ensure that only approved virus detection software is installed on computers.

vi. The contractor will scan all media utilizing approved virus detection software before it is introduced into computers.

vii. Contractors will ensure that individuals accessing government computer systems sign and comply with the Acceptable Use Policy (AUP) and complete initial and annual information assurance awareness training.

viii. The contractor will not process classified data on computers that are not accredited for classified processing.

ix. The contractor will not share personally assigned accounts, passwords, or PINs with anyone.

x. The contractor will use Command Access Card (CAC) as the primary system access credential.

xi. The contractor will not allow anyone else to operate the computer while they are logged on.

xii. The contractor will not use unapproved accounts (such as Hotmail or Yahoo mail) for official army business. The use of a commercial Internet Service Provider (ISP) or email accounts for official purposes is prohibited.

xiii. The contractor will not install their personally owned software, Shareware, Freeware, Public Domain or software downloaded from the INTERNET on a government system.

xiv. The contractor will not be simultaneously connected to a local area network and an active dial-up modem.

xv. The contractor will not be allowed remote management capabilities in the defense perimeter of the RIA.

PARKING:

1. Parking is on a first-come, first served basis, provided the parking space is not posted with a reserved, visitor or handicapped parking sign. Parking is allowed in "marked" spaces only. At no time will a contractor park within 40feet of an inhabited building. Violator's vehicle may be subject to ticketing or towing at contractor expense.

2. All valid spaces are clearly marked with white lines on both sides of the parking space. Vehicles parked in other than valid spaces are subject to being issued a parking ticket.

SMOKING POLICY:

All contractor personnel must comply with local smoking policy. See COR for local policy.

GOVERNMENT INSPECTIONS AND INVESTIGATIONS:

The government reserves the right to conduct announced or unannounced inspections and investigations at any time, pertaining to government information, equipment and/or facilities. This includes, but is not limited to, security, safety, fire prevention, and environmental inspections. The contractor shall cooperate with government officials in the conduct of all investigations.

REMOVAL OF CONTRACTOR OR GOVERMENT-FURNISHED PROPERTY:

The following procedures are prescribed for the issuance of passes for removing contractor owned material and equipment that has been brought onto the Rock Island Arsenal by authorized contractors for use in accomplishing work under a contract, or government-furnished property that, under the terms of a contract, may properly be removed by the contractor.

1. It will be the responsibility of the contracting officer, or designated inspector, to determine that property being removed by a contractor is property of the contractor, or government-furnished property being removed under the terms of the applicable contract. In case of government-furnished property, is involved, it will be the responsibility of the individuals designated above to in sure that all accounting papers prescribed by the contract or other regulations have been completed before the contractor is permitted to remove the property.

2. All contractor owned property will be labeled with the contractor's name for quick identification.

EQUAL EMPLOYMENT OPPORTUNITY (EEO) SERVICES:

EEO does not service contractors. However, if a government employee allegedly discriminates against a contractor employee, the RIA Garrison EEO office should be contacted.

REQUIRED INSURANCE

Pursuant to paragraph (a) of FAR Clause 52.228-5, "Insurance - Work on a Government Installation", or FAR Clause 52.228-7, "Insurance - Liability to Third Persons", the Contractor shall procure and maintain the following insurance during the entire period of performance under this contract:

TYPE AMOUNT

Worke r's Co mpens ation

As required by Law

Emplo yer's Li ability

Minimum liability limit $100,000

Genera l Liabil ity

Minimum bodily injury limits, $500,000 per occurrence

Autom obile L iability

Minimum liability of $200,000 per person, $500,000 per occurrence for bodily injury, and $20,000 per occurrence for property damage

Aircraf t Public and Pa ssenger Coverage required when contract performance Liability involves use of aircraft: Minimum liability of $200,000 per person, $500,000 per occurrence for bodily injury, other than passenger liability, and $200,000 per occurrence for property damage.

Passenger liability shall be at least $200,000 multiplied by the number of seats or number of passengers, whichever is greater.

Vessel Collisi on Lia bility

Coverage required when contract performance involves use of vessels: Minimum liability of $5,000,000 or the market value of the property being shipped by vessel, whichever is greater.

CONTRACTOR PERFORMANCE INFORMATION

The successful offeror/bidder under this solicitation is advised that after contract award its performance under this contract will be subject to an assessment(s) in accordance with FAR 42.15 and AFARS 5142.1503-90. The Department of Defense (DoD) Contractors Performance Assessment Reporting System (CPARS) will be used to maintain the performance report(s) generated on this contract. The rating system to be used in this assessment shall be as follows:

Exceptional (Dark Blue) - Performance meets contractual requirements and exceeds many to the Government's benefit. The contractual performance of the element or sub element being assessed was accomplished with few minor problems for which corrective actions taken by the contractor were highly effective.

Very Good (Purple) - Performance meets contractual requirements and exceeds some to the Government's benefit. The contractual performance of the element or sub element being assessed was accomplished with some minor problems for which corrective actions taken by the contractor were effective.

Satisfactory (Green) - Performance meets contractual requirements. The contractual performance of the element or sub element contains some minor problems for which corrective actions taken by the contractor appear or were satisfactory.

Marginal (Yellow) - Performance does not meet some contractual requirements. The contractual performance of the element or sub element being assessed reflects a serious problem for which the contractor has not yet identified corrective actions. The contractor's proposed actions appear only marginally effective or were not fully implemented.

Unsatisfactory (Red) - Performance does not meet most contractual requirements and recovery is not likely in a timely manner. The contractual performance of the element or sub element contains serious problem(s) for which the contractor's corrective actions appear or were ineffective.

The evaluation procedures to be used in this assessment, which include coordination with the contractor, are detailed in AFARS 5142.1503-90.

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.202-1 Definitions. Jun 2020 52.203-3 Gratuities. Apr 1984 52.203-5 Covenant Against Contingent Fees. May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government. Jun 2020 52.203-7 Anti-Kickback Procedures. Jun 2020

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

May 2014

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. Jun 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

Jan 2017

52.204-2 Security Requirements. (Alternate II) Mar 2021 Alternate II Apr 1984 52.204-9 Personal Identity Verification of Contractor Personnel. Jan 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. Jun 2020 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

Dec 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.204-27 Prohibition on a ByteDance Covered Application. Jun 2023

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

Jan 2025

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. Oct 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.211-13 Time Extensions. Sep 2000 52.215-2 Audit and Records-Negotiation. Jun 2020 52.215-8 Order of Precedence-Uniform Contract Format. Oct 1997 52.215-23 Limitations on Pass-Through Charges. (Alternate I) Jun 2020 Alternate I Oct 2009 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.219-8 Utilization of Small Business Concerns. Jan 2025 52.222-3 Convict Labor. Jun 2003 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. May 2018 52.222-6 Construction Wage Rate Requirements. Aug 2018 52.222-7 Withholding of Funds. May 2014 52.222-8 Payrolls and Basic Records. Jul 2021 52.222-9 Apprentices and Trainees. (DEVIATION 2025-O0003) Jul 2005 Deviation 2025-O0003 Mar 2025 52.222-10 Compliance with Copeland Act Requirements. Feb 1988 52.222-11 Subcontracts (Labor Standards). May 2014 52.222-12 Contract Termination-Debarment. May 2014

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

May 2014

52.222-14 Disputes Concerning Labor Standards. Feb 1988 52.222-15 Certification of Eligibility. May 2014 52.222-26 Equal Opportunity. Sep 2016 52.222-27 Affirmative Action Compliance Requirements for Construction. Apr 2015 52.222-35 Equal Opportunity for Veterans. Jun 2020 52.222-36 Equal Opportunity for Workers with Disabilities. Jun 2020 52.222-37 Employment Reports on Veterans. Jun 2020 52.222-41 Service Contract Labor Standards. Aug 2018

52.222-44 Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment.

May 2014

52.222-50 Combating Trafficking in Persons. Nov 2021 52.222-54 Employment Eligibility Verification. Jan 2025 52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. Jan 2022 52.222-62 Paid Sick Leave Under Executive Order 13706. Jan 2022 52.223-5 Pollution Prevention and Right-to-Know Information. May 2024 52.223-21 Foams. May 2024 52.223-23 Sustainable Products and Services. May 2024 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.226-7 Drug-Free Workplace. May 2024 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024

52.227-4 Patent Indemnity-Construction Contracts. Dec 2007 52.228-2 Additional Bond Security. Oct 1997 52.228-5 Insurance-Work on a Government Installation. Jan 1997 52.228-11 Pledges of Assets (DEVIATION 2020-O0016) Feb 2021 Deviation 2020-O0016 Apr 2020 52.228-12 Prospective Subcontractor Requests for Bonds. Dec 2022 52.228-14 Irrevocable Letter of Credit. Nov 2014 52.229-3 Federal, State, and Local Taxes. Feb 2013 52.229-12 Tax on Certain Foreign Procurements. Feb 2021 52.232-17 Interest. May 2014 52.232-18 Availability of Funds. Apr 1984 52.232-24 Prohibition of Assignment of Claims. May 2014 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.236-2 Differing Site Conditions. Apr 1984 52.236-3 Site Investigation and Conditions Affecting the Work. Apr 1984 52.236-5 Material and Workmanship. Apr 1984 52.236-6 Superintendence by the Contractor. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.236-8 Other Contracts. Apr 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

Apr 1984

52.236-10 Operations and Storage Areas. Apr 1984 52.236-11 Use and Possession Prior to Completion. Apr 1984 52.236-12 Cleaning Up. Apr 1984 52.236-13 Accident Prevention. Nov 1991 52.236-14 Availability and Use of Utility Services. Apr 1984 52.236-15 Schedules for Construction Contracts. Apr 1984 52.236-16 Quantity Surveys. Apr 1984 52.236-17 Layout of Work. Apr 1984 52.236-21 Specifications and Drawings for Construction. Feb 1997 52.242-13 Bankruptcy. Jul 1995 52.242-14 Suspension of Work. Apr 1984 52.243-1 Changes-Fixed-Price. Aug 1987 52.243-3 Changes-Time-and-Materials or Labor-Hours. Sep 2000 52.243-4 Changes. Jun 2007 52.243-5 Changes and Changed Conditions. Apr 1984 52.244-5 Competition in Subcontracting. Aug 2024

52.244-6 Subcontracts for Commercial Products and Commercial Services.

(DEVIATION 2025-O0003)

Jan 2025 Deviation 2025-O0003 Mar 2025

52.245-1 Government Property. Sep 2021 52.245-9 Use and Charges. Apr 2012 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). Apr 1984 52.249-2 Termination for Convenience of the Government (Fixed-Price). (Alternate I) Apr 2012 Alternate I Sep 1996 52.249-10 Default (Fixed-Price Construction). Apr 1984 52.253-1 Computer Generated Forms. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

Jan 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7003 Control of Government Personnel Work Product. Apr 1992

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting.

(DEVIATION 2024-O0013 REVISION 1)

May 2024 Deviation 2024-O0013 May 2024

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.205-7000 Provision of Information to Cooperative Agreement Holders. Oct 2024

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. Jan 2023

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials.

Sep 2014

252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023 252.225-7048 Export-Controlled Items. Jun 2013

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

Jun 2023

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

Jan 2023

252.232-7010 Levies on Contract Payments. Dec 2006 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.243-7002 Requests for Equitable Adjustment. Dec 2022 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023 252.245-7003 Contractor Property Management System Administration Jan 2025 252.245-7005 Management and Reporting of Government Property. Jan 2024 252.247-7023 Transportation of Supplies by Sea. Oct 2024

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. (Apr 1984)

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 45 days[Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 160 days.* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 Liquidated Damages-Construction. (Sep 2000)

Liquidated Damages-Construction (Sept 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the (a) Government in the amount of for each calendar day of delay until the work is completed or accepted.$1,000.00

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These (b) liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.216-7 Allowable Cost and Payment. (Aug 2018)

Allowable Cost and Payment (Aug 2018)

(a) Invoicing.

(1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with Federal Acquisition Regulation (FAR) subpart 31.2 in effect on the date of this contract and the terms of this contract. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract.

(2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act. Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232-25.

(3) The designated payment office will make interim payments for contract financing on the 30th[Contracting Officer insert day as prescribed by agency head; if not prescribed, insert "30th"] day after the designated billing office receives a proper payment request. In the event that the Government requires an audit or other review of a specific payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date.

(b) Reimbursing costs.

(1) For the purpose of reimbursing allowable costs (except as provided in paragraph (b)(2) of this clause, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term "costs" includes only-

(i) Those recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract;

(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for-

(A) Supplies and services purchased directly for the contract and associated financing payments to subcontractors, provided payments determined due will be made-

(1) In accordance with the terms and conditions of a subcontract or invoice; and

(2) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government;

(B) Materials issued from the Contractor's inventory and placed in the production process for use on the contract;

(C) Direct labor;

(D) Direct travel;

(E) Other direct in-house costs; and

(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and

(iii) The amount of financing payments that have been paid by cash, check, or other forms of payment to subcontractors.

(2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid unless-

(i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's indirect costs for payment purposes).

(3) Notwithstanding the audit and adjustment of invoices or vouchers under paragraph (g) of this clause, allowable indirect costs under this contract shall be obtained by applying indirect cost rates established in accordance with paragraph (d) of this clause.

(4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of materials at the Contractor's expense or at no cost to the Government shall be disregarded for purposes of cost-reimbursement under this clause.

(c) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks.

(d) Final indirect cost rates.

(1) Final annual indirect cost rates and the appropriate bases shall be established in accordance with subpart 42.7 of the Federal Acquisition Regulation (FAR) in effect for the period covered by the indirect cost rate proposal.

(2)

(i) The Contractor shall submit an adequate final indirect cost rate proposal to the Contracting Officer (or cognizant Federal agency official) and auditor within the 6-month period following the expiration of each of its fiscal years. Reasonable extensions, for exceptional circumstances only, may be requested in writing by the Contractor and granted in writing by the Contracting Officer. The Contractor shall support its proposal with adequate supporting data.

(ii) The proposed rates shall be based on the Contractor's actual cost experience for that period. The appropriate Government representative and the Contractor shall establish the final indirect cost rates as promptly as practical after receipt of the Contractor's proposal.

(iii) An adequate indirect cost rate proposal shall include the following data unless otherwise specified by the cognizant Federal agency official:

(A) Summary of all claimed indirect expense rates, including pool, base, and calculated indirect rate.

(B) General and Administrative expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts).

(C) Overhead expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) for each final indirect cost pool.

(D) Occupancy expenses (intermediate indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) and expense reallocation to final indirect cost pools.

(E) Claimed allocation bases, by element of cost, used to distribute indirect costs.

(F) Facilities capital cost of money factors computation.

(G) Reconciliation of books of account (i.e., General Ledger) and claimed direct costs by major cost element.

(H) Schedule of direct costs by contract and subcontract and indirect expense applied at claimed rates, as well as a subsidiary schedule of Government participation percentages in each of the allocation base amounts.

(I) Schedule of cumulative direct and indirect costs claimed and billed by contract and subcontract.

(J) Subcontract information. Listing of subcontracts awarded to companies for which the contractor is the prime or upper-tier contractor (include prime and subcontract numbers; subcontract value and award type; amount claimed during the fiscal year; and the subcontractor name, address, and point of contact information).

(K) Summary of each time-and-materials and labor-hour contract information, including labor categories, labor rates, hours, and amounts; direct materials; other direct costs; and, indirect expense applied at claimed rates.

(L) Reconciliation of total payroll per IRS form 941 to total labor costs distribution.

(M) Listing of decisions/agreements/approvals and description of accounting/organizational changes.

(N) Certificate of final indirect costs (see 52.242-4, Certification of Final Indirect Costs).

(O) Contract closing information for contracts physically completed in this fiscal year (include contract number, period of performance, contract ceiling amounts, contract fee computations, level of effort, and indicate if the contract is ready to close).

(iv) The following supplemental information is not required to determine if a proposal is adequate, but may be required during the audit process:

(A) Comparative analysis of indirect expense pools detailed by account to prior fiscal year and budgetary data.

(B) General organizational information and limitation on allowability of compensation for certain contractor personnel. See 31.205-6(p). Additional salary reference information is available at https://www.whitehouse.gov/wp-content/uploads/2017/11 /ContractorCompensationCapContractsAwardedBeforeJune24.pdf and https://www.whitehouse.gov/wp-content/uploads/2017/11 /ContractorCompensationCapContractsAwardedafterJune24.pdf.

(C) Identification of prime contracts under which the contractor performs as a subcontractor.

(D) Description of accounting system (excludes contractors required to submit a CAS Disclosure Statement or contractors where the description of the accounting system has not changed from the previous year's submission).

(E) Procedures for identifying and excluding unallowable costs from the costs claimed and billed (excludes contractors where the procedures have not changed from the previous year's submission).

(F) Certified financial statements and other financial data (e.g., trial balance, compilation, review, etc.).

(G) Management letter from outside CPAs concerning any internal control weaknesses.

(H) Actions that have been and/or will be implemented to correct the weaknesses described in the management letter from subparagraph (G) of this section.

(I) List of all internal audit reports issued since the last disclosure of internal audit reports to the Government.

(J) Annual internal audit plan of scheduled audits to be performed in the fiscal year when the final indirect cost rate submission is made.

(K) Federal and State income tax returns.

(L) Securities and Exchange Commission 10-K annual report.

(M) Minutes from board of directors meetings.

(N) Listing of delay claims…