Amendment 2.pdf

FXSB172827

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to three-fold:

1) Remove DFARS clause 252.223-7999 - Ensuring Adequate COVID-19 Safety Protocols for Federal Contractors, from this solicitation.

2) Answer questions received that are non-technical. Technical questions will be answered by the AE firm (Jacobs Engineering) in a later amendment.

3) Schedule a 2nd site visit for 21 December 2021 @ 10AM AKST. Please meet at 7252 Gibson Ave in the 176 CES parking lot.

All other solicitation terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 17-Dec-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W50S6L22B0001

X 9B. DATED (SEE ITEM 11)

29-Nov-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Dec-2021

CODE

USPFO AK 176 MSC

7252 GIBSON AVE.

ANCHORAGE AK 99506-2959

W50S6L 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

Conner J Van Fossen

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00700 - CONTRACT CLAUSES

The following have been deleted:

252.223-7999 (Dev) Ensuring Adequate COVID-19 Safety Protocols for Federal Contractors (Deviation 2021-O0009)

OCT 2021

(End of Summary of Changes)

W50S6L22B0001

W50S6L-22-B-0001

Amendment 0002 – Q&A

1. There are no Government Safety Requirements in the specifications. Is a Site and Safety Health Officer (SSHO) required?

A: No specific safety requirements are listed in the specifications. However, Section 010000 (DIVISION 01 – General Requirements) para 18.1 states “The contractor shall comply with all applicable Federal, State, Local, DOD, National Guard Bureau, Army and Air Force regulations pertaining to safety, traffic control and fire prevention.”

2. If so, can the project superintendent be the SSHO and CQCSM?

A: Yes

3. Per 011000-1.9.B, is Microsoft Project an approved Critical Path Method (CPM) format?

A: Yes

4. Per 00010, would the government allow electronic bid submission due to the current state of the pandemic?

A: Para 2 of Section 00010 states “electronic submission of bids will not be accepted.”

5. Please confirm that the hangar bay will be empty and available for contractor use during the construction period.

A: The hangar bay will be available for contractor use during the construction period. However, with a PoP of 270 days (assuming 1 Mar 22’ start, PoP ends in end of Nov 22’) and the potential for supply chain issues to delay the delivery of certain parts, we expect the contractor will coordinate scheduling and work with the 176CES & 176MXG in the event hangar space is needed.

6. Note 2 from drawing M-6.2 states; THE DDC SHALL RECEIVE ONE INPUT POINT FROM THE F/A SYSTEM (WHICH WILL BE AN ADDITIONAL ADDRESSABLE RELAY MODULE FROM THEIR SYSTEM INSTALLED BY ATS) Please clarify if ATS will be the exclusive Fire Alarm contractor for this project and if their work is to be included in the contracts bid or if ATS will be contracted directly by the Government?

A: ATS is not required to be exclusive fire alarm contractor. Ensure compatibility with existing system(s). This work shall be included in the offeror’s bid.

7. What do we do with components on wall (i.e. inverter outlet box, conduit, etc.), in way of construction?

A: Relocate components as necessary.

W50S6L22B0001

8. Spec Section 01500.2.1 paragraphs A, B & C call for a field office for the contractor as well as office space for the Government. Can a designated area within the work space inside the Hangar be substituted for these requirements? If not please provide a location where the temporary offices will be staged on site.

A: A designated contractor workspace may be located inside the Hangar bay. Government office space is not required for project. Government personnel will be working from an existing work location (7252 Gibson Ave at the 176CES building).

9. Please provide the manufacturer and model of the existing fire alarm control panel.

A: The main panel is EST (Edwards Systems Technology). It is an EST 3 R 230.

10. Will bathroom facilities in the building be available for construction personnel?

A: Yes, contractors may use the bathrooms in the facility.

W50S6L22B0001