Tailrace Bulk Head Replacement GP Dam specs.pdf

SPECIFICATIONS

(For Construction Contract)

Solicitation Number W9128F22R0011

Tailrace Bulkhead Replacement

Gavin’s Point Dam Crofton, NE

May 2022

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 00 CONSTRUCTION GENERAL

01 22 00.00 10 PRICE AND PAYMENT PROCEDURES

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 78 39.00 24 AS-BUILT DRAWINGS

DIVISION 02 - EXISTING CONDITIONS

02 83 00 LEAD IN CONSTRUCTION

DIVISION 05 - METALS

05 56 09.00 26 BULKHEAD SEALS

05 59 13.01 26 FABRICATION OF HYDRAULIC STEEL STRUCTURES

DIVISION 09 - FINISHES

09 97 02.13 26 PAINTING - HYDRAULIC STRUCTURES

-- End of Project Table of Contents --

Tailrace Bulkhead Refurbish/Replace, Gavins Point Dam, NE GP76

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

1.1.2 Delivery Location

1.2 DRAWINGS

1.3 OCCUPANCY OF PREMISES

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes but is not limited to:

a. Fabrication, painting, delivery, and testing of six new draft tube bulkheads with new seals.

b. Removal and disposal of six existing draft tube bulkheads.

1.1.2 Delivery Location

Delivery location will be at the Gavins Point Dam, approximately 6 miles West of Yankton, South Dakota.

1.2 DRAWINGS

a. The Contract Drawings that accompany these Specifications are a part thereof.

b. Contractor shall immediately check furnished For Information Only (FIO) Drawings and Contract Drawings and notify the Government of any discrepancies.

1.3 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 2

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

1.6.2 State and Local Public Roads

1.7 COOPERATION WITH OTHER CONTRACTORS

1.8 COORDINATION AND OUTAGES

1.9 SUBMITTALS

1.10 WARRANTY OF CONSTRUCTION (MAR 1994)

1.11 TELEPHONE/INTERNET

1.12 USE OF GOVERNMENT EQUIPMENT

1.12.1 Gantry Crane Operation

1.12.2 Working Hours

1.13 PORTABLE TOILETS

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans

SECTION 01 12 00 Page 2 for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation. 1.6.2 State and Local Public Roads

(a) Load Limits:

The South Dakota DOT under the Authority of SDCL 32-22-24, a Highway Maintaining Authority, and local County Road Commissions restrict the load weight of haul vehicles using highways and county road during the spring thaw period. The purpose of the load limits is to protect roads from break-up during the spring thaw. Ensure to conform to the SD DOT load restrictions for hauling, which can be found on the SD DOT website. The load restrictions are usually imposed anytime during the period of 15 February through April 30 depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.7 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of the State and others (public and private) working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid

SECTION 01 12 00 Page 3 undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits. The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.8 COORDINATION AND OUTAGES

The Contractor's employees shall not open, close or tamper with switches, valves or control devices for existing installed equipment. Only Government operating personnel will be authorized to open or close existing switches, valves and control devices to enable the Contractor to make connections or modifications to existing equipment. Work shall be coordinated and scheduled to reduce the "Down" time of operating equipment or systems to a minimum.

The Contractor must cordinate the installation of the bulkheads with the Dam. If the bulkheads are scheduled to arrive on site while the existing bulkheads are in use for inspections, there could be a six week delay waiting for the bulkheads to become availble to complete the install of the new bulkheads. If guide rail slot repairs are underway before the bulkheads are delivered, coordination of the two project schedules should be made with the COR.

The best time to rotate the old and new bulkheads will be April to May.

Unit maintenance schedule usually one unit is un-watered for unit maintenance between November and March

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-AO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

(Agreements for hauling on roads)

Care of Water; G-AO

SD-11 Closeout Submittals

SECTION 01 12 00 Page 4

Warranty of Construction

(List of warranties with copy of each)

1.10 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to

SECTION 01 12 00 Page 5 enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.11 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.12 USE OF GOVERNMENT EQUIPMENT

1.12.1 Gantry Crane Operation

Government personnel only will operate the gantry crane. The Contractor will be responsible for furnishing and performing all rigging for all lifts. The Government must inspect and approve all rigging prior to performing the lift. The Contractor will be responsible for all off-loading, movement, and loading of required construction equipment. .

1.12.2 Working Hours

The Contractor shall properly prepare and plan all lifts such that Government operators are required for a minimum number of occasions. Use of the cranehoist will only be during normal Government working hours. A cranehoist operator will not be furnished on a standby basis. The Contractor shall coordinate with the powerplant superintendent , in writing 24 hours in advance, the need for a cranehoist operator. The Government will operate the crane during the normal daytime working hours of 6:00 am to 4:00 pm Monday thru Thursday .

1.13 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff . Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended

SECTION 01 12 00 Page 6 working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 7

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00.00 10

PRICE AND PAYMENT PROCEDURES

08/15

PART 1 GENERAL

1.1 SINGLE JOB PAYMENT ITEMS

1.1.1 Fabrication of Six New Draft Tube Bulkheads, CLIN 0001

1.1.1.1 Payment

1.1.1.2 Unit of Measure

1.1.2 Delivery of Six New Draft Tube Bulkheads, CLIN 0002

1.1.2.1 Payment

1.1.2.2 Unit of Measure

1.1.3 Removal and Disposal of Existing Six Draft Tube Bulkheads, CLIN 0003

1.1.3.1 Payment

1.1.3.2 Unit of Measure

1.2 OPTIONAL CLIN

1.2.1 Spare Parts, CLIN 0004

1.2.1.1 Payment

1.2.1.2 Unit of Measure

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 22 00.00 10 Page 1

SECTION 01 22 00.00 10

PRICE AND PAYMENT PROCEDURES

08/15

PART 1 GENERAL

1.1 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this contract for which contract job payments will be made are listed in the SCHEDULE and described below.

All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.1.1 Fabrication of Six New Draft Tube Bulkheads, CLIN 0001

1.1.1.1 Payment

Payment will be made in the Contract amount under CLIN 0001 as a unit for all work required. This includes, but is not limited to; fabrication, painting, installation of seals, shop dimensional testing, and onsite testing of the six new Draft Tube Bulkheads, complete, as specified and approved.

1.1.1.2 Unit of Measure

Unit of measure: job.

1.1.2 Delivery of Six New Draft Tube Bulkheads, CLIN 0002

1.1.2.1 Payment

Payment will be made in the Contract amount under CLIN 0002 as a unit for all work required. This includes, but is not limited to; delivery of the six new Draft Tube Bulkheads, complete, as specified and approved.

1.1.2.2 Unit of Measure

Unit of measure: job.

1.1.3 Removal and Disposal of Existing Six Draft Tube Bulkheads, CLIN 0003

1.1.3.1 Payment

Payment will be made in the Contract amount under CLIN 0003 as a unit for all work required. This includes, but is not limited to; removal and disposal of six existing draft tube bulkheads. Removal may not occur until after new bulkheads are delivered and accepted by the Government.

SECTION 01 22 00.00 10 Page 2

1.1.3.2 Unit of Measure

Unit of measure: job.

1.2 OPTIONAL CLIN

1.2.1 Spare Parts, CLIN 0004

1.2.1.1 Payment

Payment will be made in the Contract amount under CLIN 0004 as a unit for all work required. This includes, but is not limited to; fabrication and painting.

1.2.1.2 Unit of Measure

Unit of measure: job.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 22 00.00 10 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

12/21

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 COMPLETION OF WORK

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

1.6 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.7 CONTRACT DRAWINGS AND SPECIFICATIONS

1.7.1 SETS FURNISHED

1.7.2 DISTRIBUTION

1.7.3 NOTIFICATION OF DISCREPANCIES

1.7.4 OMISSIONS

1.8 SUBMITTALS

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

1.9.2 PAYMENT FOR MATERIALS DELIVERED OFFSITE

1.10 DAMAGE TO WORK

1.11 AVAILABILITY AND USE OF UTILITY SERVICES

1.12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.13 INSURANCE REQUIRED

1.14 CONTRACTOR QUALITY CONTROL (CQC)

1.15 NONDOMESTIC CONSTRUCTION MATERIALS

1.16 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.17 AS-BUILT DRAWINGS

1.18 ASBESTOS AND LEAD

1.19 PARTNERING

1.20 PROFIT

1.21 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.22 DRAWING SCALES

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

12/21

PART 1 GENERAL

Attachments:

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a. Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. The electronic payroll service must be capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

(c) The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

SECTION 01 30 00.24 Page 2

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. This durable record copy of data from the electronic payroll processing system must be provided to the Government during contract closeout.

d. All Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service must be included in the Contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services must not be a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 COMPLETION OF WORK

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS), FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984).

SECTION 01 30 00.24 Page 3

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.6 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. AT Level I Training

2. Access and General Protection/Security Policy and Procedures

All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

2b. for Contractors Who Do Not Require CAC, But Require Access To A Dod Facility Or Installation

Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

3. Not Used

SECTION 01 30 00.24 Page 4

4. Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something)

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

5. Contractor Employees Who Require Access to Government Information Systems.

Not Applicable

6. OPSEC Standing Operating Procedure/Plan

Not Applicable

7. OPSEC Training

All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training.

OPSEC awareness training is available at the following websites:

https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

8. Information Assurance (IA)/Information Technology (IT) Training

Not Applicable

9. Information Assurance (IA)/Information Technology (IT) Certification

Not Applicable

10. Not Used

11. Not Used

12. Handling or Access to Classified Information.

Not Applicable

13. Will be Escorted in Areas Where They May be Exposed to Classified and/or Sensitive Materials and/or Sensitive or Restricted Areas

If applicable, all contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

SECTION 01 30 00.24 Page 5

14. Not used

15. Pre-Screen Candidates using E-Verify Program

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

16. Required Armed Security Guards

Not Applicable

17. Threat Awareness Reporting Program (TARP) Training

All new contractor employees will complete annual Threat Awareness and Reporting Program (TARP) Training provided by a Counterintelligence Agent, IAW AR 381-12 . The contractor shall submit certificates of completion for each affected contractor and subcontractor employee(s) or a memorandum for the record, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. Authorized webbased TARP training for CAC card holders is available at the following website: https://www.us.army.mil/suite/page/655474

1.7 CONTRACT DRAWINGS AND SPECIFICATIONS

1.7.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.7.2 DISTRIBUTION

The Government will provide the Contractor with a CD-ROM or DVD-ROM or sent electronically containing Adobe Acrobat.pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS. Prepare final record or as-built drawings as defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

SECTION 01 30 00.24 Page 6

1.7.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in lieu of scale measurements.

Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted adjust the scales accordingly. Advise sub-contractors of the above. Compare all drawings and verify the figures before laying out the work and take responsibility for any errors which might have been avoided thereby.

1.7.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work but work must be performed as if fully and correctly set forth and described in the drawings and specifications.

1.8 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Security Personnel List; G-PO

Security Personnel list as described in Access and General Protection/Security Policy and Procedures see OPSEC paragraphs, subparagraph 2.1.

Personnel Risk Assessment; G-PO

Provide Personnel Risk Assessment for each employee requiring authorized unescorted access to the Jobsite. See OPSEC paragraphs, subparagraph 2.3 iWATCH and/or CorpsWatch Training Sign In Sheets ;

Sign In Sheets for all employee training required for iWATCH and/or CorpsWatch Training, see OPSEC paragraphs, subparagraph 4

OPSEC Training Sign In Sheets ;

Sign In Sheets for all employee training required for OPSEC Training, see OPSEC paragraphs, subparagraph 7

E-Verify ;

Provide E-Verify completion sheets required for OPSEC, see OPSEC paragraphs, subparagraph 15

SECTION 01 30 00.24 Page 7

1.9 PAYMENT

1.9.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.9.2 PAYMENT FOR MATERIALS DELIVERED OFFSITE

a. Pursuant to Federal Acquisition Regulation (FAR) 52.232-5, Payments Under Fixed Price Construction Contracts, materials delivered to the contractor at locations other than the site of the work may be taken into consideration in making payments, if included in payment estimates and if all the conditions of the General Provisions are fulfilled. Payment for items delivered to locations other than the work site are limited to:

(1) Materials required by the technical provisions; or

(2) Materials that have been fabricated to the point where they are identifiable to an item of work required under this contract; or

(3) Items specifically listed below in paragraph b.

b. Payment for materials delivered off-site must be made only after receipt of paid invoices listing the value of material and labor incorporated in the items along with a canceled check showing the prime contractor's title to the items delivered off site. Payment for materials delivered off-site must be limited to the following items: TBD.

1.10 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work shall be as set forth in the GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Permits and Responsibilities." However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood or earthquake, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor will make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work an equitable adjustment pursuant to GENERAL CONDITIONS (CONTRACT CLAUSES) clause: "Changes," of the contract will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

SECTION 01 30 00.24 Page 8

1.11 AVAILABILITY AND USE OF UTILITY SERVICES

a. The Government will make available, from existing outlets and supplies, all reasonably required amounts of water and electricity required in the performance of the work without charge to the Contractor.

There are two 120 V A/C receptacles (20 amps). There are also two 460 V A/C Meltric brand receptacles fed by one 70 amp breaker. The tailrace crane must use one of the Meltric receptacles in order to operate and uses most of the available 70 amps when operating.. There are two treated water hookups, and there are two 100 psi compressed air hookups available to use.

b. Carefully conserve utilities furnished without charge. Install and maintain all necessary temporary connections and distribution lines in a workmanlike manner satisfactory to the Contracting Officer, pay all associated costs, and remove the same prior to final acceptance of the construction.

1.12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default:

(Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 17 Feb 15 Mar 8 Apr 5 May 5 Jun 6

SECTION 01 30 00.24 Page 9

Jul 4 Aug 4 Sep 5 Oct 4 Nov 5 Dec 16

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.13 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.14 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00.00 10 QUALITY CONTROL.

1.15 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

SECTION 01 30 00.24 Page 10

1.16 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor must submit for coordination and approval, their proposed daily work schedule for the next two week period. Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFIs)and any other information that is needed in the minutes of the meeting.

Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, the Contractor must also submit their schedule of proposed dates and times of all preparatory inspections to be performed during the next 2 weeks. All schedules shall be in developed in accordance with Section 01 32 01.00 10 PROJECT SCHEDULE Coordination action by the Contracting Officer relative to these schedules will be accomplished during these weekly meetings. Daily reports must be completed and given to the Contracting Officer or Representative within 24 hours of work. All official correspondence such as serial letters and RFIs, with attachments are to be provided in one hardcopy original with original signatures and one electronic (Adobe pdf format) copy by email.

The Government will consider the correspondence to be received when the official hardcopy or electronic copy is received by the designated office.

1.17 AS-BUILT DRAWINGS

See SECTION 01 78 39.00 24 - AS-BUILT DRAWINGS

1.18 ASBESTOS AND LEAD

a. The Contractor is warned that inhalation of lead has been associated with health hazards.

b. Lead has been determined to be present in some painted surfaces which are scheduled for removal/renovation. See Section 02 83 00 LEAD REMEDIATION for locations and proper procedures.

1.19 PARTNERING

a. The Government intends to encourage the formation of a cohesive partnership with the Contractor. This partnership will be structured to draw on the strengths of each organization to identify and achieve reciprocal goals. The objective is effective contract performance in achieving completion within budget, on schedule and in accordance with plans and specifications. This partnership between the Contractor and the Government will be voluntary and its implementation will not be part of the contract requirements nor will it result in a change to contract price or terms.

b. Not Applicable.

1.20 PROFIT

a. Use the weighted guidelines method of determining profit on any equitable adjustment change order or modification issued under this

SECTION 01 30 00.24 Page 11 contract. The profit factors must be as follows:

Factor Rate Weight Value Degree of Risk 20 See Item Relative difficulty of work 15 b. below Size of Job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

b. Based on the circumstances of each procurement action, each of the above factors must be weighted from .03 to .12 as indicated below. Obtain the value by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

(1) Degree of Risk. Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12.

Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider:

the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

(2) Relative Difficulty of Work. If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

(3) Size of Job. All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

(4) Periods of Performance. Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

(5) Contractor's Investment. To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

(6) Assistance by Government. To be weighted from .12 to .03 on the basis of average to above average. Things to consider: use of Government-owned property, equipment and facilities, and expediting assistance.

(7) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

SECTION 01 30 00.24 Page 12

1.21 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

It is the position of the Department of Defense that the Davis-Bacon Act, 40 U.S.C. 276a is applicable to temporary facilities such as job headquarters, tool yards, batch plants, borrow pits, sandpits, rock quarries, and similar operations, provided they are dedicated exclusively, or nearly so, to performance of the contract or project, and provided they are adjacent or virtually adjacent to the site of the work and are established after receipt of the proposal or bid. Clause "Payrolls and Basic Records" of the GENERAL CONDITIONS (CONTRACT CLAUSES) is applicable to such operations.

1.22 DRAWING SCALES

All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted, the contractor adjust the scales accordingly. The Contractor must also advise their sub-contractors of the above.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 13

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01.00 10

PROJECT SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government Default Software

2.1.2 Contractor Software

2.1.2.1 Primavera

2.1.2.2 Other Than Primavera

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.2 BASIS FOR PAYMENT AND COST LOADING

3.2.1 Activity Cost Loading

3.2.2 Withholdings / Payment Rejection

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

3.3.2 Activity Durations

3.3.3 Procurement Activities

3.3.4 Mandatory Tasks

3.3.5 Government Activities

3.3.6 Standard Activity Coding Dictionary

3.3.6.1 Workers Per Day (WRKP)

3.3.6.2 Responsible Party Coding (RESP)

3.3.6.3 Area of Work Coding (AREA)

3.3.6.4 Modification Number (MODF)

3.3.6.5 Bid Item Coding (BIDI)

3.3.6.6 Phase of Work Coding (PHAS)

3.3.6.7 Category of Work Coding (CATW)

3.3.6.8 Feature of Work Coding…