T10 RFP Instructions 47PE0722R0011 03 03 2022.pdf
PDF 136 KB Posted
- Solicitation number
- 47PE0722R0011
About this file
This request for proposal from the General Services Administration seeks a contractor to correct water intrusion at the JL King Justice Building in Miami, Florida. The construction performance period is 210 calendar days with liquidated damages of $140.32 per day for delays. Demolition work includes removing all existing sealants. New work will replace sealants between precast panels, windows, and other building elements. A water repellent will also be applied. Testing will verify proper sealant installation and waterproofing coverage. Proposals are due April 5, 2022 by 5:00 PM EDT and will be evaluated using lowest price technically acceptable criteria. The solicitation is set aside for service-disabled veteran-owned small businesses.
View the file
Other files
Show all 12
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
GSA Southeast Sunbelt Region
REQUEST FOR PROPOSAL (RFP) INSTRUCTIONS
GSA Solicitation Number: 47PE0722R0011
Description/Title: Correct Water Intrusion, JL King Justice Bldg, Miami
Place of Performance: 99 N.E. Fourth Street Miami, FL 33132
Contracting Officer (CO): Kay Bent, 404-394-4682 kay.bent@gsa.gov Contract Specialist (CS): Ric Sochor, 813-215-6989 ric.sochor@gsa.gov
Who Can Participate in This Procurement?
This procurement is a 100% Service-Disabled Veteran-Owned Small Business Set-Aside IAW 52.219-27
Site Visit & Pre-Proposal Conference:
A pre-proposal site visit has been scheduled for:
March 10, 2022, at 1:00 pm EST.
Offerors are highly encouraged to inspect the site where the work will be performed. See Solicitation Section I.G. FAR 52.236-27 Site Visit – Construction
Bonds & Insurance Requirements
Bid Bond (Provision - FAR 52.228-1) Performance Bond (Clause - FAR 52.228-15) Payment Bond (Clause - FAR 52.228-15) Insurance (Clause - FAR 52.228-5)
Performance Time & Liquidated Damages
The construction performance period is 210 calendar days after issuance of the NTP.
The liquidated damages for each calendar day beyond the performance period completion date: $140.32
Construction Magnitude
Between $1,000,000 - $5,000,000
System for Award Management As prescribed in FAR 4.1100, contractors are required to register in the System for Award Management (SAM) database. Please be sure your record is current!
What D o c u me n t s Do I Submit?
Document
SF 1442 (complete blocks 14 through 20c and price schedule.) Include DUNS/UEI # (blk 14).
Price Proposal – Reference Solicitation Section II.C.
Tech. Proposal – Reference Solicitation Section II.D.
Bid Guarantee – Reference Solicitation Section I.F.
Bond form (SF 24) can be provided upon request.
Offeror’s Representations and Certifications Reference Solicitation Section II.E.
When Is My Offer Due?
Unless changed by amendment, your proposal is due by the date and time specified in Block 13 of the Standard Form 1442, Solicitation, Offer, and Award which is currently:
Date: 4/5/2022 Time: 5:00 PM (EDT)
Check and acknowledge all amendments for offer due date extensions.
What method of award will be used?
LPTA IAW FAR 15.101-2
Reference Solicitation Section VI.
Where Do I Submit My Offer?
Send your electronic proposal documents to the Contract Specialist and Contracting Officer (see POC Info above)
THIS DOCUMENT IS FOR INFORMATIONAL PURPOSES ONLY to assist in proposal submission. The solicitation (RFP) contains the official data and requirements.
mailto:kay.bent@gsa.gov
File details come from the government source that posted it. Updated .