T10 RFP Instructions 47PE0721R0020 03 18 2021.docx
DOCX document 38 KB Posted
- Solicitation number
- 47PE0721R0020
About this file
This document outlines a request for proposal for construction services for a HUD office renovation project. The project involves selective demolition and new construction to reconfigure and renovate HUD office space on the 4th floor of the Brickell Plaza Federal Building in Miami, Florida. Key details include a pre-proposal site visit scheduled for March 25, 2021; a construction performance period of 180 calendar days from notice to proceed with liquidated damages of $591.42 per day for delays; a project magnitude between $500,000 to $1,000,000; and a proposal due date of April 19, 2021 by 5:00 PM EDT. The award will be made using lowest price technically acceptable evaluation. Proposals should include standard forms, price and technical proposals, bid bond, representations and certifications, and be submitted electronically to the specified contracting staff. This is a service-disabled veteran-owned small business set-aside procurement conducted by GSA Region 4 on behalf of HUD.
View the file
Other files
Show all 13
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
GSA Southeast Sunbelt Region
REQUEST FOR PROPOSAL (RFP) INSTRUCTIONS
GSA Solicitation Number: 47PE0721R0020 – Construction Services contract for HUD Office Renovation-4th Floor, Brickell Plaza Federal Building, Miami FL
Place of Performance: 909 SE 1st AVE., MIAMI, FL 33131
Contracting Officer (CO): Cathal Duffy, 407-536-8845 cathal.duffy@gsa.gov Contract Specialist (CS): Ric Sochor, 813-215-6989 ric.sochor@gsa.gov Project Manager/COR: John Valdes, 786-479-7757 john.valdes@gsa.gov
Who Can Participate in This Procurement?
This procurement is a Service-Disabled Veteran- Owned Small Business set-aside IAW 52.219-27
Site Visit & Pre-Proposal Conference:
A pre-proposal site visit has been scheduled for: March 25, 2021, at 9:00 am EDT.
Offerors are highly encouraged to inspect the site where the work will be performed. See Solicitation Section I.G. FAR 52.236-27 Site Visit – Construction
Bonds & Insurance Requirements
Bid Bond (Provision - FAR 52.228-1) Performance Bond (Clause - FAR 52.228-15) Payment Bond (Clause - FAR 52.228-15) Insurance (Clause - FAR 52.228-5)
Performance Time & Liquidated Damages
The construction performance period for this project is 180 calendar days after issuance of the NTP.
The liquidated damages for each calendar day beyond the performance period completion date: $591.42
Construction Magnitude
Between $500,000 - $1,000,000
System for Award Management As prescribed in FAR 4.1100, contractors are required to register in the System for Award Management (SAM) database. Please be sure your record is current!
What D o c u me n t s Do I Submit?
Document
SF 1442 (complete blocks 14 through 20c.)
Price Proposal
Tech. Proposal – Reference Solicitation Section II.D.
Bid Bond (SF 24) – Reference Solicitation Section I.F.
Offeror’s Representations and Certifications Reference Solicitation Section II.E.
When Is My Offer Due?
Unless changed by amendment, your proposal is due by the date and time specified in Block 13 of the Standard Form 1442, Solicitation, Offer, and Award which is currently:
Date: 4/19/2021 Time: 5:00 PM (EDT)
Check and acknowledge all amendments for offer due date extensions.
What method of award will be used?
LPTA IAW FAR 15.101-2
Reference Solicitation Section VI.A.
Where Do I Submit My Offer?
Send your electronic proposal documents to the Contract Specialist and Contracting Officer (see POC Email Info above) image1.png
File details come from the government source that posted it. Updated .