T10 RFP Instructions 47PE0721R0014 12 18 2020.pdf
PDF 109 KB Posted
- Attached to
- Amendment 01, USAO Seven Sinks & Cabinets (Kitchenettes) JL King Justice Building, Miami FL
- Solicitation number
- 47PE0721R0014
About this file
This document provides instructions for a Request for Proposal for design-build construction services for kitchenette renovations at the USAO 7 Sinks & Cabinets J.L. King Justice Building in Miami, Florida. The General Services Administration Southeast Sunbelt Region is seeking proposals for the project with a construction performance period of 210 calendar days from notice to proceed and liquidated damages of $285.63 per day for delays. Proposals are due by January 20, 2021 at 5:00 PM EDT. The anticipated contract value is between $250,000-$500,000. The procurement is set aside for Service-Disabled Veteran-Owned Small Businesses. Offerors must register in the System for Award Management and attend a mandatory pre-proposal site visit on January 6, 2021. Successful offerors will be required to provide performance and payment bonds.
View the file
Other files
Show all 11
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
GSA Southeast Sunbelt Region
REQUEST FOR PROPOSAL (RFP) INSTRUCTIONS
GSA Solicitation Number 47PE0721R0014 – Design Build Construction Services contract for USAO 7 Sinks & Cabinets Kitchenettes – J L King Justice Building, Miami
Place of Performance: 99 N.E. 4th Street, Miami, FL 33040
Contracting Officer (CO): Cathal Duffy, 407-536-8845 cathal.duffy@gsa.gov Contract Specialist (CS): Ric Sochor, 813-215-6989 ric.sochor@gsa.gov Project Manager/COR: Gary DeVeney, 305-299-8939 gary.deveney@gsa.gov
Who Can Participate in This Procurement?
This procurement is a Service-Disabled Veteran- Owned Small Business set-aside IAW
52.219-27
Site Visit & Pre-Proposal Conference:
A pre-proposal site visit has been scheduled for:
January 6, 2021, at 10:00 am EDT.
Offerors are required to inspect the site where the work will be performed. See Solicitation Section I.G.
FAR 52.236-27 Site Visit – Construction
Bonds & Insurance Requirements
Bid Bond (Provision - FAR 52.228-1) Performance Bond (Clause - FAR 52.228-15) Payment Bond (Clause - FAR 52.228-15) Insurance (Clause - FAR 52.228-5)
Performance Time & Liquidated Damages
The construction performance period for this project is 210 calendar days after issuance of the NTP. See Solicitation for design and construction phase timeframes.
The liquidated damages for each calendar day beyond the performance period completion date: $285.63
Construction Magnitude
Between $250,000 - $500,000
System for Award Management As prescribed in FAR 4.1100, contractors are required to register in the System for Award Management (SAM) database. Please be sure your record is current!
What D o c u me n t s Do I Submit?
Document
SF 1442 (complete blocks 14 through 20c.)
Price Proposal
Tech. Proposal – Reference Solicitation Section II.D.
Bid Bond (SF 24) – Reference Solicitation Section I.F.
Offeror’s Representations and Certifications Reference Solicitation Section II.E.
When Is My Offer Due?
Unless changed by amendment, your proposal is due by the date and time specified in Block 13 of the Standard Form 1442, Solicitation, Offer, and Award which is currently:
Date: 1/20/2021 Time: 5:00 PM (EDT)
Check and acknowledge all amendments for offer due date extensions.
What method of award will be used?
LPTA IAW FAR 15.101-2
Reference Solicitation Section VI.A.
Where Do I Submit My Offer?
Send your electronic proposal documents to the Contract Specialist (see POC info above) mailto:cathal.duffy@gsa.gov mailto:gary.deveney@gsa.gov
File details come from the government source that posted it. Updated .