Aerospace_Clause_and_Provisions.doc

SPE601-17-R-0301

AEROSPACE CLAUSES AND PROVISIONS

SPE601-17-R-0301

AEROSPACE CLAUSES AND PROVISIONS

B-0001 B1.09-2 SUPPLIES TO BE FURNISHED (INDEFINITE QUANTITY) (AEROSPACE ENERGY) (DLA ENERGY JAN 2012)

(a) This is an indefinite quantity contract for the purchase of supplies (and/or services, if applicable) to be furnished during the contract term. The delivery points, methods of delivery, and estimated quantities are specified in the Schedule as contract line item numbers (CLINs). The quantities shown are best estimates of required Government quantities only. Unless otherwise specified, the total quantity ordered and required to be delivered/loaded may be greater than or less than such quantities as allowed by the VARIATION IN QUANTITY clause.

(b) The following provisions apply ONLY if the applicable box is checked:

(1) [X] This is a REQUIREMENTS-TYPE contract. The Government agrees to order from the Contractor and the

Contractor shall deliver, if orders are placed by the DLA Energy Contracting Officer during the contract period, all items awarded under this contract, as allowed by the REQUIREMENTS clause. A Blanket Delivery

Order is considered “an order”, for the purposes of this contract provision.

(2) [] This is an INDEFINITE DELIVERY/INDEFINITE QUANTITY contract. The Government agrees to order from the Contractor and the Contractor shall deliver, if orders are placed by the Contracting Officer during the contract period, at least the quantity of supplies or services designated in the Schedule as the

“minimum”, as allowed by the INDEFINITE QUANTITY clause. A Blanket Delivery Order is considered

“an order”, for the purposes of this contract provision

(3) [] Orders issued by the Ordering Officer at the destination location are considered extensions of the Blanket

Delivery Order issued by the DLA Energy Contracting Officer and, as such, may be issued orally, by facsimile or by electronic commerce methods, as allowed by the ORDERING clause.

(4) [X] The unit prices specified below shall be fixed for the term of the contract.

(5) [] The prices paid shall be the unit prices specified in subsequent price change modifications issued in accordance with the ECONOMIC PRICE ADJUSTMENT clause or contract provision, as contained in the solicitation and any resultant contract. See [buyer fills in the appropriate EPA clause or contract provision].

(6) [] Items of this contract call for f.o.b. destination delivery, unless the item specifies otherwise. The destination for each item is the point of delivery shown in the particular item. Inspection for quality will be at origin with final acceptance at destination. Applicable to CLIN(s) ______________

(7) [] F.o.b. destination item(s) called for under this contract shall have shipment quantity determinations performed at destination.

(8) [X] Items of this contract call for f.o.b. origin delivery, unless the item specifies otherwise. Inspection and acceptance will be at origin. Applicable to CLIN(s) _0001-0015__________.

(9) [ ] Any offers received for less than the full quantity for each line item will be rejected by the Government.

(10) [ ] A copy of the certified weight ticket shall accompany each shipment.

(11) [ ] A copy of the Certificate of Analysis shall accompany each shipment.

(12) [ ] An original and one copy of the H-14 Transport Equipment Delay Certificate shall be provided with each shipment, if applicable.

C-0001 C1.02

ASSIST DATABASE OF SPECIFICATIONS (DLA ENERGY MAY 2014)

Unless otherwise specified, current versions of defense or federal specifications and standards, military handbooks, commercial item descriptions, qualified product lists, and other related technical documents cited in this solicitation/contract can be accessed from the Department of Defense (DoD) Acquisition Streamlining and Standardization Information System (ASSIST) database at https://assist.dla.mil under ASSIST-Quick Search or http://quicksearch.dla.mil. ASSIST is the official source for all Defense Standardization Program documents and contains the most current information on documents prepared by DoD, as well as information on how to acquire referenced non-Government standards that have been adopted for DoD use. Those who register for an ASSIST account may establish profiles to receive automatic E-mail alerts when changes are planned or made to documents of interest by selecting criteria on the [Alert Portal Profile Maintenance] screens accessed from the [User Profile] menu. Users may also view or download a bi-monthly summary of changes to the ASSIST database under the [ASSIST Update] menu.

D-0001 D10

PACKAGING REQUIREMENTS (AEROSPACE ENERGY) (DLA ENERGY MAR 2009)

(a) The Contractor shall be responsible for ensuring the hazardous materials shipment is in full compliance with all applicable packaging/packing, marking, labeling, placarding, blocking and bracing, and palletizing and shipping certifications in force and effect on the date of the shipment in accordance with the following applicable rules and regulations for the individual hazard, ultimate destination, and mode of transportation:

(1) Title 49 of the Code of Federal Regulations (49 CFR) -- Packaging.

(2) DLAI 4145.3, Preparing Hazardous Materials for Military Air Shipments.

(3) International Air Transport Association (IATA) -- Dangerous Goods Regulations.

(4) International Civil Aviation Organization (ICAO) -- Technical Instructions for the Safe Transportation of Dangerous Goods by Air.

(5) International Maritime Organization (IMO) -- International Maritime Dangerous Goods (IMDG) Code (for overseas shipments by vessel).

(6) MIL-STD 129, Standard Practice for Military Marking (for military destinations).

(7) MIL-STD-147, Department of Defense Standard Practice, Palletized Unit Loads.

(8) ASME MH 1.8, Wood Pallets.

(b) Contractor commercial packaging (ASTM D 3951) shall also be in compliance with the requirements listed.

E-0001 E1.15

CONTRACTOR INSPECTION RESPONSIBILITIES (AEROSPACE ENERGY) (DLA ENERGY SEP 2013)

(a) QUALITY CONTROL PLAN.

(1) The Contractor is required to provide and maintain an inspection system, and a written description (Quality Control Plan (QCP)) of that system, acceptable to the Government. The Contractor has the option to provide and maintain an inspection system that, as a minimum, incorporates the requirements of ISO9001, Quality Management Systems. If the Contractor chooses to comply with the ISO9001 quality system requirements and format, all the specific Quality Assurance Provisions of this contract must be included in the resulting ISO9001 document that will serve as the QCP. A copy of the QCP, in English, shall be presented to the Government Quality Assurance Representative (QAR) for their review and acceptance prior to commencement of production or services. An acceptable QCP is required prior to Government inspection and acceptance of supplies or services. The QCP shall be reviewed and updated when deemed necessary by the Contractor or the Government, to include changes necessary to prevent the recurrence of quality problems. The Contractor must sign and date the original QCP, as well as each subsequent revision. Revisions shall also be presented to the QAR for review and acceptance prior to implementation. When acceptable to the Government, the original QCP, and any revisions, shall be signed and dated by the QAR.

(2) The QCP shall include--

(i) A schematic diagram of plant facilities pertinent to the inspection system indicating all inspection points;

(ii) Sampling procedures.

(iii) Sample testing methods/procedures;

(iv) Analytical and measuring equipment calibration program;

(v) Loading/shipping procedures;

(vi) Records maintenance and reports preparation/distribution; and

(vii) Corrective action procedures.

(3) The Contractor shall require subcontractors to provide and maintain inspection systems that adhere to the requirements in this contract provision.

(b) The Contractor shall perform all inspection tests required by the specification/item description, and any modifications thereof, on the supplies to be furnished under this contract or shall have such tests performed in a laboratory acceptable to the Government. The Contractor shall notify the QAR in sufficient time to permit inspection by the Government. When such tests are performed at origin on supplies to be accepted at destination, documentation that will enable verification of the original test results shall be provided to the Government at the time of acceptance.

E-0002 E22.01

QUALITY REPRESENTATIVE (DLA ENERGY JUL 1992)

The Quality Office assigned inspection responsibility under this contract will be cited at contract award.

E-0003

E33.10 MANUFACTURING AND FILLING POINTS (AEROSPACE ENERGY) (DLA ENERGY JUL 2008)

(a) Provide the name, complete addresses and telephone number of the manufacturing and filling points for each product to be furnished, and identify the filling points as primary or secondary.

NAME, COMPLETE ADDRESS

AND TELEPHONE NUMBER OF

PRODUCT

MANUFACTURING POINT/FILLING POINT

SERVICES

(Note: List all fill points submitted in Schedule B) 0001 – 0003 Maintenance and Recertification Inspection

0004 – 0006 Cylinder Recertification 0007 – 0009 Maintenance and Repair

1 February 2017 through 31 January 2019

(b) Suppliers that list primary and alternate manufacturing/filling points for supporting the same requirement shall provide a 30 calendar day notice to the Government prior to offering an initial shipment from an alternate manufacturing/filling point.

(c) For f.o.b. origin shipments, the contract price shall not be adjusted if a Contractor uses a different fill location other than the primary fill point during contract performance. However, if the use of the alternate fill point results in increased costs to the Government, such as transportation costs, the Contractor agrees to reimburse the Government for those increased costs.

E-0004 E35

NONCONFORMING SUPPLIES AND SERVICES (DLA ENERGY DEC 2011)

(a) DEFINITION: As used in this contract provision:

Deviation is defined as a written authorization granted after contract award and prior to manufacture of an item, to depart from a particular performance or design requirement of a contract, specification, or referenced document, for a specific number of units or specific period of time, normally the duration of the contract.

Extraordinary situation means the matter cannot await resolution until the next DLA Energy business day (0800 to 1630 hours EST, Monday through Friday, Federal Holidays excluded).

Waiver is defined as a written authorization granted after contract award to accept a configuration item or other designated item which, during production or after having been submitted for inspection, is found to depart from specified requirements, but nevertheless is considered suitable for use “as is” or after repair by an approved method. Approval is on a case-by-case basis and is normally for a set period of time.

(b) The Government may, at its discretion, accept nonconforming supplies or services. In such cases, the Contractor must obtain a deviation or waiver from the Contracting Officer prior to acceptance.

(c) The following procedures shall be used to request a deviation or waiver.

(1) Requests for deviations and waivers shall be submitted by the Contractor to the Contracting Officer with a copy to the appropriate Inspection Office referenced in the LIST OF INSPECTION OFFICES FOR DLA ENERGY CONTRACTS or QUALITY REPRESENTATIVE contract provision of this contract. Each request shall provide the following information: Contractor name; name and contact information of the contractor’s authorized negotiator; contract number; contract line item number and product nomenclature, clause or contract provision number, paragraph and subparagraph, as appropriate; the nature of the request; the reason for the request; the corrective action being taken by the Contractor to correct and prevent recurrence of the condition(s) causing the nonconformance; and an agreement to pay an equitable price reduction, estimated and proposed by DLA Energy, over and above the administrative fee, contingent on the impact of the specific circumstances on DLA Energy relative to approval of the deviation or waiver.

(2) In extraordinary situations, the Contractor may initially submit a verbal request for a waiver, but not a deviation, to the Contracting Officer. Written requests shall be submitted to the Contracting Officer by the next DLA Energy business day (0800 to 1630 hours EST, Monday through Friday, Federal Holidays excluded). If the Contracting Officer cannot be reached, the Duty Officer shall be contacted to provide the necessary information to the proper individuals as soon as possible. The Duty Officer's telephone number is (800) 286-7633 or (703) 767-8420.

(3) If a deviation or waiver is granted, the contract will be modified to accept the nonconforming supplies or services and to require the Contractor to provide an equitable price reduction or other adequate consideration commensurate with the deviation or waiver being granted. If the situation warrants, a deviation or waiver may be granted without prior agreement on price reduction or other consideration, subject to agreement by the Contractor, or its representative, to subsequent negotiation. Such an agreement, in addition to a brief description of the terms of the deviation or waiver, shall be documented on the shipping document or other appropriate correspondence. After negotiations, failure to agree on adequate consideration shall be a dispute concerning a question of fact within the meaning of the Disputes paragraph of the CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS contract provision of this contract.

(4) If a deviation or waiver is granted and the nonconforming supplies are accepted, then in no event will consideration be less than $500, which covers administrative costs, plus any additional cost of Government reinspection or retest, if necessary.

(5) If a deviation or waiver is granted modifying this contract, but the supplies accepted are subsequently determined to be in conformity with contract specifications, the Contractor shall still be obligated to pay the consideration originally agreed upon in support of the deviation or waiver. If, however, this consideration exceeds $1000, a second contract modification shall be issued reducing the Contractor's obligation to $1000 (the administrative cost of issuing the two required modifications), plus, if appropriate, any cost of Government reinspection or retest performed as a result of the deviation or waiver being granted.

(d) When notification of nonconforming supplies is received after the supplies have been accepted, and the Government determines not to exercise its right to reject or to require correction under the INSPECTION OF SUPPLIES – FIXED-PRICE, INSPECTION OF SERVICES – FIXED PRICE, or CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS contract provision, then in no event will consideration be less than $500 to cover administrative costs. This $500 fee is in addition to—

(1) Consideration commensurate with the extent of nonconforming supplies; and

(2) Cost of Government reinspection or retest, if necessary.

The administrative fee will apply to each claim letter issued for off-specification product delivered to an activity.

(e) Contractors shall be held responsible for payment of any fines or penalties imposed on a receiving activity by an environmental enforcement agency, resulting from the delivery of nonconforming supplies under a DLA Energy contract.

(f) Repeated tender of nonconforming supplies or services, including those with only minor defects, will be discouraged by appropriate actions, including, but not limited to, rejecting the supplies or services whenever feasible and documenting the Contractor's performance records.

(4) If a deviation or waiver is granted and the nonconforming supplies are accepted, then in no event will consideration be less than $500, which covers administrative costs, plus any additional cost of Government reinspection or retest, if necessary.

(5) If a deviation or waiver is granted modifying this contract, but the supplies accepted are subsequently determined to be in conformity with contract specifications, the Contractor shall still be obligated to pay the consideration originally agreed upon in support of the deviation or waiver. If, however, this consideration exceeds $1000, a second contract modification shall be issued reducing the Contractor's obligation to $1000 (the administrative cost of issuing the two required modifications), plus, if appropriate, any cost of Government reinspection or retest performed as a result of the deviation or waiver being granted.

(d) When notification of nonconforming supplies is received after the supplies have been accepted, and the Government determines not to exercise its right to reject or to require correction under the INSPECTION OF SUPPLIES – FIXED-PRICE, INSPECTION OF SERVICES – FIXED PRICE, or CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS clause, then in no event will consideration be less than $500 to cover administrative costs. This $500 fee is in addition to—

(1) Consideration commensurate with the extent of nonconforming supplies; and

(2) Cost of Government reinspection or retest, if necessary.

The administrative fee will apply to each claim letter issued for off-specification product delivered to an activity.

(e) Contractors shall be held responsible for payment of any fines or penalties imposed on a receiving activity by an environmental enforcement agency, resulting from the delivery of nonconforming supplies under a DLA Energy contract.

(f) Repeated tender of nonconforming supplies or services, including those with only minor defects, will be discouraged by appropriate actions, including, but not limited to, rejecting the supplies or services whenever feasible and documenting the Contractor's performance records.

E-0005

ENERGY QAP E6 CERTIFICATE OF CONFORMANCE (AUG 2015)

(a) When authorized in writing by the cognizant DLA Energy Contract Administration Office (CAO), the Contractor shall ship with a Certificate of Conformance (COC) any supplies for which the contract would otherwise require inspection at source. In no case shall the Government's right to inspect supplies under the inspection provisions of this contract be prejudiced. Shipments of such supplies will not be made under this contract until use of the COC has been authorized in writing by the CAO, or inspection and acceptance have occurred.

(b) When the contract requires the use of Wide Area Work Flow (WAWF), contractors shall execute COC by including the appropriate indicator in the electronic transaction rather than through inclusion or attachment of the text of the certificate. Government acceptance must still be indicated by a Government official’s electronic signature on the WAWF Energy Receiving Report (ERR).

(c) When WAWF use is not required by contract or WAWF processing in unavailable, the Contractor's signed certificate shall be attached to or included on the first page of the Material Inspection and Receiving Report (DD Form 250) or other authorized document, that is distributed to the payment office (Block 12 of the DD Form 250). A copy shall also be sent with the shipment and to the CAO (Block 10 of the DD Form 250); however, the CAO copy shall only be sent if specifically requested by the Contracting Officer.

(d) The Government has the right to reject defective supplies or services within a reasonable time after delivery by written notification to the Contractor. The Contractor shall in such event promptly replace or correct the rejected supplies or services at the Contractor's expense.

(e) The certificate shall read as follows:

"I certify that on ______________ [insert date], the ______________________________________ [insert Contractor's name] furnished the supplies or services called for by Contract No. ______________________ via ______________________ [Carrier] on ________________________ [identify the bill of lading or shipping document] in accordance with all applicable requirements. I further certify that the supplies or services are of the quality specified and conform in all respects with the contract requirements, including specifications, drawings, preservation, packaging, packing, marking requirements, and physical item identification (part number), and are in the quantity shown on this or on the attached acceptance document."

Date of Execution: ____________________________________________________

Signature: ___________________________________________________________

Title: _______________________________________________________________

F-0001 F3.10 TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES (F.O.B.

DESTINATION) (AEROSPACE ENERGY) (DLA ENERGY DEC 2007)

(a) The Contractor shall be paid for detention beyond free time for delays caused by the Government. Free time will commence at the time the Contractor’s transport truck or truck and trailer arrives at the delivery destination (receiving tank identified in the contract) and will end when the carrier is released. For items involving multiple drops, time between drops will not be included in the free time. The attached Form H-14, Transport Equipment Delay Certificate, shall be completed to show the date and time the carrier arrived and departed and the reason(s) for the delays. This form must be signed by both the driver and unloading personnel. A signed copy of this form must be sent to--

ATTN: DLA ENERGY-MIC (INVOICE MONITOR)

1014 BILLY MITCHELL BLVD

SAN ANTONIO, TX 78226

(b) A minimum of two hours time is required by the Government. If Contractor free time is beyond two hours, indicate here: _________.

(c) The rate for detention shall be comparable to regulated tariffs governing the local area of the receiving activity. The rate for detention shall be stated by quarter hour.

(d) The above will not be considered in the evaluation of offers for award, except that free time of less than two hours or detention rates not comparable to regulated tariffs may render an offer unacceptable/bid nonresponsive.

(e) Detention Costs: Invoices for detention costs will be forwarded directly to the address stated above.

F-0002 F7 DELAY OF CARRIER EQUIPMENT (DETENTION) (AEROSPACE ENERGY) (DLA ENERGY APR 2006)

Detention charges at the Contractor’s facility for delay of the carrier’s equipment in excess of the carrier’s tariff/tender allowable free time is to be documented on the carrier’s Transport Equipment Delay Certificate. Both the carrier driver and the Contractor must sign the certificate.

Documentation shall include the time and date the carrier driver arrived, the time and date the carrier driver departed, and the reason(s) for the delay.

Documentation shall be provided to the carrier driver prior to his departure from the facility F-0003

F21 CONTRACTOR NOTICE REGARDING LATE DELIVERY (DLA ENERGY MAY 2009)

In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery Schedule or date, it shall immediately notify the Contracting Officer, in writing, giving pertinent details. This data shall not be construed as a waiver by the Government of any delivery Schedule or date or of any rights or remedies provided by law or under this contract.

G-0001 G9.07 ELECTRONIC TRANSFER OF FUNDS PAYMENTS - CORPORATE TRADE EXCHANGE (DLA ENERGY

JUL 2007)

(a) The Contractor shall supply the following information to the Contracting Officer no later than 5 days after contract award and before submission of the first request for payment. The bank designated as the receiving bank must be located in the United States and must be capable of receiving Automated Clearing House (ACH) transactions.

NAME OF RECEIVING BANK: | | | | | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 29 CHARACTERS)

CITY AND STATE OF RECEIVING BANK: | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 20 CHARACTERS)

AMERICAN BANKERS ASSOCIATION NINE DIGIT IDENTIFIER OF RECEIVING BANK: | | | | | | | | | |

ACCOUNT TYPE CODE: (Contractor to designate one)

[ ] CHECKING TYPE 22

[ ] SAVINGS TYPE 32

RECIPIENT'S ACCOUNT NUMBER ENCLOSED IN PARENTHESES: | | | | | | | | | | | | | | | |

(DO NOT EXCEED 15 CHARACTERS)

RECIPIENT'S NAME: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

STREET ADDRESS: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

CITY AND STATE: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

NOTE: Additional information may be entered in EITHER paragraph (b) OR paragraph (c) below. Total space available for information entered in (b) OR (c) is 153 characters.

(b) SPECIAL INSTRUCTIONS/OTHER IDENTIFYING DATA:

(DO NOT EXCEED 153 CHARACTERS)

OR

(c) THIRD PARTY INFORMATION: Where payment is to be forwarded from the receiving bank to another financial institution for deposit into Contractor's account, the following information must be supplied by the Contractor: Second Bank Name, City/State and/or Country, Account Number, and Account Name.

(DO NOT EXCEED 153 CHARACTERS)

(d) CONTRACTOR'S DESIGNATED OFFICIAL SUBMITTING ELECTRONIC FUNDS TRANSFER INFORMATION.

NAME: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

TITLE: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

TELEPHONE NUMBER: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

SIGNATURE: ______________________________________________________________________

(e) Any change by the Contractor in designation of the bank account to receive electronic transfer of funds in accordance with this provision must be received by the Contracting Officer no later than 30 days prior to the date the change is to become effective.

(f) The electronic transfer of funds does not constitute an assignment of such funds in any form or fashion.

(g) In the event corporate trade exchange (CTX) payments cannot be processed, the Government retains the option to make payments under this contract by check.

(h) NOTICE TO FOREIGN SUPPLIERS.

(1) Payment may be made through the Federal Reserve Wire Transfer system. The bank designated as the receiving bank must be located in the United States and must be capable of receiving ACH transactions. The appropriate American Bankers Association nine-digit identifier must be supplied in order for payments to be processed through CTX.

(2) If your account is with a foreign bank that has an account with a bank located within the United States, the U.S. bank may be designated as the receiving bank. The recipient's name and account number shall identify the foreign bank, and transfer instructions to supplier's account must be specified in (b) OR (c) above.

(3) The Third Party information supplied in (c) above will be located in the first RMT segment of the CTX payment information sent to the receiving bank.

(i) Notwithstanding any other provision of the contract, the requirements of this provision shall control.

I-0001

I11.01-2 ADMINISTRATIVE COST OF TERMINATION FOR CAUSE – COMMERCIAL ITEMS (DLA

ENERGY FEB 1996)

(a) In the event this contract is terminated for cause, in whole or in part, the Government will incur administrative costs.

(b) The Contractor agrees to pay all administrative costs associated with a contract termination action. The minimum amount the Contractor shall pay for each termination action is $500. This payment for administrative costs is in addition to any excess reprocurement costs and any other remedies or damages resulting from the termination.

(c) The term termination action, as used herein, means the termination for cause, including any associated reprocurement effort, involving--

(1) Any single order or any group of orders terminated together;

(2) Any item or group of items terminated together; or

(3) The entire contract.

I-0002

I190.06 MATERIAL SAFETY DATA SHEETS -- COMMERCIAL ITEMS (DLA ENERGY APR 2006)

(a) The Contractor agrees to submit to the Contracting Officer, upon request, a Material Safety Data Sheet (MSDS) that meets the requirements of 29 CFR 1910.1200(g) and the latest revision of Federal Standard No. 313 for all requested contract items. MSDSs must cite the contract number, the applicable CAGE code of the manufacturer, and, where so identified, the National Stock Number (NSN).

(b) The data on the MSDSs must be current and complete, reflecting the final composition of the product supplied. Should the description/composition of the product change in any manner from a previously submitted MSDS, the Contractor shall promptly provide a new MSDS to the Contracting Officer.

I-0003

I209.09 EXTENSION PROVISIONS (DLA ENERGY JAN 2012)

(a) The Government shall have the right to extend this contract on the same terms and conditions one or more times for a total of no more than six months. Notice of contract extension will be furnished to the Contractor not later than_30 calendar__ days prior to expiration of the contract ordering period or any extension thereof. Nothing in this contract provision precludes the Contractor from agreeing to an extension of the contract if the DLA Energy Contracting Officer fails to issue the notice prior to _30 calendar__ days before the end of the ordering period.

(b) Extension of this contract shall be considered to have been accomplished at the time the DLA Energy Contracting Officer provides written notification to the Contractor.

I-0004

I28.01 FEDERAL, STATE, AND LOCAL TAXES (DLA ENERGY NOV 2011) (DEVIATION)

(a) As used in this contract provision--

(1) After-imposed tax means any new or increased Federal, State, or local tax that the Contractor is required to pay or bear the burden of as the result of legislative, judicial, or administrative action taking effect after the contract date.

(2) After-relieved tax means any amount of Federal, State, or local tax that would otherwise have been payable on the transactions or property covered by this contract, but which the Contractor is not required to pay or bear the burden of, or for which the Contractor obtains a refund or drawback, as the result of legislative, judicial, or administrative action taking effect after the contract date.

(3) All applicable Federal and State taxes means all excise taxes that the taxing authority is imposing and collecting on the transactions or property covered by this contract pursuant to written ruling or regulation in effect on the contract date.

(4) Contract date means the date set for bid opening or, if this is a negotiated contract or a modification, the date set for final revised prices.

(5) Local taxes means taxes levied by the political subdivisions of the States, District of Columbia, or outlying areas of the United

States, e.g., cities and counties.

(6) Outlying areas means—

(i) Commonwealths. Puerto Rico and the Northern Mariana Islands;

(ii) Territories. American Samoa, Guam, and the U.S. Virgin Islands; and

(iii) Minor outlying islands. Baker Island; Howland Island, Jarvis Island; Johnston Atoll; Kingman Reef; Midway Islands;

Navassa Island; Palmyra Atoll; and Wake Atoll.

(7) State taxes means taxes levied by the States, the District of Columbia, or outlying areas of the United States.

(8) Tax means taxes, duties and environmental or inspection fees, except social security or other employment taxes.

(b) The contract price includes all applicable Federal, State, and local taxes, except as otherwise provided. (See either the

FEDERAL AND STATE TAXES/FEES or FEDERAL, STATE, AND LOCAL TAXES AND FEES contract provision.)

(c) The contract price shall be increased by the amount of any after-imposed tax if the Contractor states in writing that the contract price does not include any contingency for such tax.

(d) The contract price shall be decreased by the amount of any after-relieved tax.

(e) The contract price shall also be decreased by the amount of any tax that the Contractor is required to pay or bear the burden of, or does not obtain a refund of, through the Contractor's fault, negligence, or failure to follow instructions of the Contracting Officer.

(f) The Contractor shall promptly notify the Contracting Officer of all matters relating to any tax that reasonably may be expected to result in either an increase or decrease in the contract price and shall take appropriate action as the Contracting Officer directs.

(g) The Government shall, without liability, furnish evidence appropriate to establish exemption from any Federal, State, or local tax when the Contractor requests such evidence and a reasonable basis exists to sustain the exemption.

SOLICITATION PROVISIONS

L-0001 L1.02

PROPOSAL ACCEPTANCE PERIOD (DLA ENERGY NOV 1991)

(a) Acceptance period, as used in this provision, means the number of calendar days available to the Government for awarding a contract from the date specified in this solicitation for receipt of proposals.

(b) This provision supersedes any language pertaining to the acceptance period that may appear elsewhere in this solicitation.

(c) The Government requires a minimum acceptance period of _120_ calendar days.

(d) If the offeror specifies an acceptance period which is less than that required by the Government, such offer may be rejected.

(e) The offeror agrees to execute all that it has undertaken to do, in compliance with its offer, if such offer is acceptable to the Government and is accepted within the acceptance period stated in (c) above or within any extension thereof that has been agreed to by the offeror.

L-0002 L2.11-4

E-MAIL PROPOSALS (DLA ENERGY OCT 2010)

(a) Offerors may submit proposals via e-mail. E-mail proposals are subject to the same rules as paper proposals.

(b) E-mail receiving data and compatibility characteristics are as follows:

(1) E-mail address: Paul.Clay@dla.mil and Maria.Ng@dla.mil

(2) The DLA Energy accepts attachments in—

(i) Adobe Acrobat;

(ii) Microsoft Excel;

(iii) Microsoft Word; and

(iv) Microsoft PowerPoint.

(c) Initial proposals, modifications and proposal revisions submitted via e-mail must contain offeror's signature included in the attachment to the e-mail communication.

(d) Attachments that are not in .pdf file format must be sent password protected for “read only” to ensure the integrity of the data submitted.

(e) Proposals submitted electronically through a single e-mail must be no more than 10 MB. DLA Energy’s mail server will reject messages larger than 10 MB.

(f) The DLA Energy e-mail filter will scan the incoming e-mail and attachments for viruses and key words. Abbreviations for terms such as “Analysts” or using “3Xs” as placeholders in a document are found in the filter’s adult content library and may result in the e-mail delivery being delayed. Offerors are encouraged to verify receipt of e-mail offers by contacting the Contracting Officer prior to the solicitation closing time.

(g) If any portion of an e-mail proposal received by the Contracting Officer is unreadable, the Contracting Officer will immediately notify the offeror and permit the offeror to resubmit the proposal. The method and time for resubmission shall be prescribed by the Contracting Officer after consultation with the offeror and the resubmission shall be considered as if it were received at the date and time of the original unreadable submission for the purpose of determining timeliness, provided the offeror complied with the e-mail submissions instructions provided in this paragraph and with the time and format requirements for resubmission prescribed by the Contracting Officer.

(h) The Government reserves the right to make award solely on the e-mail proposal. However, if requested to do so by the Contracting Officer, the apparently successful offeror promptly shall submit the complete signed original proposal.

L-0003 L2.35

PROPOSAL FORMAT AND CONTENT (AEROSPACE ENERGY) (DLA ENERGY JAN 2012)

(a) All proposals shall consist of a Price Proposal. In addition, a Technical Proposal shall be submitted if indicated in paragraph (c) below.

(b) PRICE PROPOSAL.

(1) In the Schedule, Section B, Supplies or Services and Prices/Costs, offered prices shall be completed for each Contract Line Item Number (CLIN) unless the Schedule notes that multiple awards will be made. In that case, the offeror may select which CLINs or groups of CLINs, such as those applying to a specific customer location, against which to submit an offer;

(2) For each applicable box checked below, unit prices shall be formulated, as specified:

[] (i) Product with no Monthly Facility Fee (MFF). The offeror shall include all fixed, variable and incremental costs to produce and prepare product for Government inspection and acceptance. Include all transportation and shipping costs to deliver the product to the specified customer location if the product CLIN is designation as f.o.b. destination. For this solicitation, the applicable CLINs _________.

[ ] (ii) Product with an MFF CLIN. The offeror shall include only the variable and incremental costs to produce and prepare the product for Government inspection and acceptance in the product CLIN. All fixed costs associated with the facility shall be included in the MFF, to include storage and distribution of Government-owned product, if required by the Statement of Objectives (SOO). For this solicitation, the applicable CLINs are [Buyer fill in the CLIN(s)] _______________________.

[X] (iii) Services CLIN(s), such as maintenance and repair of containers. The offeror shall include all variable and fixed costs associated with the service, as described in the SOO, unless otherwise noted herein that those costs should be included in another CLIN: [Buyer fill in the CLIN(s) or put N/A if not applicable] ______________N/A______________________. For this solicitation, the applicable Services CLINS are CLIN(s) 0001 - 0009.

[] (iv) Repair Parts Specifically Identified in the Schedule. Where the Government specifically identifies repair parts which will be reimbursed under the Contract, the offeror shall include in its offered price, on a per unit basis, all costs associated with that repair part, to include the applicable labor costs to install it. For this solicitation, the applicable CLINS are [Buyer fill in the CLIN(s)] _____________.

[ ] (v) Contractor-Provided Tank(s) CLIN(s). The offeror shall include in each applicable CLIN all fixed and variable costs associated with leasing of a tank or multiple tanks to the Government under the contract. Separate CLINS have been established for the costs associated with the leasing of the tank(s) as compared to the costs associated with the tank(s) installation and removal. Where the incumbent is offering the same number and size of tanks previously provided under the previous contract, the incumbent need not propose a price for tank(s) installation. However, the incumbent shall propose a price for tank(s) removal. For this solicitation, the applicable CLINs are [Buyer fill in the CLIN(s)] ______________. .

[ ] (vi) Contractor provided equipment CLIN(s). Where the SOO requires specific contractor-provided equipment for which a separate CLIN has been established for reimbursement under the resultant contract, the offeror shall include all fixed and variable costs associated with providing such equipment, to include but not limited to delivery, installation, calibration, maintenance and repair throughout the contract term, and removal at the expiration of the contract. For this solicitation, the applicable CLINS are [Buyer fill in the CLIN(s)] _______________ .

[ ] (vii) Expedited/Emergency Delivery CLIN(s). Where the Schedule has a CLIN for Expedited and/or Emergency delivery, as defined in the SOO, the offeror shall include all costs associated with such delivery on a per shipment basis. This encompasses additional labor and transportation costs anticipated to be incurred over and above normal delivery costs. Any product ordered with an Expedited and/or Emergency delivery shall be paid at the unit price of the applicable product CLIN. For this solicitation, the applicable CLINS are [Buyer fill in the CLIN(s)] ____.

[ ] (viii) Hot Fill CLIN(s). If the solicitation includes a “Hot Fill” CLIN, the offeror shall propose a per Hot Fill Unit Price. Examples of costs that should be included in the offeror’s per Hot Fill Unit Price but not limited to these, are additional support personnel required to accomplish the Hot Fill or additional time required at the delivery location in support of the Hot Fill. The per Hot Fill Unit Price shall not include the cost of the product consumed during the Hot Fill since the Contractor will be paid for the amount of product consumed under the applicable product CLIN. For this solicitation, the applicable CLINs are [Buyer fill in the CLIN(s)] ____.

[ ] (ix) Additional CLIN(s) not described above to be priced by the offeror. For this solicitation, the applicable CLINs are [Buyer fill in the CLIN(s) _______.

[ ] (x) Not Separately Priced (NSP) CLIN(s). For CLINs shown as NSP, the offeror shall include the costs associated with that CLIN in the designated CLIN’s unit price. For this solicitation, the applicable Services CLINs are [Buyer fill in the CLIN(s)] _______________________________________.

[ ] (xi) To Be Negotiated (TBN) CLIN(s). For those CLINs designated as TBN, the Government will negotiate a unit price on a case-by-case basis, if and when requirements under the CLIN materialize. In order for the Government to add such a requirement to the contract under the TBN CLIN, the unit price must be determined fair and reasonable. For this solicitation, the applicable CLINs are [Buyer fill in the CLIN(s)]______________.

[X] (xii) Exceptions to the above. ___________0010 - 0015____________________.

(3) The Standard Form 1449 must be completed, as well as the MANUFACTURING AND FILLING POINTS and TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES (AEROSPACE ENERGY) contract provisions, if included, and all certifications and representations contained in Section K of the solicitation.

(c) TECHNICAL PROPOSAL.

(1) A Technical Proposal IS required. If a Technical Proposal is required, the two non-cost factors will be Technical Capability and Past Performance.

(2) TECHNICAL CAPABILITY. The offeror shall provide a technical proposal by completing the required fill-in data only if the applicable box is checked. [buyer checks each applicable block] ). The offeror may submit continuation sheets with this fill-in provision to provide additional technical narrative, however, the complete technical proposal, exclusive of any résumés, drawings, or blueprints, shall not exceed 12 pages. The proposal will be evaluated strictly on technical merit and should describe and justify the offeror's technical approach to the requirements of the work to be performed and/or delivery of product under the contract. The technical proposal should be specific and provide concise, straight-forward descriptions of the offeror's capability to perform the requirements of the contract. Proposals that are unrealistic in terms of the description of the offeror’s technical capability may be considered indicative of a lack of understanding of the solicitation’s requirements. :

[ ] (i) General description of how the offeror will ensure a reliable supply of on-spec product and/or service to meet the Government’s requirements as stated in the solicitation.

[ ] (A) Production capability per day of proposed fill plant.

[ ] (B) Plant storage capacity for product offered.

[ ] (C) If the offeror will be making deliveries to customers, describe type, number and size of containers that will be used for delivery of product to each customer location that the offeror proposes on.

[X] (D) If the contract requires maintenance and repair of Government-owned equipment, such as repairs to cylinders or tube trailers, describe how such services will be performed to meet solicitation requirements.

[ ] (E) Describe the in-process quality control procedures that will ensure the production and delivery of on-spec product.

[ ] (F) Describe offeror’s proposed quality sampling plan that will be implemented to assure individual shipments made under this solicitation meet the product quality requirements stated in the applicable specification or product describe.

[ ] (ii) Description of Contractor-furnished equipment at a location other than the Contractor’s facility (e.g., on Government property) such as storage tanks.

[ ] (A) Describe all Contractor provided equipment to include a description of size, certifications, instrumentation (including alarms), design parameters, etc.

[ ] (B) Include a timeline for the purchase, installation, testing and commissioning of the equipment.

[ ] (iii) Describe the method for securing delivery container(s) and/or cargo tank openings with tamper indicating devices (i.e., seals) to prevent tampering and/or pilferage from the time the cargo tank is loaded until it is delivered to its destination. (Refer to the CONTRACTOR SEAL REQUIREMENT contract provision.)

[ ] (iv) For solicitations containing product CLINs, if the offeror is not the manufacturer of the product to be delivered under the contract or is otherwise proposing to provide product from a fill plant or production facility other than one owned and operated by the offeror, the offeror shall provide a written supply commitment letter from the owner of the fill plant or production facility from where the product will be obtained in performance of any resultant contract. The written supply commitment shall clearly indicate:

[ ] (A) The owner of the fill plant or production facility is willing to provide the products and/or services required to be delivered/performed under any resultant contract for the duration of the delivery period shown in the Schedule; and

[ ] (B) Confirmation of the quantity and specification of the products to be delivered;

[X] (v) This paragraph describes additional information for the Technical Proposal not asked for in above paragraphs.

(1) A narrative describing how the offeror will provide services that meet the schedule and technical requirements of the Request for Proposal. (2) A copy of the DOT Certification that authorizes the offeror to perform the method of DOT Certification testing offered. (3) A narrative on how the offeror intends to protect Government-owned equipment while at Contractor’s facility.

(d) PAST PERFORMANCE. Past Performance information is required in response to all solicitations. For solicitations that require only a Price Proposal, past performance information will be used in the Contracting Officer’s responsibility determination of individual offerors, as required by FAR Part 9. For those solicitations that require a Technical Proposal, past performance information will be used to evaluate past performance as the second non-cost factor in addition to Technical Capability. The offeror shall submit information regarding its past performance on the form entitled Contractor Performance Data Report, as attached to the solicitation. All contracts and subcontracts (completed or in progress) for the last three years awarded by DLA Energy as well as other (completed or in progress) Government agencies or the private sector that are related to the proposed contract shall be included on the form. Failure to submit a complete list may reflect adversely on the offeror. The number of relevant past performance efforts submitted in accordance with the attachment shall not exceed five for the prime offeror. The Government reserves the right to make telephone contact with offerors, proposed subcontractors and references in order to confirm and/or clarify the past performance information submitted. The Government has the option to consider information from these sources, and any others that may be available, that it deems necessary in order to make an accurate assessment of the offeror’s past performance. In addition, the offeror should provide additional information on any significant problems encountered and corrective actions taken under contract(s).

(e) ADDITIONAL INFORMATION. For solicitations containing product CLINs that do not otherwise require a Technical Proposal, if the offeror is not the manufacturer of the product to be delivered under the contract or is proposing to provide product from a fill point or production facility other than one owned and operated by the offeror, the offeror shall provide a written supply commitment letter from the owner of the fill plant or production facility from where the product will be obtained in performance of any resultant contract. This information will be used in the Contracting Officer’s responsibility determination as required by FAR Part 9. The written supply commitment letter must clearly indicate--

[ ] (A) The owner of the fill plant or production facility is willing to provide the products and/or services required to be delivered/performed under any resultant contract for the duration of the delivery period shown in the Schedule; and

[ ] (B) Confirmation of the quantity and specification of the products to be delivered;

(f) EXCEPTIONS. Exceptions (price or technical) taken to the terms and conditions of the solicitation and/or any of its formal attachments shall be identified. Each exception shall be specifically related to each paragraph and/or specific part of the solicitation to which the exception is taken. Provide rationale in support of the exception and fully explain the impact, if any, on the performance, price, and specific requirements of the solicitation. Failure to agree to the terms and conditions of the solicitation may result in the offeror being removed from consideration for award.

L-0004

L54.02 SITE VISIT (AEROSPACE ENERGY) (DLA ENERGY APR 2006)

a) It is the responsibility of the offerors to inspect the site where supplies are to be delivered and/or services are to be performed and to obtain all available information about the site necessary to satisfy themselves about general and local conditions that may…