SolicitationSP310008B0001.pdf

SECTION B

SUPPLIES OR SERVICES AND PRICES

B.1 GENERAL OVERVIEW

This acquisition is unrestricted pursuant to the Small Business Competitiveness Demonstration Program Act of 1988, Public Law 100-656 (15 U.S.C. 644 note). Contract award will be issued pursuant to the Small Business Competitiveness Demonstration Program.

B.2 ELECTRONIC SOLICITATION

This solicitation, including the specifications, drawings, attachments, and any amendments, is only available electronically at the FedBizOpps website (www.fbo.gov). Bidders are cautioned that it is their responsibility to access the website for any amendments that may be issued under the solicitation. There will be no advance notification of amendment issue. Bidders are advised to consult the website frequently to check for the issue of amendments since an amendment may be issued up until the bid opening date and time. Failure to acknowledge amendments may render your bid non-responsive and ineligible for award.

B.3 MAGNITUDE OF CONSTRUCTION Between $1,000,000.00 and $5,000,000.00

B.4 SITE VISIT DATE, TIME AND LOCATION

Reference Section L, FAR Provision 52.236-27 for specific date, time and location.

Due to security measures currently in place on this installation, anyone planning to attend the site visit needs to provide the following information to Donna Kautz Phone: 717-770-6563, Fax:

717-770-7591 or Email: donna.kautz@dla.mil.

This information must be submitted at least two (2) working days prior to the site visit date.

Failure to submit this information in the timeframe requested above may result in delays upon your arrival at the installation.

Company Name Employee Name Employee Social Security Number Employee Date of Birth Employee State and Country of Birth On the date of the site visit, employee will need to present at least one form of photo identification, i.e., valid driver’s license. The employee will also need to present current registration and insurance for each vehicle entering the installation.

B.5 BID SUBMISSION

BIDS MUST BE SUBMITTED IN HARD COPY ONLY. ELECTRONICALLY SUBMITTED BIDS

INCLUDING FACSIMILE AND TELEGRAPH WILL NOT BE ACCEPTED. BID SHALL BE

SEALED IN AN ENVELOPE CLEARLY MARKED WITH THE BID SOLICITATION NUMBER,

THE BID OPENING DATE AND TIME. ALL BIDS SHALL BE SUBMITTED TO THE

ADDRESS SHOWN IN BLOCK 7 ON STANDARD FORM 1442.

B.6 BID OPENING DATE, TIME AND LOCATION.

Bid Opening will be held on December 6, 2007 at 2:00PM local time.

Bid Opening will be held at the Defense Distribution Center, J Avenue, Building 404, New Cumberland, PA 17070.

SP3100-08-B-0001 B-1

http://www.eps.gov/

B.7 ACCESS TO THE INSTALLATION FOR THE BID OPENING.

Due to security measures in place on this installation, anyone planning to hand carry their bid to the bid opening must abide by the same procedures as set forth in Paragraph B.4 above.

Failure to follow these procedures may result in you and your bid being late and therefore ineligible for award.

B.8 CENTRAL CONTRACTOR REGISTRATION. Failure to register in the Central Contractor Registration database by the bid opening date and time will make a bidder ineligible for award. Reference Section I, FAR Clause 52.204-7 and DFARS Clause 252.204-7004.

B.9 BIDS. Bidders must complete Blocks 14 through 20c on the Standard Form (SF) 1442.

Bidders must provide all information requested in Section K Representations, Certifications, and Other Statements of Offerors.

B.10 BID BOND. A bid bond is required. Failure to provide a bid bond for an adequate amount shall result in rejection of bid. Required amount for bid bond is twenty percent (20%).

Reference Section L, FAR Provision 52.228-1.

B.11 PERFORMANCE AND PAYMENT BONDS. The successful bidder shall be required to furnish performance and payment bonds to the Contracting Officer as follows: (Reference Section I, FAR Clause 52.228-15)

(1) Performance Bonds (Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds (Standard Form 25-A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

B.12 SUBCONTRACTING PLAN. (This only applies to a large business.) The apparent low bidder shall submit a subcontracting plan that separately addresses subcontracting with small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns. The subcontracting plan shall be submitted within three business days from the date of low bid notification to the apparent low bidder. The plan shall be included in and made a part of the resultant contract. Failure to submit the subcontracting plan shall make the bidder ineligible for the award of a contract. Reference Sections L and M for Subcontracting Plans.

SP3100-08-B-0001 B-2

SCHEDULE OF SUPPLIES/SERVICES

Note: The following project description is for the purpose of general information and is not intended to include and describe every feature or item or to define the scope of work.

PROJECT DESCRIPTION: This project consists of performing work associated with renovating and upgrading 18 restrooms in Building 2001. Work includes but not limited to plumbing fixture replacements, ceramic tile work, mechanical improvements, lighting improvements, ceiling replacements, cleaning and related painting. All work shall be performed complete and in accordance with the specifications and drawings, entitled Repair and Upgrade Restrooms Building 2001 dated September 2007 and drawing numbers: Project No. 3558 Sheets 1-57 dated September 2007.

Davis Bacon Wage Determination PA070010 Modification 8 dated 8/31/07 applies to this acquisition.

BID SCHEDULE

REPAIR AND UPGRADE RESTROOMS

BUILDING 2001 EDC

Base Bid: Including the necessary labor, material and/or equipment to perform all work to repair and upgrade restrooms Building 2001 EDC as indicated on the attached drawings and specifications.

TOTAL BID PRICE $ _____________________________

END OF SCHEDULE OF SUPPLIES/SERVICES

SP3100-08-B-0001 B-3

SECTION C

DESCRIPTION/SPECIFICATIONS

C.1 SPECIFICATIONS. The following document is provided as part of the solicitation package and shall be used in the execution of work under this contract:

DEFENSE LOGISTICS AGENCY

DEFENSE DISTRIBUTION DEPOT SUSQUEHANNA PENNSYLVANIA

NEW CUMBERLAND, PA 17070-5011

SPECIFICATIONS

FOR

REPAIR AND UPGRADE RESTROOMS

BUILDING 2001 EDC

OFFICE OF THE FACILITIES ENGINEER

SEPTEMBER 2007

LOCATED AT SECTION J OF THIS SOLICITATION

ATTACHMENT A

END OF SECTION C

SP3100-08-B-0001 C-1

SECTION D

PACKAGING AND MARKING

THIS SECTION NOT REQUIRED

END OF SECTION D

SP3100-08-B-0001 D-1

SECTION E

INSPECTION AND ACCEPTANCE

E.1 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

END OF SECTION E

SP3100-08-B-0001 E-1

SECTION F

DELIVERIES OR PERFORMANCE

F.1 52.211-13 TIME EXTENSIONS (SEP 2000)

F.2 52.242-14 SUSPENSION OF WORK (APR 1984)

F.3 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION

OF WORK (APR 1984) (DEVIATION)

The Contractor shall be required to

(a) commence work under this contract upon receipt of the notice to proceed according to the following schedule:

Upon issuance of the notice to proceed, the Government will establish a date and time (approximately 14 calendar days after the date the Contractor receives the notice to proceed) for the preconstruction conference. The Contractor shall be required to provide all initial submittal items identified on the submittal register and non-technical initial submittals as outlined in the specification at the preconstruction conference. Exceptions to this submittal delivery requirement may be for materials that have a long-lead time.

1. Project Submittal Schedule- This schedule must be provided at the preconstruction meeting for all initial submittal register items not provided at the Preconstruction meeting.

2. Contractor must provide non-technical submittal as outlined in section 01330, part 1.1.2 Submittal Descriptions of the specifications.

The Contractor shall complete the project and have ready for use within 300 days after receipt of Notice to Proceed.

(b) prosecute the work diligently, and

(c) complete the entire work ready for use as indicated above.

The time stated for completion shall include final cleanup of the premises.

(End of clause)

F.4 52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of _ $195.00_ for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed.

These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

END OF SECTION F

SP3100-08-B-0001 F-1

SECTION G

CONTRACT ADMINISTRATION DATA

G.1 252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE

DFARS (DEC 1991)

(a) "Definition. Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

END OF SECTION G

SP3100-08-B-0001 G-1

SECTION H

SPECIAL CONTRACT REQUIREMENTS

H.1 DEPOT REGULATIONS. Illegal drugs, guns or other contraband are not authorized on this Federal installation. It is the contractor's responsibility to ensure that its employees working on-site at this installation are U.S. citizens or legal aliens with no outstanding warrants. This installation is manned by a DoD Police Force who possesses apprehension authority, which includes holding suspects for local authorities. These officers can and will charge individuals with an established court appearance via the Federal Magistrate. This agency processes illegal aliens in accordance with INS instructions.

H.2 SECURITY PROCEDURES FOR CONSTRUCTION CONTRACTORS

WORKING AT THE DEFENSE DISTRIBUTION DEPOT SUSQUEHANNA (DDSP),

NEW CUMBERLAND, PA.

H.2.1 EMPLOYEES/PERSONNEL AND VISITORS

All persons, with the exception of delivery truck drivers, entering the installation must obtain an Identification Badge from DDSP Security, Pass and ID. All visitors and personnel expected to be on site for less than 90 days will receive a temporary badge.

Personnel expected to be on site for longer than 90 days will be provided a permanent badge. The construction contractor shall follow the procedures below to obtain and renew Identification Badges for all direct hire and subcontractor employees and visitors:

1) Complete the attached New PERSONNEL NOTIFICATION form (Attachment “A”).

2) Complete the attached Identification Badge request form for each employee. Use the short form (Attachment “B”) for personnel expected to be on site less than 90 days. Us the long form (Attachment “C”) for personnel expected to be on site more than 90 days. (Note: Only employees with permanent badges will be permitted to escort delivery vehicles and new employees.)

3) Fax only NEW PERSONNEL NOTIFICATION form to security desk at 717-770- 5480 and Contracting Officer’s Representative (COR) at 717-770-2910 the day prior to arrival (day prior is the minimum, may be sent up to one week prior to arrival) .

4) Fax NEW PERSONNEL NOTIFICATION form and Identification Badge request forms to Pass and ID Section (located at Post 3) at 717-770-8146 the day prior to arrival (day prior is the minimum, may be sent up to one week prior to arrival).

5) When new personnel arrive at Post 3 (DDSP entrance gate nearest the Eastern Distribution Center, Building 2001) security will notify the escort designated on the NEW PERSONNEL NOTIFICATION form. The escort will be required to meet the new personnel at Post 3 and escort same to Pass and ID for processing. If the

SP3100-08-B-0001 H-1

contractor has completed step 4 in a timely manner, badge information will be entered into DDSP system prior to arrival and will be an aid to expedite processing.

6) When new personnel arrive at Pass and ID, they will be required to provide a valid photo identification card (Driver’s License preferred) and registration and proof of insurance for any vehicles that they will be driving on the installation. New personnel will then receive a DDSP photo ID badge and a “paper” temporary vehicle pass.

The prime contractor will be responsible for providing a weekly updated list of all badges issued by Pass and ID to the COR. Badge listing shall identify Project Name, Prime contractor name and any subcontractor names. This listing shall provide the employee’s/visitor’s name, badge number (only 90 day + duration badges are assigned a number), employer, date issued and date returned to Pass and ID. Failure to return all badges issued, including temporary and/or expired badges may delay progress and/or final contract payments. The COR will forward a copy to the DDSP Pass and ID section by fax for weekly reconciliation.

H.2.2 BADGE RENEWAL OF EXPIRED OR EXPIRING BADGES

Complete a new long form badge application (Attachment “D”) and FAX to Pass and ID section (717-770-8146) 24 hours in advance of renewal application.

H.2.3 ENTRANCE INTO DDSP

Contractor personnel with DDSP ID badges, entrance into DDSP is determined by the type of vehicle they are driving:

Contractor with sedan Enter via Post 3 (EDC Gate) Contractor with empty pick-up truck Enter via Post 3 (EDC Gate) Contractor with pick-up containing tools or Enter via Post 4 (Truck Gate) jobsite equipment or having a cap Contractor with utility vehicle or van Enter via Post 4 (Truck Gate)

H.2.4 DELIVERIES

All contractor deliveries shall enter the installation through Post 4 (DDSP Truck Gate).

To help avoid delays at the entrance, all deliveries should be scheduled after 8:00AM whenever possible. The construction contractor shall follow the following procedure for all deliveries (including pick-ups at the construction site):

1) Complete the attached CONTRACTOR’S DELIVERY NOTIFICATION form (Attachment “E”).

2) Fax the completed CONTRACTOR’S DELIVERY NOTIFICATION form to the security desk at 717-770-5480 and the COR at 717-770-2910 a minimum of one day prior to delivery.

SP3100-08-B-0001 H-2

3) When the delivery truck arrives at Post 4, DDSP will contact the delivery POC identified on the notification form. The POC will be required to escort the delivery truck from Post 4 to the construction site.

4) After delivery is completed, the delivery truck must be escorted from the construction site back to Post 4.

H.2.5 PHOTOGRAPHS

Cameras may be possessed and operated by authorized persons only. To obtain a Camera Authorization Pass, the COR will fax the request to Pass and ID. The contractor’s name and length of time the camera pass is required will be included in the request. Camera Passes will be issued upon approval at the time the contractor picks up his/her badge at Pass and ID. Authorization will be for prime contractor personnel only. A Camera Pass must be in possession of the person taking the photographs when challenged. Failure to maintain, or loss of this pass will be reported to the COR for action and security will be notified as necessary. Personnel found to be in the possession of photographic equipment without the proper documentation will have their equipment confiscated and returned upon their departure from the installation or other arrangements will be made.

H.2.6 THREAT CONDITIONS

Contractors are allowed to enter the installation when threat conditions are at:

ALPHA

BRAVO

CHARLIE

Contractors will not be allowed to enter the installation when the threat condition is at:

DELTA

To determine the threat level and any other restrictions concerning restrictions or delays to enter DDSP, contractors need to call the DDSP information line:

717-770-2866 (local calling area) 1-877-639-2012 (outside local area) Section DDSP – Option #2

H.2.7 CONTACTS

DDSP Security Desk - Phone: 717-770-6270 Fax: 717-770-5480

DDSP Pass and ID Section - Phone: 717-770-7111 Fax: 717-770-8146

SP3100-08-B-0001 H-3

DDSP Emergency Phone Number: 717-770-7777

DDSP Information Line: 717-770-2866

DDSP Facilities Engineering CORs

Dale Heffner - Phone: 717-770-6240 Cell Phone: 717-439-5412 Paul Johnson - Phone: 717-770-6905 Cell Phone: 717-571-7148

Fax Number: 717-770-2910

END OF SECTION H

SP3100-08-B-0001 H-4

SECTION I

CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.arnet.gov/far/ http://www.acq.osd.mil/dpap/

I.2 52.202-1 DEFINITIONS (JULY 2004)

I.3 52.203-3 GRATUITIES (APR 1984)

I.4 52.203-5 COVENANT AGAINST CONTINGENT FEES

(APR 1984)

I.5 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES

TO THE GOVERNMENT (JUL 1995)

I.6 52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

I.7 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY

OF FUNDS FOR ILLEGAL OR IMPROPER

ACTIVITY (JAN 1997)

I.8 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR

IMPROPER ACTIVITY (JAN 1997)

I.9 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE

CERTAIN FEDERAL TRANSACTIONS (SEP 2005)

I.10 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON

RECYCLED PAPER (AUG 2000)

I.11 52.204-9 PERSONAL IDENTITY VERIFICATION OF

CONTRACTOR PERSONNEL (SEP 2007)

I.12 52.209-6 PROTECTING THE GOVERNMENT’S INTEREST

WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR

DEBARMENT (SEP 2006)

I.13 52.214-26 AUDIT AND RECORDS-SEALED BIDDING (OCT

1997)

SP3100-08-B-0001 I-1

http://www.arnet.gov/far/ http://www.acq.osd.mil/dpap/

I.14 52.214-27 PRICE REDUCTION FOR DEFECTIVE COST OR

PRICING DATA-MODIFICATIONS-SEALED

BIDDING (OCT 1997)

I.15 52.214-28 SUBCONTRACTOR COST OR PRICING DATA-

MODIFICATIONS-SEALED BIDDING (OCT 1993)

I.16 52.214-29 ORDER OF PRECEDENCE – SEALED BIDDING

(JAN 1986)

I.17 52.219-4 NOTICE OF PRICE EVALUATION FOR HUBZONE

SMALL BUSINESS CONCERNS (JUL 2005)

I.18 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS

(MAY 2004)

I.19 52.219-9 Alt 1 SMALL BUSINESS SUBCONTRACTING PLAN

(SEP 2006)

ALTERNATE 1 (OCT 2001)

I.20 52.219-16 LIQUIDATED DAMAGES-SUBCONTRACTING

PLAN (JAN 1999)

I.21 52.222-1 NOTICE TO THE GOVERNMENT OF LABOR

DISPUTES (FEB 1997)

I.22 52.222-3 CONVICT LABOR (JUN 2003)

I.23 52.222-4 CONTRACT WORK HOURS AND SAFETY

STANDARDS ACT – OVERTIME

COMPRENSATION (JUL 2005)

I.24 52.222-5 DAVIS-BACON ACT—SECONDARY SITE OF THE

WORK (JUL 2005)

I.25 52.222-6 DAVIS BACON ACT (JUL 2005)

I.26 52.222-7 WITHHOLDING OF FUNDS (FEB 1988)

I.27 52.222-8 PAYROLLS AND BASIC RECORDS (FEB 1988)

I.28 52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

I.29 52.222-10 COMPLIANCE WITH COPELAND ACT

REQUIREMENTS (FEB 1988)

SP3100-08-B-0001 I-2

I.30 52.222-11 SUBCONTRACTS (LABOR STANDARDS)

(JUL 2005)

I.31 52.222-12 CONTRACT TERMINATION-DEBARMENT

(FEB 1988)

I.32 52.222-13 COMPLIANCE WITH DAVIS-BACON AND

RELATED ACT REGULATIONS (FEB 1988)

I.33 52.222-14 DISPUTES CONCERNING LABOR STANDARDS

(FEB 1988)

I.34 52.222-15 CERTIFICATION OF ELIGIBILITY (FEB 1988)

I.35 52.222-21 PROHIBITION OF SEGREGATED FACILITIES

(FEB 1999)

I.36 52.222-26 EQUAL OPPORTUNITY (MAR 2007)

I.37 52.222-27 AFFIRMATIVE ACTION COMPLIANCE

REQUIREMENTS FOR CONSTRUCTION

(FEB 1999)

I.38 52.222-35 EQUAL OPPORTUNITY FOR SPECIAL

DISABLED VETERANS, VETERANS OF THE

VIETNAM ERA, AND OTHER ELIGIBLE

VETERANS (SEP 2006)

I.39 52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH

DISABILITIES (JUN 1998)

I.40 52.222-37 EMPLOYMENT REPORTS ON SPECIAL

DISABLED VETERANS, VETERANS OF THE

VIETNAM ERA, AND OTHER ELIGIBLE

VETERANS (SEP 2006)

I.41 52.222-39 NOTIFICATION OF EMPLOYEE RIGHTS

CONCERNING PAYMENT OF UNION DUES OR

FEES (DEC 2004)

I.42 52.222-50 COMBATING TRAFFICKING IN PERSONS (Aug 2007)

I.43 52.223-3 HAZARDOUS MATERIAL IDENITIFICATION AND

MATERIAL SAFETY DATA (JAN 1997)

SP3100-08-B-0001 I-3

I.44 52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW

INFORMATION (AUG 2003)

I.45 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

I.46 52.223-11 OZONE-DEPLETING SUBSTANCES (MAY 2001)

I.47 52.223-14 TOXIC CHEMICAL RELEASE REPORTING

(AUG 2003)

I.48 52.225-9 BUY AMERICAN ACT—CONSTRUCTION

MATERIALS (JAN 2005)

I.49 52.225-13 RESTRICTIONS ON CERTAIN FOREIGN

PURCHASES (FEB 2006)

I.50 52.227-1 AUTHORIZATION AND CONSENT (JUL 1995)

I.51 52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT

AND COPYRIGHT INFRINGEMENT (MAY 1996)

I.52 52.227-4 PATENT INDEMNITY—CONSTRUCTION

CONTRACTS (APR 1984)

I.53 52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

I.54 52.228-5 INSURANCE – WORK ON A GOVERNMENT

INSTALLATION (JAN 1997)

I.55 52.228-11 PLEDGES OF ASSETS (FEB 1992)

I.56 52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS

FOR BONDS (OCT 1995)

I.57 52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999)

I.58 52.229-3 FEDERAL, STATE AND LOCAL TAXES

(APR 2003)

I.59 52.232-5 PAYMENTS UNDER FIXED-PRICE

CONSTRUCTION CONTRACTS (SEP 2002)

I.60 52.232-17 INTEREST (JUN 1996)

SP3100-08-B-0001 I-4

I.61 52.232-23 Alt I ASSIGNMENT OF CLAIMS (JAN 1986)

ALTERNATE I (APR 1984)

I.62 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION

CONTRACTS (SEP 2005)

I.63 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—

CENTRAL CONTRACTOR REGISTRATION

(OCT 2003)

I.64 52.233-1 DISPUTES (JULY 2002)

I.65 52.233-3 PROTEST AFTER AWARD (AUG 1996)

I.66 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT

CLAIM (OCT 2004)

I.67 52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

I.68 52.236-3 SITE INVESTIGATION AND CONDITIONS

AFFECTING THE WORK (APR 1984)

I.69 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

I.70 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR

(APR 1984)

I.71 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

I.72 52.236-8 OTHER CONTRACTS (APR 1984)

I.73 52.236-9 PROTECTION OF EXISTING VEGETATION,

STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

I.74 52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

I.75 52.236-11 USE AND POSSESSION PRIOR TO COMPLETION

(APR 1984)

I.76 52.236-12 CLEANING UP (APR 1984)

I.77 52.236-13 ACCIDENT PREVENTION (NOV 1991)

I.78 52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES

(APR 1984)

SP3100-08-B-0001 I-5

I.79 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS

I.80 52.236-17 LAYOUT OF WORK (APR 1984)

I.81 52.236-21 SPECIFICATIONS AND DRAWINGS FOR

CONSTRUCTION (FEB 1997)

ALTERNATE I (APR 1984)

I.82 52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

I.83 52.242-13 BANKRUPTCY (JUL 1995)

I.84 52.243-4 CHANGES (JUN 2007)

I.85 52.245-1 PROPERTY RECORDS (JUN 2007)

I.86 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

I.87 52.248-3 VALUE ENGINEERING – CONSTRUCTION

(SEP 2006)

I.88 52.249-2 Alt I TERMINATION FOR CONVENIENCE OF THE

GOVERNMENT (FIXED-PRICE)(MAY 2004) –

ALTERNATE I (SEP 1996)

I.89 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION)

I.90 52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES

I.91 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

I.92 252.203-7001 PROHIBITION ON PERSONS CONVICTED OF

DFARS FRAUD OR OTHER DEFENSE-CONTRACT-

RELATED FELONIES (DEC 2004)

I.93 252.204-7000 DISCLOSURE OF INFORMATION (DEC 1991)

DFARS

I.94 252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK

DFARS PRODUCT (APR 1992)

SP3100-08-B-0001 I-6

I.95 252.204-7004 ALTERNATE A (NOV 2003)

I.96 252.205-7000 PROVISION OF INFORMATION TO COOPERATIVE

DFARS AGREEMENT HOLDERS (DEC 1991)

I.97 252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE

DFARS OWNED OR CONTROLLED BY THE

GOVERNMENT OF A TERRORIST COUNTRY

(DEC 2006)

I.98 252.219-7003 SMALL BUSINESS SUBCONTRACTING

DFARS PLAN (DOD CONTRACTS) (APR 2007)

I.99 252.223-7001 HAZARD WARNING LABELS (DEC 1991)

DFARS

I.100 252.223-7004 DRUG-FREE WORK FORCE (SEP 1988)

I.101 252.223-7006 PROHIBITION ON STORAGE AND DISPOSAL OF

DFARS TOXIC AND HAZARDOUS MATERIALS

(APR 1993)

I.102 252.225-7012 PREFERENCE FOR CERTAIN DOMESTIC

DFARS COMMODITIES (JAN 2007)

I.103 252.225-7014 PREFERENCE FOR DOMESTIC SPECIALTY

DFARS METALS (JUN 2005)

I.104 252.225-7031 SECONDARY ARAB BOYCOTT OF ISRAEL

DFARS (JUN 2005)

I.105 252.227-7033 RIGHTS IN SHOP DRAWINGS (APR 1966)

DFARS

I.106 252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006)

DFARS

I.107 252.236-7000 MODIFICATION PROPOSALS-PRICE

DFARS BREAKDOWN (DEC 1991)

SP3100-08-B-0001 I-7

I.108 252.243-7001 PRICING OF CONTRACT MODIFICATIONS

DFARS (DEC 1991)

I.109 252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT

DFARS (MAR 1998)

I.110 252.247-7023 TRANSPORTATION OF SUPPLIES BY SEA

DFARS (MAY 2002)

I.111 52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of HQ DLA, Procurement Integrity and Pricing Branch (J-3313) and shall not be binding until so approved.

I.112 52.204-7 CENTRAL CONTRACTOR REGISTRATION (OCT 2003)

DFARS 252.204-7004 ALTERNATE A (NOV 2003) substitutes the following paragraph (a) for paragraph (a) of the FAR 52.204-7 clause:

(a) Definitions. As used in this clause--

“Central Contractor Registration (CCR) database” means the primary Government repository for contractor information required for the conduct of business with the Government.

“Commercial and Government Entity (CAGE) code” means—

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an “NCAGE code.”

“Data Universal Numbering System (DUNS) number” means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

“Data Universal Numbering System +4 (DUNS+4) number” means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional CCR records for identifying alternative Electronic Funds Transfer (EFT) accounts (see Subpart 32.11 of the Federal Acquisition Regulation) for the same parent concern.

“Registered in the CCR database” means that—

SP3100-08-B-0001 I-8

(1) The Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the CCR database;

(2) The Contractor’s CAGE code is in the CCR database; and

(3) The Government has validated all mandatory data fields and has marked the records “Active.”

(b)

(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the CCR database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS+4” followed by the DUNS or DUNS+4 number that identifies the offeror’s name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the CCR database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number—

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://www.dnb.com; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business name.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company physical street address, city, state and Zip Code.

(iv) Company mailing address, city, state and Zip Code (if separate from physical).

(v) Company telephone number.

SP3100-08-B-0001 I-9

http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/04.htm#TopOfPage

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the CCR database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the CCR database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the CCR database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the CCR database to ensure it is current, accurate and complete. Updating information in the CCR does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(g)

(1)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the CCR database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The

SP3100-08-B-0001 I-10

Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the CCR information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the CCR record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the CCR database. Information provided to the Contractor’s CCR record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the Internet at http://www.ccr.gov or by calling 1- 888-227-2423, or 269-961-5757.

I.113 52.219-28 POST AWARD SMALL BUSINESS PROGRAM

REREPRESENTATION (JUN 2007)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

SP3100-08-B-0001 I-11

http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/04.htm#TopOfPage

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract. (3) For long-term contracts—

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the exercise date specified in the contract for any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/ .

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure they reflect current status. The Contractor shall notify the contracting office by e-mail, or otherwise in writing, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

SP3100-08-B-0001 I-12

http://www.sba.gov/services/contractingopportunities/sizestandardstopics/

The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code ______________ assigned to contract number ______________.[Contractor to sign and date and insert authorized signer's name and title].

(END OF CLAUSE)

I.114 52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT

FOR EPA-DESIGNATED PRODUCTS (AUG 2000)

(a) Definitions. As used in this clause—

“Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall—

(1) Estimate the percentage of the total recovered material used in contract performance, including, if applicable, the percentage of postconsumer material content; and

(2) Submit this estimate to Defense Distribution Center, Acquisition Operations, Attn: Donna Kautz, J Avenue, Building 404, New Cumberland

PA 17070-5001.

(End of clause)

I.115 52.228-15 PERFORMANCE AND PAYMENT BONDS –

CONSTRUCTION (NOV 2006)

(a) Definitions. As used in this clause --

“Original contract price” means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

SP3100-08-B-0001 I-13

(b) Amount of required bonds. Unless the resulting contract price is $100,000 or less, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance Bonds (Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds (Standard Form 25-A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection.

(i) The Government may require additional performance and payment bond protection if the contract price is increased.

The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier’s check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the:

U.S. Department of Treasury Financial Management Service Surety Bond Branch 3700 East West Highway, Room 6F01 Hyattsville, MD 20782 Or via the internet at http://www.fms.treas.gov/c570/ .

(e) Notice of subcontractor waiver of protection (40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first

SP3100-08-B-0001 I-14

http://frwebgate.access.gpo.gov/cgi-bin/leaving.cgi?from=leavingFR.html&log=linklog&to=http://www.fms.treas.gov/c570/ furnished labor or material for use in the performance of the contract.

I.116 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR

(Apr 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least (20) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

I.117 252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS

DFARS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall --

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general –

(1) Large scale drawings shall govern small scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work.

The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to all specifications and drawings identified in each task order.

SP3100-08-B-0001 I-15

I.118 52.228-9000 INSURANCE (FEB 2005)

DLAD

The Contractor shall, at its own expense, provide and maintain during the entire period of any resulting contract, including any extensions granted by contract modification, at least the kinds and minimum amounts of insurance noted here:

Workers’ Compensation and Employer’s Liability - $100,000 (except in states with exclusive or monopolistic funds that do not permit workers’ compensation to be written by private carriers.)

General Liability- $500,000 per occurrence Automobile Liability – Property damage $20,000 per occurrence, Bodily injury $200,000 per person and $500,000 per occurrence.

When requested by the Contracting Officer, the Contractor shall provide a copy of all subcontractors’ proofs of required insurance no later than five (5) days before each subcontractor commences work on the Government installation.

END OF SECTION I

SP3100-08-B-0001 I-16

SECTION J

LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

J.1 This solicitation package is comprised of the following documents:

a. Specifications for Repair and Upgrade Restrooms Building 2001 EDC – 305 pages

b. Drawings for Repair and Upgrade Restrooms Building 2001 EDC Drawing Numbers: Project No. 3558 sheets 3558.1-3558-57 57 pages

c. Form Attachment “A” – New Personnel Notification Form – 1 page

d. Form Attachment “B” – Short Form – 1 page

e. Form Attachment “C” – Long Form - 1 page

f. Form Attachment “D” – Badge Renewal Form – 1 page

g. Form Attachment “E” – Contractor Delivery Notification Form – 1 page

h. General Wage Decision Number PA070010, Modification Number

8 dated 08/31/2007 – 9 pages

i. Standard Form 24 – Bid Bond – 2 pages

j. Standard Form 25 – Performance Bond – 2 pages

k. Standard Form 25-A – Payment Bond – 2 pages

l. Sample Subcontracting Plan – 13 pages

END OF SECTION J

SP3100-08-B-0001 J-1

SECTION K

REPRESENTATIONS, CERTIFICATIONS, AND OTHER

STATEMENTS OF BIDDERS

K.1 52.203-11 CERTIFICATION AND DISCLOSURE REGARDING

FAR PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (SEP 2007)

K.2 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN

FAR FEDERAL TRANSACTIONS (SEP 2007)

K.3 252.209-7001 DISCLOSURE OF OWNERSHIP OR CONTROL BY THE

DFARS GOVERNMENT OF A TERRORIST COUNTRY

(OCT 2006)

K.4 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS

(JAN 2006)

(a)

(1) The North American Industry classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $31,000,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (c) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (c) of this provision instead of completing the corresponding individual representations and certification in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (c) applies.

SP3100-08-B-0001 K-1

[ ] (ii) Paragraph (c) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website at http://orca.bpn.gov . After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date].

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on ORCA.

(End of Provision)

K.5 52.223-4 RECOVERED MATERIAL CERTIFICATION (OCT 1997)

As required by the Resource Conservation and Recovery Act of 1976

(42 U.S.C. 6962(c)(3)(A)(i)), the offeror certifies, by signing this offer, that the percentage of recovered materials to be used in the performance of the contract will be at least the amount required by the applicable contract specifications.

(End of provision)

K.6 252.247-7022 REPRESENTATION OF EXTENT OF

DFARS TRANSPORTATION BY SEA (AUG 1992)

(a) The Offeror shall indicate by checking the appropriate blank in paragraph (b) of this provision whether transportation of supplies by sea is anticipated under the resultant contract. The term supplies is defined in the Transportation of Supplies by Sea clause of this solicitation.

(b) Representation. The Offeror represents that it:

SP3100-08-B-0001 K-2

http://orca.bpn.gov/

____ (1) Does anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

____ (2) Does not anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

(c) Any contract resulting from this solicitation will include the Transportation of Supplies by Sea clause. If the Offeror represents that it will not use ocean transportation, the resulting contract will also include the Defense FAR Supplement clause at 252.247-7024, Notification of Transportation of Supplies by Sea.

(End of provision)

K.7 52.233-9001 DISPUTES: AGREEMENT TO USE ALTERNATIVE

DLAD DISPUTE RESOLUTION (JUN 2001)

(a) The parties agree to negotiate with each other to try to resolve any disputes that may arise. If unassisted negotiations are unsuccessful, the parties will use alternative dispute resolution (ADR) techniques to try to resolve the dispute.

Litigation will only be considered as a last resort when ADR is unsuccessful or has been documented by the party rejecting ADR to be inappropriate for resolving the dispute.

(b) Before either party determines ADR inappropriate, that party must discuss the use of ADR with the other party. The documentation rejecting ADR must be signed by an official authorized to bind the contractor (see FAR 52.233-1), or, for the Agency, by the contracting officer, and approved at a level above the contracting officer after consultation with the ADR Specialist and with legal counsel ( see DLA Directive 5145.1). Contractor personnel are also encouraged to include the ADR Specialist in their discussions with the contracting officer before determining ADR to be inappropriate.

(c) If you wish to opt out of this clause, check here [ ]. Alternate wording may be negotiated with the contracting officer.

END OF SECTION K

SP3100-08-B-0001 K-3

http://160.147.217.67/SR2.htm

SECTION L

INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

L.1 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY

REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

L.2 52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 1989)

L.3 52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

L.4 52.214-5 SUBMISSION OF BIDS (MAR 1997)

L.5 52.214-6 EXPLANATION TO PROSEPCTIVE BIDDERS (APR 1984)

L.6 52.214-7 LATE SUBMISSIONS, MODIFICATION AND

WITHDRAWALS OF BIDS (NOV 1999)

L.7 52.214-12 PREPARATION OF BIDS (APR 1984)

L.8 52.214-18 PREPARATION OF BIDS – CONSTRUCTION (APR 1984)

L.9 252.225-7031 SECONDARY ARAB BOYCOTT OF ISRAEL

DFARS (JUN 2005)

L.10 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government…