SOW - Att 06 - AE _ CPM Schedule - Residential Recovery Prg - Honolulu.pdf
PDF 64 KB Posted
- Solicitation number
- 36C77624R0017
About this file
This document outlines requirements for an Architect/Engineer (A/E) Critical Path Method (CPM) schedule for the Expand Renovate Center Recovery Program - Honolulu project. The A/E must designate a representative responsible for developing the CPM schedule and coordinating with the Project Manager and Contracting Officer. The A/E is also required to engage a qualified CPM consultant to create the schedule using Precedence Diagramming Method techniques. Within 10 days of award, the A/E must submit the name of the CPM Developer, the software to be used, and qualifications demonstrating the developer's ability to meet the requirements. The related federal contract opportunity is for design services for the project, issued by the Department of Veterans Affairs Technology Acquisition Center under solicitation number 36C77624R0017.
View the file
Other files
Show all 14
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
03-01-20
01 32 16.01 - 1
SECTION 01 32 16. 01
ARCHITECTURAL AND ENGINEERING CPM SCHEDULES
PART 1- GENERAL
1.1 DESCRIPTION:
The Architect/Engineer of Record (A/E) shall develop a Critical Path
Method (CPM Schedule) plan and schedule demonstrating fulfillment of the contract requirements as designated in VA PG 18-15, shall keep the
CPM up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract. Conventional Critical Path Method (CPM) Precedence
Diagramming Method (PDM) technique will be utilized to satisfy both time and cost applications. All schedule data and reports required under this specification section shall be based upon regular total float, not relative total float schedules.
1.2 A/E 'S REPRESENTATIVE:
A. The A/E shall designate an authorized representative in the firm who will be responsible for the preparation of the CPM Schedule, review and report progress of the project with and to the Project Manager and the
Contracting Officer.
B. The A/E's representative shall have direct project control and complete authority to act on behalf of the A/E in fulfilling the requirements of this specification section and such authority shall not be interrupted throughout the duration of the project.
1.3 A/E 'S SCHEDULE PREPARATION:
A. To prepare the CPM Schedule, and subsequent periodic updates, which reflects the A/E's project plan, the A/E shall either designate a qualified individual within their firm or engage an independent CPM consultant (CPM Developer) who is skilled in the time and cost application of scheduling using (PDM) network techniques for Design projects, the cost of which is included in the A/E's bid.
B. Within 10 calendar days after award of the contract, the A/E shall submit to the Contracting Officer:
1. The name of the CPM Developer.
2. The Computer Software to be utilized.
3. Sufficient information to show that the CPM Developer has the qualifications to meet the requirements specified in the preceding paragraph.
File details come from the government source that posted it. Updated .