Solicitation W912WJ21B0005.pdf

PLANS AND SPECIFICATIONS TITLED: Electrical Upgrades, Littleville Lake Dam, Huntington, MA Dated March 2021.

REPRESENTATIONS AND CERTIFICATIONS: Section 00600; CONTRACT CLAUSES: Section 00700; SPECIAL CONTRACT REQUIREMENTS:

Section 00800.

NOTE TO BIDDERS: Please pay special attention to Sections: Section 00100 (Instructions to bidders) Section 00600 (Representations &

Certif ications) and Contract Clauses 52.204-7 (System for Aw ard Management (SAM) and 252.204-7004 Alt A (SAM). All offerors must complete the annual representations and certif ication electronically via the SAM w ebsite at https://w w w .sam.gov/portal/public/SAM/ or by telephone at 1-866-606-8220. Please ensure your f irm is registered in the SAM database prior to submitting a bid.

The applicable NAICS Code and Size Standard for this procurement are as follow s: NAICS Code: 238210 Size Standard: $16,500,000.00.

This Solicitation is 100% set-aside for: Small Business

X

SARA J TORRES 978-318-8478

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

02-Apr-2021

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________240 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________05 May 2021 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA ROAD

CONCORD MA 01742-2751

W912WJ

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 978-318-8000 TEL: FAX:

W912WJ21B0005 53

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912WJ21B0005

Section 00100 - Bidding Schedule/Instructions to Bidders

BID SCHEDULE

BIDDING SCHEDULE

Refer to Section 01 22 00 Measurement And Payment.

Item

No.

Description

Quantity

Unit

Unit Price Amount

All Work

Job

Job

TOTAL AMOUNT $

Note 1: Bidders must bid all items. The work will be awarded as a whole to one bidder.

Offers will be evaluated and the low bidder determined by the Total Estimated Amount for Line Item 0001.

Note 2: All work shall be completed within the time period specified in Section 0080 00 Special

Contract Requirements, Subpart Commencement, Prosecution And Completion Of Work (Apr

1984) Far 52.211-10.

Note 3: Identify a point of contact e-mail for all correspondence related to this bid: @

VIRTUAL BID OPENING

WHAT - Bids shall be submitted electronically, as described. The bid shall not contain classified data.

The use of hyperlinks in bids is prohibited.

NOTE: The only authorized transmission method for bids in response to this solicitation is electronically via SAFE online submission. NO OTHER TRANSMISSION METHODS (E-MAIL, FACSIMILE, REGULAR MAIL, HAND CARRIED, ETC.) WILL BE ACCEPTED.

WHEN - Bids must be submitted not later than one (1) hour before the time designated for bid opening.

Bids submitted after the bid submission time will be considered late bids.

THE BID SUBMISSION TIME IS 1:00 PM Eastern Time.

Bids must be received by the Government by the date/time specified in the solicitation.

HOW - Bidders shall electronically send their bids using the following link:

https://safe.apps.mil/

WHO-The SAFE site will require contacts for bid submission to be provided. All requests for information and the bid submission must be sent to BOTH of the below contacts to ensure timely receipt of bids. Please use the following contact information to submit bids:

Contract Specialist Sara J. Torres at Sara.J.Torres@usace.army.mil

Contracting Officer Erin E. Bradly at Erin.E.Bradley@usace.army.mil

BIDDERS MUST REQUEST AN UPLOAD CODE: Bidders must e-mail the Contract Specialist and

Contracting Officer no later than five (5) working days prior to the bid opening date to receive a request code which will allow for file uploads via the SAFE site. Bidders that fail to request a code at least five (5) working days before bid opening date may not be able to receive a request code in time to upload their bids.

SUBMISSION FORMAT: Submission shall be in Adobe PDF format. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, recommend that you combine or

ZIP your files before uploading to the SAFE site. Bidders may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

BID GUARANTEE: This solicitation requires submission of a bid guarantee in accordance with FAR

52.228-1. Electronic bid submissions must include a scanned copy of the original bid guarantee. The original bid guarantee with “wet” signature and raised seal (if applicable) must be mailed or delivered to the below and received by the bid opening time and date:

Bid Opening Official – Contracting Division

U.S. Army Corps of Engineers 696

Virginia Road

Concord, MA 01742

Minor discrepancies in receipt of the original bid guarantee due to COVID-19 related impacts may be waived solely at the discretion of the Contracting Officer. For example, there are guards who are stationed at the 696

Virginia Road location who can take receipt of guarantees. If no guard is available to sign for packages at the time of delivery and a package is not delivered, the Contracting Officer may allow for delayed delivery of the original mailto:Sara.J.Torres@usace.army.mil mailto:Erin.E.Bradley@usace.army.mil bid guarantee. A scanned copy of the original bid guarantee must be included in the electronic bid submission for the bid to be considered responsive.

FILE DESCRIPTION: Include a “File Description” for each file you upload. The “File Description” will be included in the e-mail notice to each of the recipients you choose to have access your file(s). NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

1. Once at the SAFE website, select the “Drop-off” icon. This allows users without a

Common Access Card (CAC, an ID issued to certain Government users), or users whose computer is not configured to read a CAC the option to access the SAFE site as a guest.

2. After selecting the “Click Here” link, you will be prompted to add your personal information, file information, recipient (Government points of contact) information and e-mail settings.

3. When completing your file information, you will be required to enter the e-mail addresses for all recipients. For this solicitation, the recipients are the Contract Specialist and the Contracting Officer, listed above. Although the e-mail address of the Government employee who initiated the request code will be automatically entered, this address may not be correct. The Bidder must enter and add the email addresses for both the Contracting Officer and Specialist listed above to the Recipient List. The

Bidder can enter an additional e-mail address if desired. After entering the e-mail address, click the

ADD button to add the e-mail to the “Recipients List” for your response. When your bid is submitted, a notification will be sent to the selected recipients.

NOTE: Do NOT send the SAFE site packages to group e-mail accounts.

Even if you successfully upload your bid to the SAFE site, notification will not be sent to the Government recipients until you verify your e-mail address. Entering an incorrect e-mail may result in the rejection of your submission for lateness. A Bidder can confirm proper submission by the ‘Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Bidders will have more success utilizing any particular browser.

TIMELINES OF BIDS:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the SAFE website. For bids larger than the 2GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids. Bidders are responsible for ensuring that bids are submitted so as to reach the designated recipient. Bidders are responsible for allowing sufficient time for the bid to be received in accordance with the instructions provided.

BID OPENING

Bids will be opened one hour after the time for bid submission noted above. This one hour delay is necessary to allow for technical delays. The Bid Opening Official or Contract Specialist may open electronic documents before the bid opening to prepare for the bid opening, but will not record or communicate bid prices with any other individual until the bid opening. No Government officials will open electronic documents until the independent government estimate is finalized and received by the Bid Opening Official.

THE BID OPENING TIME IS 2:00 PM EASTERN TIME

The bid opening will be conducted via public conference call. Bidders and members of the public may use the below information to access the conference call:

Call In info:

+1-844-800-2712 US Toll Free

+1-669-234-1177 US Toll

Access code: 199 140 7476

During the bid opening, the Bid Opening Official will read the bid totals in the order received electronically. The

Bid Opening Official will then read the total amount of the independent government estimate and announce the apparent low bidder. If requested, the Bid Opening Official may read the line item prices of the apparent low bidder. The Contract Specialist will record the bid opening results, which will be posted to www.beta.SAM.gov as quickly as practicable following the bid opening.

In accordance with FAR 14.402-1(c), interested persons may examine the bids after the bid opening. Interested persons may contact the Contract Specialist identified above following the bid opening to request an electronic copy of the bid(s). Please be considerate of limited Government resources and request bid copies only as necessary.

To preserve conference line stability, bidders are asked to limit the number of individual calls to the conference line to the minimum needed for participation. The bid opening will proceed as scheduled even if individual bidders or members of the public are not able to access the telephone line at the bid opening time. Any interested party may access the results of the bid opening on www.beta.SAM.gov shortly after the bid opening.

ATOPSEC

-Suspicious Activity Reporting Training

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT

5 calendar days after the completion of the training.

-Pre-screen candidates using E-Verify Program.

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

http://www.beta.sam.gov/

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018

52.204-16 Commercial and Government Entity Code Reporting AUG 2020

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-22 Alternative Line Item Proposal JAN 2017

52.214-3 Amendments To Invitations For Bids DEC 2016

52.214-4 False Statements In Bids APR 1984

52.214-6 Explanation To Prospective Bidders APR 1984

52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999

52.214-18 Preparation of Bids-Construction APR 1984

52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting

Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

5.9% Huntington, MA 6.9% Nationwide

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract

Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract

Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Huntington, MA, Hampsire County.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause

52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the

Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph

(b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR

52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3M, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Contracting Officer

Contracting Division

696 Virginia Road

Concord, MA 01742

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

Date: Monday, April 12th, 2021 at 10:00am Eastern Time

(c) Participants will meet at—

The Project Office

32 Goss Hill Road

Huntington, MA 01050

Please Note that Google has it come up as 39 instead of 32.

Important Note:

1. Companies interested in attending the site visit shall only send up to two individuals to the site.

2. Face masks must be worn at all times while on site. No exceptions. Social distancing guidelines shall be maintained.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/content/regulations

INQUIRIES

Telephone inquiries relating to this solicitation should be directed as follows:

New England District, Corps of Engineers

Procurement of Plans and Specifications, Prospective Bidders List, Bid Results, and Award Information ………………. 978-318-8478

Technical Inquiries on Plans and

Specifications ………………………… 978-318-8478

MAGNITUDE OF PROJECT

The estimated cost of the work is between $250,000 and $500,000 https://www.acquisition.gov/content/regulations

Section 00600 - Representations & Certifications

VETERANS INFO

Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222‐38, FAR Clause 52.222‐35, FAR Clause 52.22237, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no setaside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx

Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/

Department of Veterans Affairs–VOW to Hire Heros Act http://benefits.va.gov/vow/

Army Wounded Warrior Program – http://wtc.army.mil/modules/employers/index.html

U.S. Chamber of Commerce Foundation–Hiring Our Heros http://www.hiringourheroes.org/

Guide to Hiring Veterans – Reference Material http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_-

_guide_to_hiring_veterans_0.pdf

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-13 Violation of Arms Control Treaties or Agreements --

Certification.

JUL 2020

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $16,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by http://www.fedshirevets.gov/index.aspx http://www.dol.gov/vets/ http://benefits.va.gov/vow/ http://wtc.army.mil/modules/employers/index.html http://www.hiringourheroes.org/ http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_-%20_guide_to_hiring_veterans_0.pdf http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_-%20_guide_to_hiring_veterans_0.pdf checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or

Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at

52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR

4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change https://www.sam.gov/

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

Section 00700 - Contract Clauses

52.202-1 Definitions JUN 2020

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020

52.203-7 Anti-Kickback Procedures JUN 2020

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

JUN 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018

52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other

Covered Entities.

JUL 2018

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

JUN 2020

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2020-O0008).

MAR 2020

52.219-8 Utilization of Small Business Concerns OCT 2018

52.219-14 Limitations On Subcontracting MAR 2020

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records AUG 2018

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 https://www.sam.gov/

52.222-15 Certification of Eligibility MAY 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-37 Employment Reports on Veterans JUN 2020

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons OCT 2020

52.222-54 Employment Eligibility Verification OCT 2015

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.223-4 Recovered Material Certification MAY 2008

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-10 Waste Reduction Program MAY 2011

52.223-15 Energy Efficiency in Energy-Consuming Products MAY 2020

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.223-20 Aerosols JUN 2016

52.223-22 Public Disclosure of Greenhouse Gas Emissions and

Reduction Goals -- Representation.

DEC 2016

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent JUN 2020

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.227-17 Rights In Data-Special Works DEC 2007

52.228-11 Pledges Of Assets AUG 2018

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-17 Interest MAY 2014

52.232-23 Assignment Of Claims MAY 2014

52.232-27 Prompt Payment for Construction Contracts JAN 2017

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items OCT 2020

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2020

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements NOV 2020

252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2020

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

MAY 2019

252.215-7013 Supplies and Services Provided by Nontraditional Defense

Contractors.

JAN 2018

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7012 Preference For Certain Domestic Commodities DEC 2017

252.225-7048 Export-Controlled Items JUN 2013

252.227-7033 Rights in Shop Drawings APR 1966

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items OCT 2020

252.247-7023 Transportation of Supplies by Sea FEB 2019

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (AUG 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in the provision at 52.204-26, Covered Telecommunications Equipment or Services--Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause

52.204-25,…