Solicitation W912HZ25Q0021__Sample Analyses.pdf

PR W2R2 USA ENGR R AND D CTR

MITCHELL WILBANKS

3909 HALLS FERRY RD

VICKSBURG MS 39180-6133

TEL: (601) 634-7242 FAX:

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912HZ25Q0021 15-May-2025 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ [ ] IS X[ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

ERDC CONTRACTING OFFICE

3909 HALLS FERRY ROAD

VICKSBURG MS 39180-6199

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

16-Jun-2025(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

CRYSTAL E NORTH

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912HZ25Q0021

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Task 1

FFP

Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team

Task 1: Molecular signaling analyses using peptide/protein measurement via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

See Section C, PWS for additional information.

FOB: Destination

PSC CD: AJ12

NET AMT

0002 1 Job OPTION Option Task 2

FFP

Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team

Option Task 2: Phage particle measurement using TEM/SEM analyses for 10 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

See Section C, PWS for additional information.

0003 1 Job OPTION Option Task 3

FFP

Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team

Option Task 3: Cyanobacteria inhibition using peptide/protein measurement using via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

See Section C, PWS for additional information.

0004 1 Job OPTION Option Task 4

FFP

Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team

Option Task 4: Trehalose measurement via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

See Section C, PWS for additional information.

TOTALS

Totals (CLIN 0001-0004) $____________

YES NO

Are you available to start work by July 1, 2025 _____ _____

If you are not available to start work by July 1, 2025, when are you available to start work? __________________

Section C - Descriptions and Specifications

PERFORMANCE WORK STATEMENT

PERFORMANCE WORK STATEMENT (PWS)

Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team

Part 1 General Information

1. General: This is a non-personal service(s) contract under which the personnel rendering the service(s) are not subject, either by the contract’s terms or by the manner of its administration, to the supervision and control usually prevailing in relationships between the Government and its employees.

1.1 Description of Services/Introduction: This is a non-personal service(s) contract to perform different types of sample analyses for current research conducted by the US Army Engineer Research and Development Center (ERDC) Genomics and Systems Biology (GSB) Team.

1.2 Background: The GSB Team has 3 primary business areas: genomics and next generation toxicology;

bioengineering, synthetic and bio-inspired processes/products and quantitative and systems biology. This diverse portfolio requires the utilization of numerous instrument types and sample type expertise, much of which, is not currently available at ERDC.

1.3 Scope: The Contractor shall provide non-personal service(s). The Contractor shall provide all personnel, equipment, facilities, supervision, and other items necessary to perform services as described in the PWS and associated contract documents, except for those items specifically mentioned in the PWS and associated contract documents. The Contractor shall perform to the standards and acceptable quality levels identified in this PWS and associated contract documents.

1.4 Objectives: The contractor shall perform molecular signaling analyses using peptide/protein measurement via HPLC, LC-MS analyses which will allow researchers to determine the best method to produce optimal signaling within a colony and will support model development; phage particle measurement using Transmission Electron Microscopy/Scanning Electron Microscopy (TEM/SEM) analyses which will be used to describe and characterize phage isolates; cyanobacteria inhibition using peptide/protein measurement using via HPLC, LC-MS analyses to determine effectiveness of plasmids containing genes to alter circadian rhythm of cyanobacteria; and trehalose measurement via High Performance Liquid Chromatography (HPLC) and/or Liquid Chromatography-Mass Spectrometry (LC-MS) analyses to determine the impact on cell survival during desicaation. Deliverables include monthly progress reports, methods used, and results (data).

The data obtained from these analyses will allow researchers to determine the best method to produce optimal signaling within a colony and determine optimal parameters to support model development.

1.5 General Information:

1.5.1 The Contractor shall inform the COR of issues or potential issues that might affect the performance within five business days of identifying those issues. Verbal reports shall be followed up by written reports within 10 business days.

1.5.2 Quality Assurance: The Government will evaluate the Contractor’s performance under this contract in accordance with the Quality Assurance Surveillance Plan (QASP). This plan is primarily focused on what the Government must do to ensure that the Contractor has performed in accordance with the performance standards. It defines how the performance standards will be applied, the frequency of surveillance, and the acceptable quality levels (performance thresholds).

1.5.3 Recognized Holidays: The following provides information on recognized holidays for the purpose of the PWS. If submittal of any documentation (e.g. deliverables, submittals, etc.) deadlines fall on a holiday, the closest work day prior to the holiday will apply as the deadline for submittal.

1.5.3.1 U.S. Holidays: Work may be performed on U.S. federally recognized holidays occurring during the normal workweek unless otherwise directed by the Contracting Officer. When a U.S. holiday occurs on a Saturday or a Sunday, the holiday is observed on the preceding Friday or following Monday, respectively.

New Year’s Day January 1st M. L. King Memorial Day 3rd Monday in Jan Presidents Day 3rd Monday in February Memorial Day last Monday in May Juneteenth June 19th Independence Day July 4th Labor Day 1st Monday in September Columbus Day 2nd Monday in October Veteran’s Day November 11th Thanksgiving Day 4th Thursday in November Christmas Day December 25th

1.5.4 Operating Hours: The Government facility office hours, facility operating hours, and the Contractor support hour requirements often coincide, however, they may differ. Please refer to the following.

1.5.4.1 Government Facility Office Hours: The Government facility office hours are 0700 - 1900 except U.S.

Holidays identified in paragraph 1.5.3.1 above or when the Government facility is closed due to local or national emergencies, administrative closings, or similar Government directed facility closings.

1.5.4.2 Government Facility Operating Hours: The Government facility operating hours occur between the hours of 0700 – 1900 Monday – Friday. The Government facility is closed for operations during the recognized U.S.

Holidays identified in paragraph 1.5.3.1 above. The Government facility may close due to local or national emergencies, administrative closings, or similar Government directed facility closings and will be communicated by the Contracting Officer to the Contractor.

1.5.4.3 Contractor Support Hours: The Contractor shall provide support between the hours of 0800 – 1600 Monday through Friday. The facility may be closed during local or national emergencies, administrative closings, or similar Government directed facility closings. The Contractor shall maintain an adequate workforce at all times, for the uninterrupted performance of all tasks defined within this PWS when the Government facility is not closed for the above reasons. When hiring personnel, the Contractor shall keep in mind that the stability and continuity of the workforce is essential.

1.5.5 Place of Performance: The work cover under this contract will be completed at the contractor’s laboratories.

1.6 Security Requirements: The following information is provided on security related matters.

1.6.1 General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor (“Contractor”) and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as “RAMs”), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

1.6.2 Contracts requiring armed security guards: All contract personnel performing contract security guard duties shall comply with the Individual Reliability Program in accordance with AR 190-56 (The Army Civilian Police and Security Guard Program), as well as applicable installation, facility and area commander installation/facility policies and procedures regarding storing weapons and ammunition in accordance with AR 190- 11 (Physical Security of Arms Ammunition, and Explosives).

1.7 Post Award Conference/Periodic Progress Meetings: The Contractor shall attend any post award conference convened by the contracting activity or contract administration office in accordance with FAR Subpart 42.5. The Contracting Officer, COR, and other Government personnel, as appropriate, may meet periodically with the Contractor to review the Contractor's performance. At these meetings the Contracting Officer will apprise the Contractor of how the Government views the Contractor's performance and the Contractor shall apprise the Government of problems, if any, being experienced. Appropriate action shall be taken to resolve outstanding issues.

These meetings shall be at no additional cost to the Government.

1.7.1 The Contractor shall attend, participate in, and furnish input to scheduled and unscheduled meetings, conferences, and briefings that relate to the functions and services herein as required by the Government to provide effective communication and impart necessary information. The Contract Manager or designated representative shall attend meetings as requested by the Government. Meeting attendees shall at times include Contractor managerial, supervisory, and other personnel knowledgeable of the subject matter. Meetings may start or end outside of regular duty hours.

1.8 Contracting Officer’s Representative (COR): As determined by the Contracting Officer, a COR will be appointed and identified by letter of designation, a copy of which will be provided to the Contractor by the Contracting Officer. The designation letter states the responsibilities and limitations of the COR, especially with regard to changes in cost or price, estimates, or changes in delivery dates. The COR is not authorized to change any of the terms and conditions of the resulting order. The COR monitors all technical aspects of the contract and assists in contract administration. The COR is not authorized to obligate the Government. If the work is not written in the contract, the COR is not authorized to request new work. The COR is authorized to perform the following functions:

assure that the Contractor performs the technical requirements of the contract, perform inspections necessary in connection with contract performance, maintain written and oral communications with the Contractor concerning technical aspects of the contract, issue written interpretations of technical requirements, including Government drawings, designs, specifications, monitor Contractor's performance and notifies both the Contracting Officer and Contractor of any deficiencies, coordinate availability of Government property, and coordinate site entry of Contractor personnel.

1.9 Identification of Contractor Employees: All Contractor personnel attending meetings, answering Government telephones, and working in other situations where their Contractor status is not obvious to third parties must identify themselves, to include proper marking of signature blocks in correspondence, to avoid creating an impression in the minds of members of the public that they are Government officials. The Contractor shall ensure that all documents or reports, produced by Contractors are suitably marked as Contractor products or that Contractor participation is appropriately disclosed.

1.10 Contractor Travel: Travel is not required for this contract action.

1.11 Data Rights: Government has unlimited rights to all documents and materials produced under this contract.

All documents and materials, to include the source codes of software, produced under this contract shall be Government owned and are the property of the Government with all rights and privileges of ownership and copyright belonging exclusively to the Government. These documents and materials may not be used or sold by the Contractor without written permission from the Contracting Officer. All materials supplied to the Government shall be the sole property of the Government and may not be used for any other purpose. This right does not abrogate any other Government rights.

1.12 Non-Disclosure Requirements: Performance under this contract may require the Contractor to access data and information proprietary to a Government agency, another Government Contractor, or of such nature that its dissemination or use other than as specified in this work statement would be adverse to the interests of the Government or others. The Contractor and Contractor personnel, shall not divulge or release data or information developed, or obtained under performance of this PWS, except to authorized Government personnel or upon written approval of the Contracting Officer. The Contractor shall not use, disclose, or reproduce proprietary data, which bears a restrictive legend, other than as specified in this PWS. All documentation showing individual names or other personal information shall be controlled and protected under the provisions of the Privacy Act of 1974, Public Law 93-579, 5 United States Code (U.S.C.) Section 552a.

1.13 Protection of Government and Contract Information: Per Public Use Notice of Limitations stated by Defense imagery Management operations Center and contained at www.dimoc.mil/resources/limitations/ , the Contractor shall not cite any information (e.g., contract information, pictures, locations, etc.) obtained through this contract on any hard copy or digital marketing tools to include its company website.

1.14 Safety: The following provides information pertaining to Safety and Accident Prevention:

1.14.1 Safety Laws and Regulations: The Contractor shall comply with FAR 52.236-13, Accident Prevention (November 1991), the references contained therein (e.g. U.S. Army Corps of Engineers Safety and Health Requirements Manual (EM 385-1-1))

The requirements under FAR 52.236-13 and specifically of the EM 385-1-1 include, but are not limited to the following:

PART 2

GOVERNMENT PROPERTY (GP) AND SERVICES

2. Government Property and Services

2.1 Materials: The Government will provide samples and sample information required for the Contractor to perform the Task(s) as outlined in the PWS.

PART 3

CONTRACTOR FURNISHED ITEMS AND SERVICES

3. Contractor Furnished Property and Services

3.1 General: The Contractor shall furnish all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items necessary to perform services as described in the PWS and associated contract documents, except for those items specified in Part 2 Government Property and Services.

3.2 Materials: The Contractor shall provide specific items as listed in each task of the PWS along with deliverables as listed in the PWS. Other items to be provided by the Contractor include Personal Protective Equipment, lab supplies, and office supplies needed in the performance of this contract.

PART 4

SPECIFIC TASKS

4.1 Basic Services: The Contractor shall provide services for completion of the listed task(s) and optional task(s) as listed below.

4.2 Tasks: Tasks consist of the following:

Task 1: Molecular signaling analyses using peptide/protein measurement via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity.

Samples may be disposed after 3 months of analyses.

Deliverables

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a technical report detailing methods and results/findings.

Option Task 2: Phage particle measurement using TEM/SEM analyses for 10 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

Deliverables

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a technical report detailing methods and results/findings.

Option, Task 3: Cyanobacteria inhibition using peptide/protein measurement using via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity.

Samples may be disposed after 3 months of analyses.

Deliverables

Monthly progress reports describing methods and results.

Option Task 4: Trehalose measurement via HPLC, LC-MS analyses for 30 samples. Samples shall be analyzed within 1 month of receipt in order to ensure downstream data integrity. Samples may be disposed after 3 months of analyses.

Monthly progress reports describing methods and results.

PART 5

ATTACHMENT AND TECHNICAL EXHIBIT LISTING

5. Attachment and Technical Exhibit List

5.1 Technical Exhibit A – Performance Requirements Summary

TECHNICAL EXHIBIT A

Performance Requirements Summary (PRS)

PERFORMANCE OBJECTIVE STANDARD PERFORMANCE

THRESHOLD

ACCEPTABLE

QUALITY

LEVELS (AQLs)

METHOD OF

SURVEILLANCE

Task 1 - Molecular signaling analyses using peptide/protein measurement via HPLC, LC-MS analyses for 30 samples.

Deliverables

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a technical report detailing methods and results/findings.

Standards:

Successful demonstration of deliverables for the task.

The contractor shall provide a technical report detailing methods and

AQL: All data provided will be defensible for peer review and indicate a successful experiment.

Delays shall be reported as soon as possible.

Approval by the technical POC or COR is needed for delayed reports.

Report Review

What: A monthly status report and upon completion of the task a technical report documenting methods and results.

Who: Technical POC and COR will inspect deliverables.

Standard(s): Inspection applies to all standards.

Option Task 2: Phage particle measurement using TEM/SEM analyses for 10 samples.

Deliverables

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a demonstration of deliverables for the task.

The contractor shall provide a technical report detailing defensible for peer review and indicate a successful experiment.

Delays shall be reported as soon as possible.

Approval by the technical POC or COR is needed for delayed reports.

Report Review

What: A monthly status report and upon completion of the task a technical deliverables.

Standard(s): Inspection applies to all standards.

Option Task 3 - Cyanobacteria inhibition using peptide/protein measurement using via HPLC, LC-MS analyses for 30 samples.

Deliverables

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a demonstration of deliverables for the task.

The contractor shall provide a technical report detailing defensible for peer review and indicate a successful experiment.

Delays shall be reported as soon as possible.

Approval by the technical POC or

Report Review

What: A monthly status report and upon completion of the task a technical deliverables.

Standard(s): Inspection applies to all standards.

COR is needed for delayed reports.

Option Task 4 - Trehalose measurement via HPLC, LC-MS analyses for 30 samples.

Monthly progress reports describing methods and results.

Upon completion of each task, the contractor shall provide a demonstration of deliverables for the task.

The contractor shall provide a technical report detailing defensible for peer review and indicate a successful experiment.

Delays shall be reported as soon as possible.

Approval by the technical POC or COR is needed for delayed reports.

Report Review

What: A monthly status report and upon completion of the task a technical deliverables.

Standard(s): Inspection applies to all standards.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 01-JUL-2026 TO

30-JUN-2027

N/A PR W2R2 USA ENGR R AND D CTR

MITCHELL WILBANKS

3909 HALLS FERRY RD

VICKSBURG MS 39180-6133

(601) 634-7242

W81EWF

0002 POP 01-JUL-2026 TO

30-JUN-2027

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-JUL-2026 TO

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 01-JUL-2026 TO

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989

Section G - Contract Administration Data

ADMINISTRATIVE DATA

ADMINISTRATIVE DATA:

Reference Solicitation W912HZ25Q0021 for Instrumental Sample Analyses Conducted for the Genomics and Systems Biology Team.

CONTRACTOR POINTS OF CONTACT:

TBD

Phone: TBD E-Mail: TBD

CONTRACTING OFFICER’S REPRESENTATIVE:

TBD

Phone: TBD E-Mail: TBD

GOVERNMENT CONTRACTING POINTS OF CONTACTs:

Contract Specialist Contracting Officer Ms. Crystal North Ms. Sonia Boyd Phone: N/A Phone: 601-751-0822 E-mail: Crystal.E.North@usace.army.mil E-mail: Sonia.J.Boyd@usace.army.mil

INVOICE INSTRUCTIONS:

(1) A proper invoice must be in accordance with FAR 32.905 (b)(1), or invoice instructions contained elsewhere in this document.

(2) Submit invoice via email to: CEFC.CEFC-payments@usace.army.mil

To avoid delay in payment a copy must also be sent to TBD

(3) If more than one invoice is required, the contractor’s final invoice shall be submitted within 45 days after the final period of performance date specified in the contract. The invoice must be clearly marked “final” and submitted as outlined above. In addition, a copy must be sent to: Crystal.E.North@usace.army.mil

Invoices must be submitted to all locations indicated in order for payment to be processed.

Only a warranted contracting officer, acting within their appointed limits, has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the contracting officer attempts to make changes to the terms and conditions of this contract, you shall not proceed with the change and shall immediately notify the contracting officer. Proceeding with any work not authorized by the contracting officer will be at the contractor’s own risk.

Section I - Contract Clauses

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities

DEC 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-26 Covered Telecommunications Equipment or Services-- Representation.

OCT 2020

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

JAN 2025

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.222-3 Convict Labor JUN 2003 52.222-50 Combating Trafficking in Persons NOV 2021 52.223-23 (Dev) Sustainable Products and Services (DEVIATION 2025-

O0004)

MAR 2025

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.226-8 Encouraging Contractor Policies To Ban Text Messaging

While Driving

MAY 2024

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014 52.246-9 Inspection Of Research And Development (Short Form) APR 1984 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

MAY 2024

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2023 252.204-7024 Notice on the Use of the Supplier Performance Risk System MAR 2023 252.225-7001 Buy American and Balance of Payments Program FEB 2024 252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022 252.225-7048 Export-Controlled Items JUN 2013 252.225-7056 Prohibition Regarding Business Operations with the Maduro

Regime

JAN 2023

252.225-7972 (Dev) Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems (DEVIATION 2024-O0014)

AUG 2024

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

DEC 2018

252.232-7006 Wide Area WorkFlow Payment Instructions JAN 2023 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV 2021)

(a) Definitions. As used in this clause--

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial products or commercial services, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)--

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23-13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES) (DEVIATION 2025-O0003/ DEVIATION 2025-O0004) (MAR 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L.

117-328), unless the agency grants an exception--see paragraph (b) of 52.204-27.

(v) 52.204-30, Federal Acquisition Supply Chain Security Act Orders--Prohibition. (DEC 2023) (Pub. L. 115-390, title II).

(vi) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(vii) [Reserved]

(viii) [Reserved]

(ix) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(x) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(xi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(xii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77 and 108-78 (19 U.S.C.

3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.233-1, Disputes (MAY 2014).

(vii) 52.244-6, Subcontracts for Commercial Products and Commercial Services (JAN 2025).

(viii) 52.253-1, Computer Generated Forms (JAN 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) (41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community--see FAR 3.900(a).

(ii) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-

282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(iii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (JAN 2025) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

(iv) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) (41 U.S.C. chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(v) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vi) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, “United States” includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vii) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(viii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(ix)(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(x) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.))).

(xi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xii) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2024) (42 U.S.C. 11001-11050 and 13101-13109) (Applies to services performed on Federal facilities).

(xiii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (MAY 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products as prescribed at FAR 23.109(d)(1)).

(xiv) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (MAY 2024) (42 U.S.C. 7671, et seq.) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xv) 52.223-20, Aerosols (MAY 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (MAY 2024) (42 U.S.C. 7671, et seq.) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xvii) 52.223-23, Sustainable Products and Services (MAR 2025) (DEVIATION 2025-O0004)) (7 U.S.C. 8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l) (Applies to contracts when the agency identifies in the statement of work, or elsewhere in the contract, the sustainable products and services that apply to the acquisition).

(xviii)(A) 52.225-1, Buy American--Supplies (OCT 2022) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in 2.101 on the date of award of this contract, and the acquisition--

(1) Is set aside for small business concerns; or

(2) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $50,000).

(B) Alternate I (OCT 2022) (Applies if the Contracting Officer has filled in the domestic content threshold below, which will apply to the entire contract period of performance. Substitute the following sentence for the first sentence of paragraph (1)(ii)(A) of the definition of domestic end product in paragraph (a) of 52.225-1:

(A) The cost of its components mined, produced, or manufactured in the United States exceeds percent of the cost of all its components. [Contracting officer to insert the percentage per instructions at 13.302- 5(d)(4).])

(xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xx) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information).

(xxi) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxii) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act--Covered Foreign Entities (Nov 2024). (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

(xxiii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(xxiv) 52.247-69, Reporting Requirement for U.S.-Flag Air Carriers Regarding Training to Prevent Human Trafficking (JAN 2025) (49 U.S.C. 40118(g)). (Applies to contracts with a U.S.-flag carrier for the transportation by air of passengers; does not apply to contracts awarded by the Department of Defense or contracts for commercial products).

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (NOV 2021) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.)

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded (JAN 2025) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (JAN 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

(Insert one or more Internet addresses)

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers.