Solicitation W912GB21Q0010.pdf

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912GB21Q0010 23-Jul-2021 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

SEE SCHEDULE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ [ ] IS X[ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS

KONRAD ADENAUER RING 39

D-65187 WIESBADEN GERMANY

WIESBADEN 65187

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ] FOB

DESTINATION

[ ] OTHER X

(See Schedule)

09-Aug-2021(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

ALYSHA MACDONALD

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912GB21Q0010

Section A - Solicitation/Contract Form

POCS

CONTACT INFORMATION

US GOVERNMENT POINTS OF CONTACT:

PRIMARY CONTRACT SPECIALIST: Ms. Alysha MacDonald at Alysha.A.MacDonald@usace.army.mil

CONTRACTING OFFICER: Ms. MAJ Andrene Alexander at andrene.a.alexander@usace.army.mil

INSTRUCTIONS TO OFFERORS

A. INTRODUCTION

1. The US Army Corps of Engineers (USACE) Europe District (NAU) intends to select one contractor for the renovation of the existing 2-story solid concrete / masonry facility with flat roof that serves as orphanage housing 15 people (10 children, 2 caregivers-teachers and 3 additional staff members). The building is continuously operated and will remain occupied during renovation.

B. PROPOSAL SUBMISSION

Introduction. To assure timely and equitable evaluation of proposals, Offerors must follow the instructions contained herein. Offerors are required to meet all Solicitation requirements, including terms and conditions, representations and certifications, and technical requirements, in addition to those identified as evaluation factors. The Offeror shall submit in the proposal all requested information specified in this section of the Request for Proposal (RFP) at or before the exact time specified. Failure to meet a requirement may result in an Offeror being ineligible for award. Copies of the RFP are available by INTERNET ACCESS ONLY. All solicitation documents will made available via SAM.GOV publishing. All amendments will be made available via SAM.GOV. It shall be the Offeror’s responsibility to check SAM.GOV for any amendments.

Inquiries. Offerors with technical inquiries and any other questions shall submit their inquiries via Bidder Inquiry in ProjNet at http://www.projnet.org/projnet. The bidder inquiry key is TFPYXM-2IJSDH. Offerors are requested to review the specification in its entirety and review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry. The Government reserves the right to decline addressing certain questions. Further, no questions, unless in the Government’s interest, will be answered any later than five business days prior to the stated deadline for offers. All Offerors are encouraged to register on ProjNet for alerts to stay abreast of Q&A’s that are posted in reference to this Solicitation. Only self-registered users on ProjNet can submit and review inquiries. To self-register, go to the webpage, click BID tab, select Bidder Inquiry, select agency USACE, enter the key for this Solicitation listed above, and your email address. After initial login, enter all the required information to create your user ID.

Verify the information on the next screen and from there you may submit and view inquiries.

Those submitting inquiries will receive a system generated email notification when their inquiry has been processed and answered. It is the Offeror’s responsibility to monitor for inquiries and responses.

If an Offeror has technical difficulties that cannot be resolved in a timely manner, they may submit their responses via email to the Contract Specialist, Alysha MacDonald, at Alysha.A.MacDonald@usace.army.mil.

1.General Proposal Submission Requirements.

a. Electronic Proposals. In an effort to reduce paperwork and costs, ALL RESPONSES TO THIS ANNOUNCEMENT SHALL BE SUBMITTED ELECTRONICALLY. Hand carried delivery or USPS/UPS/Fedex delivery of hard copies and/or CD-ROMs are not authorized.

Facsimile submission is not authorized. Offerors are to submit their proposal via email to the Contract Specialist, Alysha MacDonald, at alysha.a.macdonald@usace.army.mil and the contracting officer, MAJ Andrene Alexander, at andrene.a.alexander@usace.army.mil.

b. File Organization, Formatting, and other instructions. Although hard copies are not accepted, each file shall be clearly indexed, and logically assembled. Font size shall be 10 or larger. Pages shall be letter sized--larger page sizes (such as 11x17 foldouts, etc.) will be counted as two pages. Offerors shall prepare proposals in the English language. Proposals shall be in a narrative format, organized and titled so that each section of the proposal follows the order and format of the factors. Information presented should be organized so as to pertain to only the evaluation factor in the section that the information is presented. Proposals shall completely and adequately address the requirements of this Solicitation. Offerors are reminded that elaborate corporate marketing information, formatting, special reproduction techniques, etc., are not necessary. Failing to submit attachments or failing to complete the proposal properly may result in rejection of the offer without further evaluation. Information pertaining to more than one evaluation factor should be repeated in the each section for each factor. Electronic files shall be Microsoft Windows compatible. Files shall be submitted in their native format (i.e., doc, xls, ppt, etc.), or if in pdf format, shall be in searchable text. If the electronic files are of a size at which they must be compressed (zipped), they shall be compressed into one zipped folder.

c. Any information, presented in a proposal that the Offeror wants safeguarded from disclosure to other parties must be identified. The Government will endeavor to honor the restrictions against release requested by Offerors, to the extent permitted under United States law and regulations.

d. SPECIAL NOTICE: System for Award Management. Please take notice that the

System for Award Management (SAM, www.sam.gov) has a new entity registration requirement that firms submit an "original, signed notarized letter identifying the authorized Entity

Administrator for the entity associated with the Data Universal Numbering System (DUNS) number before the registration will be activated." This applies to all new entity registrations and all entity registration renewals, effective 29 April 2018. Further information behind this new requirement is posted to the General Services Administration's (GSA) announcement page at https://www.gsa.gov/samupdate. Please also refer to Federal Service Desk's (FSD) instructions on how to comply with this new requirement. NOTE: the instructions are different for domestic (U.S. based) and international (not U.S. based) firms. Offerors are reminded that this Solicitation includes the provision FAR 52.204-7 SAM and the resulting award will include the clause FAR 52.204-13 SAM Maintenance. These provisions/clauses require all contractors to register and maintain an active SAM entity registration in order to be eligible for contract awards, as prescribed by the regulation at FAR Subpart 4.11. In order to eligible for the contract award resulting from this Solicitation, Offerors are advised to take immediate action to ensure your SAM entity registration is current and/or will be current at the time of proposal receipt by this contracting office. Instructions for domestic entities (located in the U.S. or its outlying areas):

https://fsd.gov/fsd-gov/answer.do?sysparm_kbid=d2e67885db0d5f00b3257d321f96194b&sysparm_search=kb0013

183. Instructions for international entities (not located in the U.S. or its outlying areas):

https://www.fsd.gov/fsd-gov/answer.do?sysparm_kbid=dbf8053adb119344d71272131f961946&sysparm_search=KB001

C. NEGOTIATIONS

1. General Information: The Contracting Officer intends to evaluate proposals and award a contract without negotiations. Therefore, Offerors should include their best price terms in their initial offer and not assume they will have an opportunity to participate in negotiations and/or be asked to submit a revised proposal. However, the Contracting Officer may determine it necessary after evaluating initial proposals to engage in negotiations and/or other bilateral communications with one or more Offerors. The Contracting Officer will notify all Offerors when an award is made.

2. Negotiations Scheduling: If negotiations are conducted, the Contracting Officer may negotiate orally, in writing, etc. The method for negotiations will be at the discretion of the Contracting Officer. The Contracting Officer will provide additional instructions with the notification that negotiations are necessary.

Section B - Supplies or Services and Prices

PRICE SCHEDULE

Offerors shall provide pricing for all base and option items.

The following items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Statement of Work (SOW), Solicitation. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, and safety requirements.

All work shall be performed in accordance with these documents. Refer to Specification Section 01 22 00 Price and Payment Procedures for additional description of the work associated with each of the items.

Period of Performance: Refer to clause COMMENCEMENT PROSECUTION AND EXECUTION OF WORK (52.211-10) in the Solicitation for the period of performance for all base and option items.

Liquidated Damages: Refer to clause LIQUIDATED DAMAGES-CONSTRUCTION (52.211-12) in the Solicitation for the liquidated damages for all base and option items.

Option Items: The Government reserves the right to award the options up to 90 calendar days from contact award. Exercising Option CLIN 0002 will not extend the contract period of performance.

Item No. Title Quantity Unit Unit Price Amount

BASE ITEMS

Renovation of Jogeva

Orphanage 1 Job $ $

Total of Base Items 0001 $

OPTION ITEMS

Basement Exterior

Waterproofing 1 Job $ $

Total of Option Items 0002 $

Total of all Base and Option Items

EXTENSIONS: All extensions of the unit prices shown will be subject to verification by the Government.

In case of variation between the unit price and the extension, the unit price will be considered to be the offer.

-- END OF PROPOSAL SCHEDULE --

PRICE AND PAYMENT PROCEDURES

01/21

PART 1 GENERAL

1.1 PAYMENT TYPES

The costs for performance of any work required by the contract which is not associated with a specific base or option item description shall be included in the first base item (Base Item 0001).

1.1.1 Single Job Payment Items

Payment items for the work of this contract for which contract lump sum payments will be made are listed in the PRICE SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved.

The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.1.2 Unit Price Payment Items

Payment items for the work of this contract on which the contract unit price payments will be made are listed in the BIDDING SCHEDULE and described below. The unit price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

For each unit price payment item identified in the SCHEDULE OF ITEMS, the contractor shall submit a Quantity Measurement Plan describing the procedures they will employ to ensure accurate measurement and recording of quantities submitted for payment. This plan must be approved prior to performing any work associated with the applicable items.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

1.3 SCHEDULE OF ITEMS: BASE ITEMS

1.3.1 Base Item 0001: Renovation of Jogeva Orphanage

Unit of Measure: Job.

Payment will be made for costs associated with the renovation of existing two-story solid orphanage solid concrete / masonry facility with flat roof which includes installation of exterior renovation of existing facility, replacement of exterior stairwell, replacement of roof covering, patch work and paint, installation of ventilation fans, and minor plumbing repairs as indicated in the SECTION 01 10 10 and shown on the conceptual layout, with the exceptions of the bid options listed below. This work shall include all applicable demolition and removals work to support the work elements contained in this item.

1.4 SCHEDULE OF ITEMS: OPTION ITEMS

1.4.1 Awarding of Options

The Government reserves the right to award any option or combination of options in any order and the exercise of any option will not commit the Government to award any other option(s).

1.4.2 Option 1: Item 0002: Basement Exterior Waterproofing

Unit of Measure: Job.

Payment will be made for costs associated with the exterior waterproofing of basement walls as indicated in SECTION 01 10 10 and the conceptual layout, with the exceptions of the bid options listed below.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section -

Section H - Special Contract Requirements

GENERAL REQUIREMENTS

VAT Procedures--Estonia

The U.S. Government does not pay Value Added Tax (VAT) or other taxes for goods or services purchased in Estonia. The current method of obtaining this VAT exemption is that contractors on USACE contracts will receive a reimbursement of VAT paid in further of a USACE directly from the Estonian Ministry of Finance (MoF). To properly receive reimbursements the below listed procedures will be followed. Be advised that contractors are responsible for providing accurate and timely information to facilitate VAT reimbursement procedures. USACE will not reimburse contractors for the costs associated with processing VAT reimbursement and will not be liable for any delays associated with VAT reimbursement.

1. As part of regularly submitted invoices, contractors shall include a line item for VAT incurred as part of executing the project (the contractor shall retain sufficient documentation to substantiate the amount of VAT included on the invoice to USACE).

2. USACE will pay contractor invoice exclusive of VAT.

3. USACE and/or the contractor will prepare the attached VAT reimbursement form in two copies for each invoice. The contractor shall prepare the form or provide sufficient information as necessary and at the request of the Contracting Officer Representative

(COR).

4. The contractor shall provide the COR with the name and bank account information for deposit of VAT reimbursement.

5. USACE shall coordinate with the Ministry of Defense for countersignature of each VAT form.

6. USACE will then return the VAT forms to the contractor. One VAT form will be retained by the contractor and one VAT form shall be submitted to the Estonian Tax Authority by the contractor.

7. The Tax Authority will deposit the reimbursement into the contractors account roughly 20 days after USACE submits the reimbursement request.

WORKERS COMPENSATION INSURANCE (DEFENSE BASE ACT) – COUNTRIES WITH

WAIVERS

(a) This clause supplements FAR Clause 52.228-3. The Department of Labor has waived application of the Defense Base Act (DBA) for performance of work by employees other than U.S. citizens and employees recruited in the U.S. in any country listed at the US Department of Labor website here: https://www.dol.gov/owcp/dlhwc/dbawaivers/dbawaivers.htm

Accordingly, this clause applies to work performed by U.S. citizens, employees recruited in the U.S. and also to work by any employee performed in a country for which a Defense Base Act waiver is not in place.

The Department of Labor (DOL) has approved multiple insurance carriers which promote a competitive market environment. Therefore, contractors shall obtain commercially available DBA insurance from a DOL authorized insurance carrier unless the contractor is under a self insurance program approved by the DOL or subject to a waiver. The DOL approved carriers and self insured employers are available at http://www.dol.gov/owcp/dlhwc/lscarrier.htm.

(b) The contractor agrees to insert a clause substantially the same as this one in all subcontracts to which DBA is applicable. Subcontractors shall be required to insert a similar clause in any of their subcontracts subject to the DBA.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018 52.204-13 System for Award Management Maintenance OCT 2018 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-13 Violation of Arms Control Treaties or Agreements -- Certification.

FEB 2021

52.214-34 Submission Of Offers In The English Language APR 1991 52.217-5 Evaluation Of Options JUL 1990 52.222-56 Certification Regarding Trafficking in Persons Compliance

Plan.

OCT 2020

52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014 52.228-11 (Dev) Individual Surety--Pledge of Assets (DEVIATION 2020-

O0016)

FEB 2021

52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 (Dev) Performance and Payment Bonds-Construction. (Deviation

2020-O0016)

JUN 2020

52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-27 (Dev) Payments in Support of Emergency and Contingency

Operations (Deviation 2009-O0011)

JAN 2017

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017 252.225-7042 Authorization to Perform APR 2003 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.229-7001 Tax Relief APR 2020 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7008 Assignment of Claims (Overseas) JUN 1997 252.233-7001 Choice of Law (Overseas) JUN 1997 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use no later than 365 calendar days after the contractor receives the Notice to Proceed. Any options, if awarded, shall be completed concurrently with all other work.

The time stated for completion shall include final cleanup of the premises. The Government intends to issue a single Notice to Proceed for all work.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $583 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (FEB 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (NOV 2020).

(ix) 52.253-1, Computer Generated Forms (JAN 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (JAN 2020) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) (41 U.S.C. chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (OCT 2020) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (NOV 2020) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (JAN 2021) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract, and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (JUN 2020) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 90 days from Notice to Proceed. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Contracting Office

USACE NAU

Konrad-Adrenauer Ring 39, 65187 Wiesbaden Germany

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- 1130 to 1230 Eastern European Standard Time on 29 July 2021

(c) Participants will meet at-- GPS Coordinates: 58.727947, 26.344185

Note: Any interested contractors must notify the USACE PM, USACE CS, and the USACE PE their intent to participate in the site visit, and the names of the individuals attending by COB 27 Jul 2021.

PM: Adrian Rios, Adrian.T.Rios@usace.army.mil PE: Chris Bailey, Christopher.C.Bailey@usace.army.mil CS: Alysha MacDonald, alysha.a.macdonald@usace.army.mil

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far

252.225-7043 ANTITERRORISM/FORCE PROTECTION POLICY FOR DEFENSE CONTRACTORS

OUTSIDE THE UNITED STATES (JUN 2015)

(a) Definition. United States, as used in this clause, means, the 50 States, the District of Columbia, and outlying areas.

(b) Except as provided in paragraph (c) of this clause, the Contractor and its subcontractors, if performing or traveling outside the United States under this contract, shall--

(1) Affiliate with the Overseas Security Advisory Council, if the Contractor or subcontractor is a U.S. entity;

(2) Ensure that Contractor and subcontractor personnel who are U.S. nationals and are in-country on a non-transitory basis, register with the U.S. Embassy, and that Contractor and subcontractor personnel who are third country nationals comply with any security related requirements of the Embassy of their nationality;

(3) Provide, to Contractor and subcontractor personnel, antiterrorism/force protection awareness information commensurate with that which the Department of Defense (DoD) provides to its military and civilian personnel and their families, to the extent such information can be made available prior to travel outside the United States; and

(4) Obtain and comply with the most current antiterrorism/force protection guidance for Contractor and subcontractor personnel.

(c) The requirements of this clause do not apply to any subcontractor that is--