Solicitation - W15QKN26QA143.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Patrick.Ferguson Line

Patrick.Ferguson Line

Section 00 00 00 - Procurement and Contracting Requirements

Range Echo Berm Upgrade - Fort Devens, MAInstrument Name:

A. This project is for construction services at Fort Devens, MA. The purpose of this requirement is for the construction of Berm Upgrades on Range Echo in support of United States Army Garrison (USAG) Devens Reserve Forces Training Area (DRFTA) Directorate of Planning, Training, Mobilization, and Security (DPTMS). B. The NAICS Code is 238910 with a size standard of $19,000,000.00. C. This is a Firm Fixed Price Total Small Business Set Aside. D. Place of Performance will be Range Echo at Fort Devens, MA. E. Period of Performance (POP) shall be 365 days after Notice to Proceed.

Product Service Code : Z2PC

*** THIS REQUIREMENT IS A 100% SMALL BUSINESS SET ASIDE IN ACCORDANCE WITH

FAR 19.502-2 ***

THIS REQUIREMENT IS SUBJECT TO THE AVAILABILITY OF FUNDS IN ACCORDANCE

WITH FAR CLAUSE 52.232-18

INSTRUCTIONS TO OFFERORS

1. GENERAL INSTRUCTIONS

This solicitation is issued for a commercial construction requirement using Revolutionary Federal Acquisition Regulation Overhaul (RFO) Federal Acquisition Regulation (FAR) Part 12 procedures, with applicable construction requirements under RFO FAR Part 36 and RFO Defense Federal Acquisition Regulation Supplement (DFARS) Part 236.

This acquisition uses the lowest price technically acceptable (LPTA) methodology. Award will be made to the responsible quoter whose quote is technically acceptable and whose total evaluated price is the lowest price determined fair and reasonable.

The Government contemplates award of a firm-fixed-price purchase order resulting from this request for quotations.

For acquisitions conducted as a request for quotations, a quotation is not an offer. The Government's issuance of a purchase order is the offer. A binding contract is formed when the contractor accepts the purchase order by signature, written acceptance, or substantial performance.

2. REQUIREMENT DESCRIPTION AND ATTACHMENTS

W15QKN26QA143

The Government requires performance of commercial construction services for Range Echo Firing Berm Upgrade (DEVENS) at Devens RFTA located at Installation PBO, Whse Bldg 3574, 12 Feinberg Street, Devens, MA 01434-4429. The work shall be performed in accordance with the solicitation and all attachments listed below.

All work shall be performed in accordance with the Specifications of Work, drawings, Davis-Bacon wage decision, Construction Form, and any other attachments incorporated into the solicitation or resulting award.

Attachment(s):

Attachment 0001 Specifications of Work

Attachment 0002 Davis-Bacon Wage Decision

Attachment 0003 Construction Cost Breakdown Form

3. POINTS OF CONTACT

Contracting Officer: Jasmyne Peterson, jasmyne.c.peterson.civ@army.mil

Contract Specialist: Mitchell Douglas, mitchell.e.douglas.civ@army.mil

All communications regarding this solicitation shall be submitted in writing to the contracting officer and contract specialist.

4. SUBJECT TO AVAILABILITY OF FUNDS

NOTICE: THIS REQUIREMENT IS ISSUED AS SUBJECT TO AVAILABILITY OF FUNDS (SAF).

FUNDS ARE NOT CURRENTLY AVAILABLE. NO AWARD WILL BE MADE UNDER THIS

SOLICITATION UNTIL FUNDS ARE AVAILABLE. THE GOVERNMENT RESERVES THE

RIGHT TO CANCEL THIS SOLICITATION, IN WHOLE OR IN PART, IF FUNDS DO NOT

BECOME AVAILABLE.

5. SUBMISSION REQUIREMENTS

The quoter shall submit the following documents by the date and time stated in the solicitation:

a. Standard Form 1442. Complete and sign the required blocks of the Standard Form (SF) 1442.

The SF 1442 must be signed by an individual authorized to bind the quoter.

b. Attachment 0003, Construction Cost Breakdown Form. The quoter shall submit Attachment 0003 in Microsoft Excel format with all formulas intact and functional. Attachment 0003 constitutes the technical and price submission. Attachment 0003 shall include, as applicable:

Labor categories

Labor hours

Labor rates

Material types, quantities, and unit prices

Equipment quantities, durations, and unit prices

Overhead, profit, bonding, and general and administrative costs

Subcontractor identification and subcontracted work scope, if applicable

c. Acknowledgment of amendments. The quoter shall acknowledge all amendments issued before the submission deadline.

d. System for Award Management registration. The quoter shall have active System for Award Management (SAM) registration at the time of quote submission and at the time of award.

e. Line item pricing. The quoter shall include pricing for each contract line item number or line item identified in the solicitation and Attachment 0003.

f. Davis-Bacon wage decision. The applicable Department of Labor Davis-Bacon wage decision is incorporated into this solicitation and any resulting purchase order as Attachment "0002", "Davis- Bacon Wage Decision". Submission of a quote constitutes agreement to comply with the incorporated Davis-Bacon wage decision and applicable construction labor requirements.

6. SITE VISIT

Site visits are optional but highly encouraged. A site visit will be available 17 JULY 2026 at 10:

00AM EDT. The primary site visit POC will be Daniel Sanchez, Range Officer. All Contractors interested in attending the site visit shall submit their request via email to the site visit POC, Daniel Sanchez, at daniel.j.sanchez76.civ@army.mil, the Contracting Officer, Ms. Jasmyne Peterson, at jasmyne.c.peterson.civ@army.mil, and the Contract Specialist, Mr. Mitchell Douglas, at mitchell.e.

douglas.civ@army.mil. All requests to attend the site visit shall be submitted no later than 10:00AM EDT, Thursday, 16 JULY 2026.

See FAR 52.236-27, Site Visit (Construction), when included in the solicitation, and the applicable solicitation notice for site visit date, time, location, scheduling, and point of contact information.

The quoter is responsible for reviewing the solicitation, attachments, drawings, specifications, site conditions made available through the solicitation, and any site visit information before submitting a quote. In no way shall failure to inspect the site constitute grounds for a claim after award.

7. QUESTIONS AND ANSWERS

Questions regarding this solicitation shall be submitted in writing to the contracting officer and contract specialist no later than 12:00PM EDT Monday, 20 JULY 2026.

Phone calls will not be accepted for questions. Questions must be submitted in writing via email to the Contracting Officer, Jasmyne Peterson, at jasmyne.c.peterson.civ@army.mil and the Contract Specialist, Mitchell Douglas, at mitchell.e.douglas.civ@army.mil.

The contracting officer will review late questions on a case-by-case basis and determine whether a response is necessary to maintain the integrity of the acquisition and protect the Government's interests.

Responses to questions will be provided by amendment or through the official solicitation posting.

8. AMENDMENTS

The Government may issue amendments to this solicitation. Quoters are responsible for monitoring the solicitation posting for amendments.

The quoter shall acknowledge and sign any and all amendments issued before the submission deadline, which shall be included in the solicitation response. In doing so, the Offeror accedes to the contract terms and conditions as written. Failure to acknowledge amendments may result in rejection if the contracting officer determines the failure is material.

9. COMMUNICATIONS AFTER RECEIPT

The Government intends to evaluate quotes and make award without further communication. The Government reserves the right to request information necessary to evaluate compliance, technical acceptability, price reasonableness, or responsibility.

The Government may request correction of apparent clerical errors, clarification of information already submitted, or information needed to complete the Government's evaluation. The Government may communicate with one or more quoters when the contracting officer determines the communication is in the Government's interest and does not prejudice the evaluation.

The Government may issue an amendment and request revised quotes when the contracting officer determines revisions are necessary or in the Government's interest.

Nothing in this section requires the Government to request clarification, request revised submissions, or communicate with any quoter.

10. BONDS, PAYMENT PROTECTION, AND BID GUARANTEE

Bond, payment protection, and bid guarantee requirements are based on the quoted price. The quoter shall review the requirements below before submitting its quote.

a. Quoted price at or below $35,000. Payment protection is not required for a construction purchase order at or below $35,000.

b. Quoted price greater than $35,000 but not greater than $150,000. Payment protection is required in accordance with RFO FAR 28.102-1(b). Acceptable payment protection may include a payment bond, irrevocable letter of credit, or other payment protection authorized by the solicitation and accepted by the contracting officer.

c. Quoted price greater than $150,000. Performance and payment bonds are required in accordance with RFO FAR 28.102-1(a) and 52.228-15, Performance and Payment Bonds, Construction. The performance bond and payment bond amounts shall each equal 100 percent of the original award price unless otherwise stated by the contracting officer.

d. Bid guarantee. If the quoted price exceeds $150,000 and performance and payment bonds are required, the quoter shall submit a bid guarantee with its quote. The bid guarantee amount shall be 20 percent of the quote price or $3 million, whichever is less, unless otherwise stated in the solicitation. Failure to submit a required bid guarantee in the proper form and amount by the submission deadline may result in rejection at the compliance review stage.

e. Bond submission after award. Required performance and payment bonds are due within 10 calendar days after award. Bonds shall be submitted by email with raised seals clearly shaded.

The contractor shall not begin work until required bonds are furnished and accepted by the contracting officer.

11. INSURANCE REQUIREMENTS

The apparent successful quoter shall provide proof of insurance at the time of award when requested by the contracting officer. Failure to provide proof of required insurance may result in the Government proceeding to the next eligible quoter or taking other action in the Government's interest.

12. COMPLIANCE REVIEW

Before technical and price evaluation, the Government will conduct a compliance review. A quote may be rejected if the contracting officer determines it contains a material compliance issue.

The following may result in rejection:

Late submission

Failure to submit Attachment 0003, Construction Cost Breakdown Form

Failure to submit Attachment 0003 in Microsoft Excel format

Broken, locked, deleted, altered, or nonfunctional formulas in Attachment 0003

Missing line item pricing

Missing labor, material, equipment, overhead, profit, bonding, or general and administrative pricing where required by Attachment 0003

Failure to properly complete or sign the Standard Form 1442

Failure to acknowledge amendments, if applicable

Inactive or incomplete System for Award Management registration at quote submission

Any other omission, inconsistency, or error the contracting officer determines material

The contracting officer will determine the materiality of any compliance issue.

13. EVALUATION PROCESS

Only quotes deemed compliant will proceed to technical acceptability and price evaluation.

Technical acceptability and price reasonableness will be evaluated separately.

Refer to Addendum to FAR 52.212-2 "Addendum to Evaluation Criteria".

14. OFFER VALIDITY

All offers shall remain valid for 120 calendar days.

15. ADDENDUMS

See Federal Acquisition Regulation (FAR) 52.212-1 "Addendum For Instructions To Offerors", FAR

52.212-2 "Addendum For Evaluation Criteria" and FAR 52.212-4 "Addendum For Contract Terms and Conditions--Commercial Products and Commercial Services.

16. TIME EXTENSIONS

In accordance with FAR 52.211-13 "Time Extensions", extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order may also provide an equitable readjustment of liquidated damages under the new completion schedule.

17. COMPLETING A QUOTE FOR SUBMITTAL

a. Quotes are due no later than the date and time specified in the Standard Form (SF) 1442, Block 13, and shall be submitted via email to the Contract Specialist, Mitchell Douglas at mitchell.e.

douglas.civ@army.mil, and the Contracting Officer, Ms. Jasmyne Peterson at jasmyne.c.peterson.

civ@army.mil. Updates to this solicitation will be posted under the solicitation notice on the SAM website (https://www.SAM.gov).

b. Quotes shall include the Offerors CAGE Code, Unique Entity Identified (UEI), Federal Tax Identification Number (TIN), and any small business preference or socioeconomic concern (such as 8(a) certified, HUBZone certified, Women-Owned Small Business/Economically Disadvantaged Women-Owned Small Business, and Service-Disabled Veteran-Owned Small Business) under the applicable NAICS Code (see SF1442, Block 10).

c. The Offeror shall submit a price for each FFP Contract Line Item Number (CLIN) on the SF1442 under Section 00 10 00--Solicitation, Contract Line Item Number (CLIN) Schedule. The Offeror shall complete blocks 14, 15, and 30. The Offeror is required to submit a signed SF1442 (Blocks 30a-30c).

d. Provide the name, title, address, email address and telephone number of the company/division point of contact regarding business decisions made with respect to the quote who is authorized to contractually obligate the company. The Offeror shall identify those individuals authorized to negotiate with the Government.

e. Pricing for each CLIN shall be submitted in the proper format. The proper format consists of QUANTITY * UNIT PRICE = AMOUNT/NET AMOUNT. In the even there is a discrepancy in the calculation, the UNIT PRICE will be held to the intended price multiplied by the QUANTITY. If the Offeror shows only the AMOUNT/NET AMOUNT, but fails to enter a UNIT PRICE, the AMOUNT /NETAMOUNT divided by the QUANTITY will be held to be the intended price.

f. The Offeror shall submit with its quote, the Prime Contractor's valid Certificate of Insurance (COI) in accordance with the requirements and applicable insurance amounts set forth within the solicitation at FAR 52.228-5, "Insurance--Work on a Government Installation" and "Insurance Requirements" listed below.

g. The Offeror shall complete all "fill-ins" in provisions and clauses that apply to the response to this solicitation.

h. The Offeror shall complete Standard Form LLL, "Disclosure of Lobbying Activities" if applicable.

i. Failure to provide any applicable information required by this solicitation may result in the Offeror being deemed non-responsive and ineligible for consideration of award.

CONTRACT ADMINISTRATION

Inquiries concerning all contractual actions after award shall be directed first to the Contract Administrator and Contracting Officer.

The Contract Administrator will incorporate all changes and other administrative actions Changes:

to the contract as directed and authorized by the Contracting Officer.

CONSTRACT SPECIALIST: Mitchell Douglas

Email: mitchell.e.douglas.civ@army.mil

CONTRACTING OFFICER: Jasmyne Peterson

Email: jasmyne.c.peterson.civ@army.mil

CUSTOMER: Devens Reserve Forces Training Area (DRFTA), Directorate of Planning Training Mobilization, and Security (DPTMS)

Primary POC: Mr. Daniel Sanchez, Range Operations Officer (ROO)

Email: daniel.j.sanchez76.civ@army.mil

Phone: (520) 717-3721

PERFORMANCE LOCATION:

Devens South Post Range Complex, Echo Range

Devens, MA 01434

REQUIRED INSURANCE

FAR 28.307-2 Liability

In accordance with FAR 28.307-2, the Contractor is required to provide and maintain the kinds and minimum amounts of insurance stated below:

a) Workers' Compensation and Employer's Liability. Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers. (See 28.305(c) for treatment of contracts subject to the Defense Base Act.)

(b) General Liability.

(1) The contracting officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000 per occurrence.

(2) Property damage liability insurance shall be required only in special circumstances as determined by the agency.

(c) Automobile Liability. The contracting officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(d) Aircraft Public and Passenger Liability. When aircraft are used in connection with performing the contract, the contracting officer shall require aircraft public and passenger liability insurance.

Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger liability, and $200,000 per occurrence for property damage. Coverage for passenger liability bodily injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

(e) Vessel Liability. When contract performance involves use of vessels, the contracting officer shall require, as determined by the agency, vessel collision liability and protection and indemnity liability insurance.

HQ AMC-LEVEL PROTEST

If Internet access is not available contact the contracting officer or HQ, AMC to obtain the AMC Level

Protest Procedures.

Web Address: http://www.amc.army.mil/amc/commandcounsel.html

The AMC-level protest procedures are found at:

Email: usarmy.redstone.usamc.mbx.protests@army.mil

Fax: (256) 450-8840

Redstone Arsenal, AL 35898-5000

Rm: A6SE040.001

4400 Martin Road

Office of Command Counsel-Deputy Command Counsel

Headquarters U.S. Army Materiel Command

Address:

Send protests (other than protests to the contracting officer) to: jasmyne.c.peterson.civ@army.mil

If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible contracting officer. However, you can also protest to Headquarters, AMC. The HQ, AMC-Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with the General Accounting Office or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. The AMC protest decision goal is to resolve protests within 20 working days from filing. To be timely, protests must be filed within the periods specified in FAR 33.104.

LVL I ANTI-TERRORISM AWARENESS

52.000-4002 LEVEL 1 ANTI TERRORIST AWARENESS TRAINING REQUIREMENTS FOR

CONTRACTOR EMPLOYEES (OCT 2010)

(a) All contractor employees requiring access to any Federally-controlled facility and logical access to Federally controlled information systems except for "national security systems" as defined by 44 U.S.C. 3542(b)(2), should be certified in Level 1 Anti Terrorism Training. The training is accessible from any computer with access to the World Wide Web and is available at https:/atlevel1.dtic.mil /at. The contractor is responsible for ensuring that the training has been satisfactorily completed and that valid certificates of completion have been submitted to the Contracting Officers Representative (COR) with a copy furnished to the Contracting Officer. The Certificates are valid for one year, therefore, training shall be completed every year for the duration of the contract.

(b) The term Federally-controlled facility is defined as:

(1) Federally-owned buildings or leased space, whether for single or multi-tenant occupancy, and its grounds and approaches, all or any portion of which is under the jurisdiction, custody or control of a department or agency;

(2) Federally-controlled commercial space shared with non-government tenants. For example, if a department or agency leased the 10th floor of a commercial building, the Directive applies to the 10th floor only;

(3) Government-owned, contractor-operated facilities, including laboratories engaged in national defense research and production activities; and

(4) Facilities under a management and operating contract, such as for the operation, maintenance, or support of a Government-owned or Government-controlled research, development, special production, or testing establishment.

(c) The term "Federally-controlled information system" means an information system (44 U.S.C.

3502(8) used or operated by a Federal agency, or a contractor or other organization on behalf of the agency (44 U.S.C. 3544(a).

(d) The term "contractor employee" includes employees, agents, students or student interns, or representatives and all employees, agents or representatives of all subcontractors and suppliers.

DISCLOSURE OF UNIT PRICE

52.224-4001 DISCLOSURE OF UNIT PRICE INFORMATION OCT 2010

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such posting prior to submission of initial proposals.

*** END OF NARRATIVE ***

Section 00 01 15 - List of Drawing Sheets

The attachments included in this section are incorporated by reference and made part of this contract with the same force and effect as if included in full text.

*** END OF NARRATIVE ***

Identifier Document Name

Document Description

Reference Identifier

Date Line Item

Page Numbers

Document Type

Provided Under Separate Cover

0001 TAB 6 - P WS

Firing Points Up date Range Echo Cont ract

Statement of Work

Jun

Attachment No

0002 DBA_WD_Mas sachusetts

_MA2026000

1_Mod._No.

_1_Rev._Da te_05.18.2 6

Wage Determination

May

Attachment No

0003 Contractor Cost Brea kdown

Cost Breakdown Form

Jun

Attachment No

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Item Supplies/Service Quanti ty

Unit Unit Price Amount

0001 Product Service Description: Echo Range Firing Berm Update

Product Service Code: Z2PC

North American Industry Classification System (NAICS):

238910

Pricing Arrangement: Firm Fixed Price

1 Job

0002 Product Service Description:

Bonding

Product Service Code: Z2PC

North American Industry Classification System (NAICS):

238910

Pricing Arrangement: Firm Fixed Price

1 Job

Section 00 21 00 - Instructions

Addendum to 52.212-1, Instructions to Offerors--Commercial Products and Commercial Services

Paragraphs (D), (E), (H), and (I) are hereby deleted from the referenced provisions.

Paragraph (C) Period of Acceptance of offers:

The Offeror agrees to hold the prices in its offer firm for 120 calendar days form the date specified for receipts of offers, unless another time period is specified in an addendum to the solicitation.

*** END OF NARRATIVE ***

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.204-7 System for Award Management- Registration. (Deviation 2026- O0038)

2026-02

52.212-1 Instructions to Offerors- Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-02

52.214-34 Submission of Offers in the English Language.

1991-04

52.214-35 Submission of Offers in U.S.

Currency.

1991-04

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (Deviation 2026- O0038)

2026-02

52.225-10 Notice of Buy American Requirement-Construction

2014-05

Materials.

52.233-2 Service of Protest. (Deviation 2026-O0038)

2026-02

52.237-1 Site Visit. 1984-04

DFARS Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.204-7024 Notice on the Use of the Supplier Performance Risk System.

2023-03

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors.

2023-01

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.216-1 Type of Contract. (Deviation 2026-O0038)

Type of Contract (Feb 2026) (Deviation 2026-O0038)

The Government contemplates award of a Firm-Fixed-Price (FFP)[Contracting Officer insert specific type of contract] contract resulting from this solicitation.

(End of provision)

52.228-1 Bid Guarantee. 1996-09

Bid Guarantee (Sept 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

52.252-1 Solicitation Provisions Incorporated by Reference.

1998-02

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far-overhaul________[Insert one or more Internet addresses]

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.215-7008 Only One Offer. 2022-12

ONLY ONE OFFER (DEC 2022)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable (10 U.S.C. 3705) or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 3702 and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.

S. Contracting Officer that the proposed price is fair and reasonable as requested by the Contracting Officer[U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

Section 00 45 00 - Representations and Certifications

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

2024-09

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements- Representation.

2017-01

52.223-1 Biobased Product Certification.

(Deviation 2026-O0038)

2026-02

52.229-12 Tax on Certain Foreign Procurements. (Deviation 2026- O0038)

2021-02

DFARS Provisions Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials.

2022-09

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls.

2016-10

252.225-7055 Representation Regarding Business Operations with the Maduro Regime.

2022-05

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

2023-06

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.203-2 Certificate of Independent Price Determination.

1985-04

Certificate of Independent Price Determination (Apr 1985)

(a) The offeror certifies that-

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to-

(i) Those prices;

(ii) The intention to submit an offer; or

(iii) The methods or factors used to calculate the prices offered.

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory-

(1) Is the person in the offeror's organization responsible for determining the prices being offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to paragraphs (a)(1) through (a)(3) of this provision; or

(2)

(i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to paragraphs (a)(1) through (a)(3) of this provision ____[insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization];

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) of this provision have not participated, and will not participate, in any action contrary to paragraphs (a)

(1) through (a)(3) of this provision; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to paragraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) above, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

52.209-2 Prohibition on Contracting With Inverted Domestic Corporations-

2026-02

Representation. (Deviation 2026-

Prohibition on Contracting with Inverted Domestic Corporations-Representation (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Subsidiary means an entity in which more than 50 percent of the entity is owned-

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-3(b) applies or the requirement is waived in accordance with the procedures at 9.108-5.

(c) Representation. The Offeror represents that-

(1) It [ ] is, [ ] is not an inverted domestic corporation; and

(2) It [ ] is, [ ] is not a subsidiary of an inverted domestic corporation.

52.209-5 Certification Regarding Responsibility Matters.

(Deviation 2026-O0038)

2026-02

Certification Regarding Responsibility Matters (Feb 2026) (Deviation 2026-O0038)

(a)

(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are [ ] are not [ ] presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have [ ] have not [ ], within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks "have", the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are [ ] are not [ ] presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)

(B) of this provision; and

(D) Have [ ], have not [ ], within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds the threshold at 9.104-5(a)(2) for which the liability remains unsatisfied. Federal taxes are considered delinquent if both of the following criteria apply:

(1) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if a pending administrative or judicial challenge remains. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(2) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) The Offeror has [ ] has not [ ], within a 3-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) "Principal," for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.

g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the Government will consider the certification in connection with a determination of the Offeror's responsibility.

Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) This provision does not require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a). The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If the Government later determines that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.209-7 Information Regarding Responsibility Matters.

(Deviation 2026-O0038)

2026-02

Information Regarding Responsibility Matters (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this provision-

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law.

Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (Feb 2026) (Deviation 2026-O0038)

(a) The Government will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that-

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.209-13 Violation of Arms Control Treaties or Agreements- Certification. (Deviation 2026-

Violation of Arms Control Treaties or Agreements-Certification (Feb 2026) (Deviation 2026-

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial products and commercial services as defined in Federal

Acquisition Regulation 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

[ ] (1) The Offeror certifies that-

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament…