Solicitation - FA500421B0005.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA500421B0005

Section A - Solicitation/Contract Form

- One 500 kVA transformer, one power drop, five power poles, associated guy wires and lines.

- The transformer will be ground mounted and require a new concrete pad. A utility vault will also be required.

- The power drop should be located on the same concrete pad as the transformer.

- Provide underground service from a pole that has a three bank transformer on it and add a riser across the road.

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Power Upgrades to Charlie Battery:

Construct electrical components for providing all planning, labor, material, equipment, permits, and transportation and performing all operations necessary to perform the work described in strict accordance with the Contract Documents especially the Statement of Work and project specifications for FTQW 21-2009

PC.

Firm Fixed Price

CIN: 00000000000006695539

1 Job

Section C - Description/Specifications/Statement of Work

Requirements The Joint Pacific Range Complex is adding modern emitters which require improvements and expand the power infrastructure at the Charlie Battery area approximately 13 miles east of Eielson AFB, Alaska. Install one 500 kVA transformer, one power drop, five power poles, associated guy wires and lines. The transformer will be ground mounted and require a concrete pad. A utility vault will also be required. Provide underground service from a pole that has a three bank transformer on it and add a riser across the road.

DFARS Clauses Incorporated by Full Text

252.222-7000 Restrictions on Employment of Personnel 2000-03

As prescribed in 222.7004, use the following clause:

RESTRICTIONS ON EMPLOYMENT OF PERSONNEL (MAR 2000)

(a) The Contractor shall employ, for the purpose of performing that portion of the contract work in , individuals who are residents Alaska thereof and who, in the case of any craft or trade, possess or would be able to acquire promptly the necessary skills to perform the contract.

(b) The Contractor shall insert the substance of this clause, including this paragraph (b), in each subcontract awarded under this contract.

(End of clause)

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08

0001 Inspection and Acceptance Location Both Destination Instructions: All inspection/acceptance shall be coordinated with the listed POC.

DoDAAC: F1U1RG Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

F1U1RG 354 RANGE SQUADRON

AF NO MILSBILLS PROC CP 9073777264

354 BROADWAY AVE BLDG 3112

EIELSON AFB, AK 99702 1801

UNITED STATES

OfficeCode:

James Kot Email: james.kot@us.af.mil Telephone: 907-377-7061

Section F - Deliveries or Performance

Delivery Schedule Ship To Address

Delivery Schedule From date of lead time event to completion of performance 300 Calendar Days Date of Notice to Proceed Receipt

Ship To DoDAAC: F1U1RG Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

F1U1RG 354 RANGE SQUADRON

AF NO MILSBILLS PROC CP 9073777264

354 BROADWAY AVE BLDG 3112

EIELSON AFB, AK 99702 1801

UNITED STATES

OfficeCode:

James Kot Email: james.kot@us.af.mil Telephone: 907-377-7061

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown. 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports WAWF payment instructions.

in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

Construction Invoice

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in Document routing.

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700

Issue By DoDAAC FA5004

Admin DoDAAC FA5004

Inspect By DoDAAC F1U3C7

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) FA5004

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

james.kot@us.af.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

Section H - Special Contract Requirements

Section I - Contract Clauses

52.228-1 Bid Guarantee.

As prescribed in 28.101-2 , insert a provision or clause substantially as follows:

Bid Guarantee (Sept 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be __20__ percent of the bid price or $_3,000,000.00__, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2020-06 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2020-08 52.204-19 Incorporation by Reference of Representations and Certifications. 2014-12 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.219-6 Deviation 2020-O0008 Notice of Total Small Business Set-Aside (DEVIATION 2020-O0008) (Revision 2) 2020-11 52.219-13 Notice of Set-Aside of Orders. 2020-03 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2021-07 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. 2014-05 52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-54 Employment Eligibility Verification. 2015-10 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2020-06 52.223-21 Foams. 2016-06 52.232-23 Assignment of Claims. 2014-05 52.233-3 Protest after Award. 1996-08 52.236-5 Material and Workmanship. 1984-04

52.236-7 Permits and Responsibilities. 1991-11 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.243-5 Changes and Changed Conditions. 1984-04 52.247-15 Contractor Responsibility for Loading and Unloading. 1984-04 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). 1984-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. 2011-09 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2021-01

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7048 Export-Controlled Items. 2013-06 252.232-7010 Levies on Contract Payments. 2006-12

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

2020-04

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.244-7000 Subcontracts for Commercial Items. 2020-10

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. 1989-12

As prescribed in , insert the following clause:4.103

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of [identify title of designated agency official here] and shall not be binding until Contracting Officer so approved.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04

As prescribed in , insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The 11.404(b) clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the 10 date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .300

* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 Liquidated Damages-Construction. 2000-09

As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of ____$303.09___for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-14 Limitations on Subcontracting. 2020-11

As prescribed in , insert the following clause:19.507(e)

LIMITATIONS ON SUBCONTRACTING (MAR 2020)

This clause does not apply to the unrestricted portion of a partial set-aside.(a)

. This clause applies only to-(b) Applicability

Contracts that have been set aside for small business concerns or 8(a) participants;(1)

Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; (2)

Orders set aside for small business concerns or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(3) (i)(F); and

Orders issued directly to small business concerns or 8(a) participants under multiple-award contracts as described in 19.504(c)(1)(ii).(4)

By submission of an offer and execution of a contract, the Contractor agrees that in performance of the (c) Limitations on subcontracting.

contract in the case of a contract for-

. At least 50 percent of the cost of contract performance incurred for personnel shall be expended for (1) Services (except construction) employees of the concern.

. The concern shall perform work for at least 50 percent of (2) Supplies (other than procurement from a nonmanufacturer of such supplies) the cost of manufacturing the supplies, not including the cost of materials.

. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its (3) General construction own employees.

. The concern will perform at least 25 percent of the cost of the contract, not including the cost (4) Construction by special trade contractors of materials, with its own employees.

The Contractor shall comply with the limitations on subcontracting as follows:(d)

For contracts, in accordance with paragraph (b)(1) and (2) of this clause-(1)

[ ] Contracting Officer check as appropriate.

By the end of the base term of the contract and then by the end of each subsequent option period; or

By the end of the performance period for each order issued under the contract.

For orders, in accordance with paragraphs (b)(3) and (4) of this clause, by the end of the performance period for the order.(2)

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2020-11

As prescribed in , insert the following clause:19.309(c)(1)

POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

. As used in this clause-(a) Definitions means a contract of more than five years in duration, including options. However, the term does not include contracts that Long-term contract exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

-Small business concern

Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is (1) bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the (2) Affiliates others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (b) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the (1) novation agreement was executed prior to inclusion of this clause in the contract.

Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to (2) include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

For long-term contracts-(3)

Within 60 to 120 days prior to the end of the fifth year of the contract; and(i)

Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.(ii)

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (c) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that (d) corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a (e) construction or service contract, is 500 employees.

Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this (f) clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not (g) required to, take the actions required by paragraphs (f) or (h) of this clause.

If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code (h) applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it is, is not a small business concern under NAICS Code assigned to contract number .(1) ____ ____

[ .] The Contractor (2) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause represents that it is, is not, a small disadvantaged business concern as defined in .13 CFR 124.1002

[ ] The Contractor (3) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a women-owned small business concern.

Women-owned small business (WOSB) concern eligible under the WOSB Program. [(4) Complete only if the Contractor represented itself ] The Contractor represents that-as a women-owned small business concern in paragraph (h)(3) of this clause.

It is, is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(4)(ii) 13 CFR part 127

(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:____ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

Economically disadvantaged women-owned small business (EDWOSB) concern.[(5) Complete only if the Contractor represented itself as a ] The Contractor represents that-women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.

It is, is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(5)(ii) 13 CFR part 127

(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: .] Each EDWOSB concern participating in the joint ____ venture shall submit a separate signed copy of the EDWOSB representation.

[ ] The Contractor (6) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a veteran-owned small business concern.

[ ] The (7) Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.

Contractor represents that it is, is not a service-disabled veteran-owned small business concern.

[ ] The Contractor (8) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that-

It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone (i) Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in (ii) paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small ____ business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[ ] Contractor to sign and date and insert authorized signer's name and title.

(End of clause)

52.219-28 Alternate I Post-Award Small Business Program Rerepresentation. (Alternate I) 2020-11

As prescribed in , insert the following clause:19.309(c)(1)

POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

. As used in this clause-(a) Definitions means a contract of more than five years in duration, including options. However, the term does not include contracts that Long-term contract exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

-Small business concern

Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is (1) bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the (2) Affiliates others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (b) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the (1) novation agreement was executed prior to inclusion of this clause in the contract.

Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to (2) include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

For long-term contracts-(3)

Within 60 to 120 days prior to the end of the fifth year of the contract; and(i)

Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.(ii)

If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the (c) Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that (d) corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a (e) construction or service contract, is 500 employees.

Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this (f) clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not (g) required to, take the actions required by paragraphs (f) or (h) of this clause.

If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code (h) applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it is, is not a small business concern under NAICS Code assigned to contract number .(1) ____ ____

[ .] The Contractor (2) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause represents that it is, is not, a small disadvantaged business concern as defined in .13 CFR 124.1002

[ ] The Contractor (3) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a women-owned small business concern.

Women-owned small business (WOSB) concern eligible under the WOSB Program. [(4) Complete only if the Contractor represented itself ] The Contractor represents that-as a women-owned small business concern in paragraph (h)(3) of this clause.

It is, is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(4)(ii) 13 CFR part 127

(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:____ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

Economically disadvantaged women-owned small business (EDWOSB) concern.[(5) Complete only if the Contractor represented itself as a ] The Contractor represents that-women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.

It is, is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB (i) Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

It is, is not a joint venture that complies with the requirements of , and the representation in paragraph (h)(5)(ii) 13 CFR part 127

(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: .] Each EDWOSB concern participating in the joint ____ venture shall submit a separate signed copy of the EDWOSB representation.

[ ] The Contractor (6) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that it is, is not a veteran-owned small business concern.

[ ] The (7) Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.

Contractor represents that it is, is not a service-disabled veteran-owned small business concern.

[ ] The Contractor (8) Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

represents that-

It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone (i) Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in (ii) paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small ____ business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[ ] Contractor to sign and date and insert authorized signer's name and title.

(End of clause)

. As prescribed in 19.309(c)(2), substitute the following paragraph (h)(1) for paragraph (h)(1) of the basic clause:Alternate I (MAR 2020)

(h)(1) The Contractor represents its small business size status for each one of the NAICS codes assigned to this contract.

NAICS Code Small business concern (yes/no)

[ ]Contracting Officer to insert NAICS codes.

52.225-9 Buy American-Construction Materials. 2021-02

As prescribed in , insert the following clause:25.1102(a)

BUY AMERICAN-CONSTRUCTION MATERIALS (FEB 2021)

. As used in this clause-(a) Definitions

-Commercially available off-the-shelf (COTS) item

Means any item of supply (including construction material) that is-(1)

A commercial item (as defined in paragraph (1) of the definition at Federal Acquisition Regulation (FAR) 2.101);(i)

Sold in substantial quantities in the commercial marketplace; and(ii)

Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in (iii) the commercial marketplace; and

Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.(2)

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.

However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

-Cost of components means

For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the (1) construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation (2) costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

means-Domestic construction material

For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-(1)

An unmanufactured construction material mined or produced in the United States; or(i)

A construction material manufactured in the United States, if-(ii)

The cost of its components mined, produced, or manufactured in the United States exceeds 55 percent of the cost of all its (A) components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

The construction material is a COTS item; or(B)

For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material (2) manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, Fastener rivets, nails, clips, and screws.

means a construction material other than a domestic construction material.Foreign construction material means iron or steel products not produced in the United States. Produced in the United States means that all Foreign iron and steel manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

means that the cost of the iron and steel content exceeds 50 percent of the total cost of Predominantly of iron or steel or a combination of both all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.Steel

"United States" means the 50 States, the District of Columbia, and outlying areas.

Domestic preference. (b) This clause implements 41 U.S.C.chapter 83, Buy American, by providing a preference for domestic construction (1) material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

This requirement does not apply to information technology that is a commercial item or to the construction materials or components (2) listed by the Government as follows:

[Contracting Officer to list applicable excepted materials or indicate "none"]None

The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government (3) determines that-

The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to (i) the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

The application of the restriction of the Buy American statute to a particular construction material would be impracticable or (ii) inconsistent with the public interest; or

The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available (iii) commercial quantities of a satisfactory quality.

Request for determination of inapplicability of the Buy American statute. (c) (1) Any Contractor request to use foreign construction material (i) in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

A description of the foreign and domestic construction materials;(A)

Unit of measure;(B)

Quantity;(C)

Price;(D)

Time of delivery or availability;(E)

Location of the construction project;(F)

Name and address of the proposed supplier; and(G)

A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this (H) clause.

A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the (ii) format in paragraph (d) of this clause.

The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a (iii) duty-free certificate may be issued).

Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably (iv) foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer (2) and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material.