Solicitation Amendment N4215826Q00260001 SF 30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form Continuation

The following changes have been made:

INFORMATION FROM TO

Response Due Date 04 Aug 2026 27 Aug 2026

N4215826Q00260001

Continuation of Supplies or Services and Prices/Costs

The following CLIN(s) / SLIN(s) / ELIN(s) were added:

Item Supplies / Services Quantity Unit Unit Price Amount Option Line Item

Option Period for completion of HPACs.

Product Service Code: J039 Pricing Arrangement: Firm Fixed Price

30 Days

The following CLIN(s) / SLIN(s) / ELIN(s) were modified:

INFORMATION FROM TO

Description Provide technical support services in support of HPAC #1

Provide technical support services in support of HPAC #1 - #3

INFORMATION FROM TO

Description Provide technical support services in support of HPAC #2

Unplanned Material

Unit of Measure Job Group Product Service Code J039

The following CLIN(s) / SLIN(s) / ELIN(s) were deleted:

Item Supplies / Services Quantity Unit Unit Price Amount

Provide technical support services in support of HPAC #3 Pricing Arrangement: Firm Fixed Price

1 Job

Continuation of Inspection and Acceptance

The inspection and acceptance locations for the following CLIN(s) / SLIN(s) / ELIN(s) were added:

Option Line Item 1001 Acceptance Location - N42158 - N42158

INFORMATION VALUE

Action Acceptance Location Destination

Acceptance Location

N42158 N42158

1 NORFOLK NAVAL SHIPYARD BUILDING 276

PORTSMOUTH, VA 23709-1001

UNITED STATES

Instructions IAWSOW POC Name Nancy Wilson POC Email nancy.h.wilson.civ@navy.mil POC Telephone (757) 810-4936

Inspection Location - N42158 - NORFOLK NAVAL SHIPYARD GF

INFORMATION VALUE

Action Inspection Location Destination

Acceptance Location

N42158

NORFOLK NAVAL SHIPYARD GF

1 NORFOLK NAVAL SHIPYARD, BUILDING 276

PORTSMOUTH, VA 23709-1001

UNITED STATES

Instructions IAWSOW POC Name Nancy Wilson POC Email nancy.h.wilson.civ@navy.mil POC Telephone (757) 810-4936

The inspection and acceptance locations for the following CLIN(s) / SLIN(s) / ELIN(s) were deleted:

Acceptance Location - N42158 - N42158 Inspection Location - N42158 - NORFOLK NAVAL SHIPYARD GF

Continuation of Deliveries or Performance

The delivery information for the following CLIN(s) / SLIN(s) / ELIN(s) were added:

Place of Performance - N42158 - NORFOLK NAVAL SHIPYARD GF

INFORMATION VALUE

Address

Place of Performance N42158

NORFOLK NAVAL SHIPYARD GF

1 NORFOLK NAVAL SHIPYARD, BUILDING 276

PORTSMOUTH, VA 23709-1001

UNITED STATES

POC Name TBD POC Email TBD POC Telephone TBD Delivery Delivery Period PeriodStart = 17 Aug 2026. PeriodEnd = 06 Jan 2027.

Option Line Item 1001

INFORMATION VALUE

Period of Performance 17 Aug 2026 to 06 Jan 2027

Service Performance Site - N42158 - NORFOLK NAVAL SHIPYARD GF

INFORMATION VALUE

Address

Service Performance Site N42158

NORFOLK NAVAL SHIPYARD GF

1 NORFOLK NAVAL SHIPYARD, BUILDING 276

PORTSMOUTH, VA 23709-1001

UNITED STATES

POC Name TBD POC Email TBD POC Telephone TBD Delivery Delivery Period PeriodStart = 17 Aug 2026. PeriodEnd = 06 Jan 2027.

The delivery information for the following CLIN(s) / SLIN(s) / ELIN(s) were deleted:

Service Performance Site - N42158 - NORFOLK NAVAL SHIPYARD GF

Period of Performance Service Performance Site - N42158 - NORFOLK NAVAL SHIPYARD GF

Addendum to Contract Clauses

Contract Clauses

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Full Text

52.217-8 Option to Extend Services. (Nov 1999)

OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within [insert the period of time within which the Contracting Officer may exercise the option].30

(End of clause)

52.217-9 Option to Extend the Term of the Contract. (Mar 2000)

OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within [insert the period of time within which the 30 Contracting Officer may exercise the option]; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least days[ ] before the contract expires. The preliminary notice does not commit the 30 60days unless a different number of days is inserted Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed (months) (years).1 month

(End of clause)

52.252-2 Clauses Incorporated by Reference. (Feb 1998)

CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR Clauses: https://www.acquisition.gov/far-overhaul/far-part-deviation-guide DFARS Clauses: https://www.acq.osd.mil/dpap/dars [Insert one or more Internet/dfars_far_overhaul_class_deviations.html NMCARS: https://www.secnav.navy.mil/rda/DASN-P/Pages/NMCARS.aspx addresses]

(End of clause)

52.252-6 Authorized Deviations in Clauses. (Nov 2020)

AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any [insert regulation name] (48 Defense Acquisition Regulations System, Department of Defense CFR ) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.2

(End of clause)

Additional Regulation or Supplemental Clauses Incorporated by Full Text

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018) (Oct 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee's name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office via the COR by 15 January for the previous calendar year, even if no work related injuries or , illnesses occurred. If a contractor's injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Safety Office points of contacts are as follows:

TBD

(End of Text)

G-242-H002HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (JUL 2021)(Jul 2021)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods. Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor's expense with no cost or liability to the U.

S. Government.

(b) The federal Government observes public Holidays that have been established under 5 U.S.C. 6103. The actual date of observance for each of the holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/.

N4215826Q00260001 https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/ https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company's established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

Norfolk Naval Shipyard Receiving Office, Bldg. 276 0720 1550

(g) All deliveries to the Receiving Officer, Norfolk Naval Shipyard Receiving Office, Bldg. 276 ,shall be made Monday through Friday from to , local time. Deliveries will not be accepted after . No deliveries will be accepted on federal government holidays.0720 1550 1550

(End of Text)

The following clauses were deleted:

Other Clauses

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018) (Oct 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee's name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office via the COR by 15 January for the previous calendar year, even if no work related injuries or , illnesses occurred. If a contractor's injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Safety Office points of contacts are as follows:

__________________________ [insert name and code]

(End of Text)

G-242-H002HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (JUL 2021)(Jul 2021)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods. Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor's expense with no cost or liability to the U.

S. Government.

(b) The federal Government observes public Holidays that have been established under 5 U.S.C. 6103. The actual date of observance for each of the holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company's established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

[ ] [ ]insert specific Departments insert times

(g) All deliveries to the Receiving Officer, [ Negotiator insert delivery location],shall be made Monday through Friday from [ ] to [ ], local time. Deliveries will not be accepted after Negotiator enter beginning hour of operation Negotiator enter closing hour of operation

[ ]. No deliveries will be accepted on federal government holidays.Negotiator enter closing hour of operation

(End of Text)

N4215826Q00260001 https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/ https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays

52.217-7 VAR IOPTION FOR INCREASED QUANTITY—SEPARATELY PRICED LINE ITEM (MAR

1989) (NAVSEA VARIATION I) (OCT 2018)(Oct 2018)

The Government may require the delivery of the numbered line item(s)/subline item(s), identified in the Schedule as an option item(s), in the quantity and at the price(s) stated in the Schedule. If more than one option exists, the Government has the right to unilaterally exercise any such option, in whole or in part up to the total quantity specified in the option item, whether or not it has exercised other options. Option(s) shall be exercised, if at all, by written or telegraphic notice(s) signed by the Contracting Officer and sent within the time(s) specified below:

ITEM(S) LATEST OPTION EXERCISE DATE

0001 1 Days from POP end date

0002 1 Days from POP end date

0003 1 Days from POP end date

(End of Clause)

52.217-9 VAR IIOPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000) (NAVSEA

VARIATION II) (OCT 2018)(Oct 2018)

(a) The Government may extend the term of this contract by written notice(s) to the Contractor within the periods specified below. If more than one option exists, the Government has the right to unilaterally exercise any such option whether or not it has exercised other options.

ITEMS LATEST OPTION EXERCISE DATE

0001 1 day before POP end date

0002 1 day before POP end date

0003 1 day before POP end date

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any option(s) under this clause, shall not exceed five (5) years, however, in accordance with paragraph (g)(ii) of the requirement of this contract entitled "Level of Effort", if the total manhours delineated in paragraph (a) of the Level of Effort requirement, have not been expended within the period specified above, the Government may require the Contractor to continue to perform the work until the total number of manhours specified in paragraph (a) of the aforementioned requirement have been expended.

(End of Clause)

List of Contract Documents, Exhibits, or Attachments

The following attachments were added:

STATEMENT OF WORK (SOW)

The following attachments were deleted:

SOW (OFFICIAL) - HPAC #1, #2, and #3 offical with removal

Addendum to Solicitation Provisions

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Full Text

52.252-1 Solicitation Provisions Incorporated by Reference. (Feb 1998)

SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

FAR Clauses: https://www.acquisition.gov/far-overhaul/far-part-deviation-guideDFARS Clauses: https://www.acq.osd.mil/dpap/dars /dfars_far_overhaul_class_deviations.htmlNMCARS: https://www.secnav.navy.mil/rda/DASN-P/Pages/NMCARS.aspx[NMCARS: https://www.

secnav.navy.mil/rda/DASN-P/Pages/NMCARS.aspx[Insert one or more Internet addresses]

(End of provision)

52.252-5 Authorized Deviations in Provisions. (Nov 2020)

AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any [insert regulation name](48 CFR Chapter ) Defense Acquisition Regulations System, Department of Defense 2 provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

1 NORFOLK NAVAL SHIPYARD, BUILDING 276

PORTSMOUTH, VA 23709-1001

UNITED STATES

Theresa Clark, Email: theresa.m.clark36.civ@us.navy.mil Telephone: 757-396-8345 AdminBy:

SCD: PAS:

1. Extend the closing date to 8/21/2026.

2. Include a revised Statement of Work.

3. Revised CLIN Restructure.