Sol_140P2023R0087.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Donna Prock 0000000000

1x 08/23/2023

140P2023R0087

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

CAHA 249093-This design-build project will replace the obsolete trailer housing at

Cape Hatteras. This project includes the design, construction, demo costs, and supervision to replace trailer units at the Cape Hatteras Island District housing area with a Commercial Off the Shelf Housing Solution.

a) This acquisition is being conducted via a competitive 8(a) set aside. The North

American Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation.

b) The design and construction budget is $6.3M.

c) The Government will follow the two-phase design-build selection process described in FAR 36.301 in order to select a design-build contractor.

d) The submission requirements for the different phases are detailed in Section L of the RFP. A maximum of three (3) offerors shall be selected to move forward to Phase

2. It is anticipated that a negotiated firm-fixed price contract will be awarded requiring submission of both a technical and price proposal. The Government will consider an offeror's technical capability in comparison to its price.

e) This is currently an unfunded requirement with a high expectation that funds will be available. When funds become available a contract will be awarded at that time.

Continued ...

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 548 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR 52.211-10

10/02/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 8/2014)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, DSC Contracting Services Div 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Bai Perney

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 8/2014) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 72

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P2023R0087

Project Team

CO: Bai Perney

CS: Donna Prock

PM: Lawrence Mason (COR)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation

08/23/2023

Document No.

140P2023R0087 Document Title CAHA 249093 Replace Hatteras Island District Obsolete Trailers

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246‐12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211‐10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211‐12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211‐13 TIME EXTENSIONS (SEPT 2000)

52.242‐14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201‐70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204‐70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS ‐ CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM (APR 2013)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: KEY PERSONNEL

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

1452.203‐70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

52.203‐17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM EMPLOYEES OF

WHISTLEBLOWER RIGHTS (JUN 2020)

52.204‐23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES DEVELOPED OR

PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (NOV 2021)

52.204‐25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES AND EQUIPMENT (NOV 2021)

1452.215‐70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984)

52.219‐14 LIMITATIONS ON SUBCONTRACTING (OCT 2022) (DEVIATION OCT 2022)

52.219‐17 SECTION 8(A) AWARD (OCT 2019)

52.219‐18 NOTIFICATION OF COMPETITION LIMITED TO ELIGIBLE 8(A) PARTICIPANTS. (OCT 2022)

Document No.

140P2023R0087 Document Title

52.223‐9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA‐ DESIGNATED PRODUCTS—

ALTERNATE I (MAY 2008)

52.225‐9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

1452.228‐70 LIABILITY INSURANCE. (JUL 1996)

52.236‐1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236‐2 DIFFERING SITE CONDITIONS (APR 1984)

52.236‐3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236‐4 PHYSICAL DATA (APR 1984)

52.236‐5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236‐6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236‐7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236‐8 OTHER CONTRACTS (APR 1984)

52.236‐9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS (APR

1984)

52.236‐10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236‐11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236‐12 CLEANING UP (APR 1984)

52.236‐13 ACCIDENT PREVENTION (NOV 1991)

52.236‐14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236‐15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236‐17 LAYOUT OF WORK. (APR 1984)

52.236‐21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) ALTERNATE II (APR1984)

52.236‐26 PRECONSTRUCTION CONFERENCE (FEB 1995)

1452.236‐70 PROHIBITION AGAINST USE OF LEAD‐BASED PAINT (JUL 1996)

52.252‐2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252‐6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.229-11TAX ON CERTAIN FOREIGN PROCUREMENTS – NOTICE AND REPRESENTATION (JUN 2020)

52.204‐8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

Document No.

140P2023R0087 Document Title

52.204‐24 REPRESENTATIONS REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES

AND EQUIPMENT (NOV 2021)

52.204‐26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES‐REPRESENTATION (OCT 2020)

52.204‐27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

52.209‐7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209‐13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS‐CERTIFICATION (NOV 2021)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.211‐3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS. (JUNE 1988)

1452.215‐71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE INTERIOR (APR 1984) ... 51

52.216‐1 TYPE OF CONTRACT (APR 1984)

52.222‐23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY

FOR CONSTRUCTION (FEB 1999)

52.225‐10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY 2014)

52.228‐1 BID GUARANTEE (SEP 1996)

52.233‐2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (SEPT 2006) (DEVIATION) (JUL 1996)

52.252‐1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.236‐27 SITE VISIT (CONSTRUCTION) – ALTERNATE I (FEB 1995)

52.252‐5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION – COMPETITIVE SOURCE SELECTION 57

SECTION L ‐ INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION – COMPETITIVE SOURCE

SELECTION

E. VOLUME I, TECHNICAL PROPOSAL – FORMAT, ORGANIZATION, CONTENTS

PHASE 1 – TECHNICAL PROPOSAL:

PHASE 2 – TECHNICAL AND BUSINESS PROPOSALS:

PHASE 2- VOLUME 2 – BUSINESS & PRICE PROPOSAL – FORMAT, ORGANIZATION, CONTENTS

SECTION M – EVALUATION FACTORS FOR AWARD

Document No.

140P2023R0087 Document Title

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

SECTION B – BID SCHEDULE

CONTRACT PRICE SCHEDULE

SOLICITATION NUMBER: 140P2023R0087

PARK - PMIS: CAHA 249093

PROJECT TITLE: Replace Hatteras Island District Obsolete Trailers

Offerors are required to submit, at a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable.

On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of summation error, the total corrected amounts govern. Round totals & extended prices to whole dollars.

CONTRAC

T LINE-

ITEM

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI)

TITLE

QTY

UNIT OF

MEASUR

E

UNIT

PRICE

TOTAL

PRICE

Residence #1, 3BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #2, 3BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #3, 3BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Document No.

140P2023R0087 Document Title

Residence #4, 3BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #5, 3BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #6, 3BR/2BA, ABA Accessible (Base Bid) DESIGN:

DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #7, 4BR/2BA (Base Bid)

DESIGN: DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #8, 4BR/2BA, ABA Accessible (Base Bid) DESIGN:

DEMO, SITE, UTILITIES,

FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

TOTAL BASE PRICE (Contract Line-Item Number 1 through 15) $

Residence #9, 3BR/2BA (Optional Bid) DESIGN: DEMO, SITE, UTILITIES, FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #10, 3BR/2BA (Optional Bid) DESIGN: DEMO, SITE, UTILITIES, FOUNDATION, BUILDING

1 LS $ $

Document No.

140P2023R0087 Document Title

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #11, 3BR/2BA (Optional Bid) DESIGN: DEMO, SITE, UTILITIES, FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

Residence #12, 4BR/2BA (Optional Bid) DESIGN: DEMO, SITE, UTILITIES, FOUNDATION, BUILDING

1 LS $ $

CONSTRUCT: DEMO, SITE,

UTILITIES, FOUNDATION,

BUILDING

1 LS $ $

TOTAL PRICE FOR ALL OPTIONS (Contract Line-Item Number 16 through 23)

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line-Item Number 1 through 23)

SECTION C – SPECIFICATIONS / DRAWINGS

This design-build project will replace the obsolete trailer housing at Cape Hatteras.

Project Location: Dare County, Cape Hatteras, Buxton, NC

This project includes the site-adapted design, construction, demolition, and supervision to replace existing modular housing units at the Cape Hatteras Island District housing area with commercial off-the-shelf modular housing units or an equivalent pre-designed conventional housing. Utilities (water and electric) are already in place for connection and new housing units will tie into the existing septic system. The new housing units will include three and four bedrooms each with two bathrooms each.

Two housing units must be ABA compliant. All units will be equipped with a residential fire suppression system to meet current safety codes.

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

SECTION D – PACKING AND MARKING

No clauses included.

Document No.

140P2023R0087 Document Title

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

Document No.

140P2023R0087 Document Title

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 548 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,457.21 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

Document No.

140P2023R0087 Document Title

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting

Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

Document No.

140P2023R0087 Document Title

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph

(e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM

(DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO).

Document No.

140P2023R0087 Document Title

Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating

"No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of Notice)

Document No.

140P2023R0087 Document Title

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(APR 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract. The IPP website address is: https://www.ipp.gov.

The contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the contractor. If the CMR recommends acceptance, the contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP)

2. Completed copy of the Pay Estimate Form (including signed certification of subcontractor payments)

3. Completed copy of the Limitations on Subcontracting Report

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts

5. A copy of the current construction schedule (refer to project specification section 013216)

6. A copy of the current Schedule of Values. (refer to project specification section 013216)

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment.

The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause)

Document No.

140P2023R0087 Document Title

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

1. Lead Designer*: __________________________________________________________ [Provide designer of record AE Firm name and individual name]

2. Project Manager: _________________________________________________________

3. Job-site Superintendent:

4. On-Site Quality Control Manager**:

5. On-Site Safety Manager**:

The Lead Designer must be an individual that meets the licensing requirements in Special Requirement 4 herein, and may not hold any other key personnel position. The Lead Designer* must be the same individual and with the same AE Firm submitted in the offeror’s proposal and may not be substituted.

(See Section L, Evaluation Factors for definition of “AE”).

For positions 2 – 5, each position may be filled by a separate individual; however, the On-Site Quality Control Manager** and the On-Site Safety Manager** may be filled by the same qualified individual.

Therefore, for positions 2 - 5, at least three (3) individuals are required for Key Personnel.

The Job Site Superintendent, On-Site Quality Control Manager, and the On-Site Safety Manager are required to be on-site during all work activities under the Contract.

(b) During the first 120 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 120 -day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

Document No.

140P2023R0087 Document Title

SPECIAL REQUIREMENT 2: KEY TRADES

(a) The Contractor shall identify firms that will perform the following KEY TRADES under this contract. If Key Trades will be self-performed, note “self-performed” in the appropriate trade; otherwise provide the name(s) of assigned subcontractors.

Earthwork/Civil Subcontractor: _______________________ Mechanical Services: _______________________ Electrical Services: _______________________ Other: _______________________

(b) The assignments above are permanent for the contract duration. The Contractor shall make no substitutions of the above listed Key Trade assignments unless the substitution is approved or directed by the Contracting Officer. The Contractor shall send requests for substitutions to the Contracting Officer a minimum of 15 calendar days prior to any substitution and provide the information required by paragraph (c) below.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete qualification statements for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes shall have comparable qualifications to the firm being replaced. The Contracting Officer will approve or deny substitution requests within 15 calendar days after receipt of all required information. This clause will be modified to reflect any approved changes.

(End of Local Clause)

SPECIAL REQUIREMENT 3: RESPONSIBILITY

(a) The Contractor shall be responsible for the professional quality, technical accuracy, and the coordination of all designs, drawings, specifications, and other services furnished by the Contractor under this contract. The Contractor shall, without additional compensation, correct or revise any errors or deficiencies in its designs, drawings, specifications, and other services.

(b) Neither the Government’s review, approval or acceptance of, nor payment for, the services required under this contract shall be construed to operate as a waiver of any rights under this contract or of any cause of action arising out of the performance of this contract, and the Contractor shall be and remain liable to the Government in accordance with applicable law for all damages to the Government caused by the Contractor’s negligent performance of any of the services furnished under this contract.

(c) The rights and remedies of the Government provided for under this contract are in addition to any other rights and remedies provided by law.

(d) If the Contractor is comprised of more than one legal entity, each such entity shall be jointly and severally liable hereunder.

(End of Local Clause)

SPECIAL REQUIREMENT 4: REGISTRATION REQUIREMENTS OF DESIGNERS

Architects or engineers registered to practice in the particular professional field involved in a State, the District

Document No.

140P2023R0087 Document Title of Columbia, or an outlying area of the United States shall prepare or review and approve the design of architectural, structural, mechanical, electrical, civil, or other engineering features of the work.

(End of Local Clause)

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN

2020)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS

OR STATEMENTS (JAN 2017)

52.204-4 PRINTED OR COPIED DOUBLE SIDED ON POSTCONSUMER FIBER CONTENT PAPER

(MAY 2011)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV

2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUNE 2023)

Document No.

140P2023R0087 Document Title

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH

CONTRACTOR’S DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (NOV

2021)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY

MATTERS (OCT 2018)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (NOV

2015)

52.215-2 AUDIT AND RECORDS-NEGOTIATIONS (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—

MODIFICATIONS (JUN 2020)

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (JUN 2020)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB)

OTHER THAN PENSIONS (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN

CERTIFIED COST OR PRICING DATA—MODIFICATIONS (NOV 2021)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (MAR 2020)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT 2022)

52.219-28 POST AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAR 2023)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION

(MAR 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION - DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIREMENTS AND RELATED

REGULATIONS (MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 EQUAL OPPORTUNITY (SEP 2016)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APRIL

2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

Document No.

140P2023R0087 Document Title

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (MAY 2022)

52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 14026 (JAN 2022)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2022)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING

(JUN 2020)

52.223-21 FOAMS (JUN 2016)

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JUN 2020)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 PLEDGES OF ASSETS (FEB 2021)(DEVIATION MAY 2023)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020)(DEVIATION MAY

2023)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT

(OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS CONTRACTORS (MAR

2023)

52.233-1 DISPUTES (MAY 2014) – ALTERNATE 1 (DEC 1991)

Document No.

140P2023R0087 Document Title

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (MAR 2023)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING – CONSTRUCTION (OCT 2020)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012),

ALT 1 (SEP 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205–1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

(End of clause)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (JUN 2020)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C.

4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and Federal Acquisition Regulation (FAR) 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section FAR 3.908.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold, as defined in FAR 2.101 on the date of subcontract award.

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (NOV 2021)

(a) Definitions. As used in this clause—

Covered article means any hardware, software, or service that–

(1) Is developed or provided by a covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a covered entity; or

Document No.

140P2023R0087 Document Title

(3) Contains components using any hardware or software developed in whole or in part by a covered entity.

Covered entity means–

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab;

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any covered article. The Contractor is prohibited from—

(1) Providing any covered article that the Government will use on or after October 1, 2018; and

(2) Using any covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractor identifies a covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 1 business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a covered article, any reasons that led to the use or submission of the covered article, and any additional efforts that will be incorporated to prevent future use or submission of covered articles.

(d) Subcontracts.