Sol_140FC224Q0003.pdf

140FC224Q0003

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

11/14/2023 0040642523

1 37

FWS, Construction A/E Team 2 5275 Leesburg Pike Falls Church VA 22041

FWS Constr A/E 2 12/28/2023

FWS ST CROIX WMD

1764 95TH STREET

NEW RICHMOND

WI 54017-6306

612 713-5215Jeanne Mohlis

11/28/2023 1300 CS

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

Period of Performance: 11/28/2023 to 12/28/2023

00010 Construct RV Pad per attached drawings, specifications, and wage determination.

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

A - Solicitation/Contract Form Clauses B - Supplies or Services/Prices……………………………………………………………………………… 1 Clauses E - Inspection and Acceptance ………………………………………………………………… 1 Clauses F - Deliveries or Performance Clauses G - Contract Administration Data Clauses H - Special Contract Requirements Clauses I - Contract Clauses Clauses J - List of Documents, Exhibits, and Other Attachments Clauses K - Representations, Certifications, and Other Statements of Bidders Clauses L - Instructions, Conditions, and Notices to Bidders Clauses

A – Contract Form Clauses Solicitation

B- Supplies or Services/Prices

144805.26 Bid Schedule (MAY 1997)

The bid schedule for this project is included as a separate document as listed in Section J, List of Documents, Exhibits, and Other Attachments. Electronic offers of proposals or modifications to proposals will ONLY be accepted.

BOND REQUIREMENTS: In accordance with FAR 52.228-1 and 52.228-2, the bond requirements for proposals are 20% of the proposal price but shall not exceed $3 million. 100% performance and payment bond is required.

E - Inspection and Acceptance

52.246-12 Inspection of Construction. (AUG 1996)

F – Deliveries or Performance Clauses

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 calendar days after the date the contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages-Construction. (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $96.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 Time Extensions (SEP 2000)

52.242-14 Suspension of Work. (APR 1984)

144805.10 Material Approval Submittals (MAY 1997)

The submittals contemplated by the clause entitled, "Materials and Workmanship" shall be accomplished on Form R3-124, Transmittal of Shop Drawings, Equipment Data, Material Samples, or Manufacturer's Certificates of Compliance for Approval.

Any requirement for the contractor to submit certificates, manufacturing brochures, etc. shall be submitted in five (5) copies. Submittals shall be made at least ten (10) days before items are incorporated in the work and in all instances within 30 days of award. Submittals will normally be approved/disapproved within seven (7) calendar days after submission. Incorporation of materials in a project prior to receipt of approved submittals shall be solely at the risk of the contractor.

G - Contract Administration Data

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S.

Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP: Invoice, Davis Bacon Payrolls for the payment period requested.

Please send a copy of invoice(s) and payrolls to Jeanne_mohlis@fws.gov The Contractor must use the IPP website to register access and use IPP for submitting http://www.ipp.gov/ mailto:Jeanne_mohlis@fws.gov requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

144805.04 Prompt Payment Act (MAY 1997)

(a) PROGRESS PAYMENTS - Pursuant to FAR 52.232-5 entitled, "Payments Under

Fixed-Price Construction Contracts", the contractor shall be entitled to payments on the basis of the amount of work satisfactorily complete in each thirty (30) day period, less retainage.

(1) At the close of each thirty (30) day period, the Contractor or his agent shall consult with the Inspector for the purpose of arriving at an agreed percentage of work completed. (The Contractor shall be responsible for arranging this meeting.)

(2) After the Inspector and Contractor have agreed on the percentage of work completed, the Contractor shall submit his invoice to the Contracting Officer.

(3) Failure to consult with the Inspector prior to submission may be cause for rejection of the invoice.

(b) FINAL PAYMENT - Pursuant to Special Contract Requirements entitled, "Final Inspection," all deficiencies noted shall be corrected prior to final payment.

144805.08 Appointment of Contracting Officer’s Technical Representative (MAY 1997)

(a) The Contracting Officer may designate individuals to act as the Contracting Officer's Technical Representative (COTR) under this contract. Such designation shall be by written letter of appointment. The appointment shall be for purposes of technical surveillance of work being performed under this contract.

(b) The COTR will function as a liaison between the contractor and the Government. The presence or absence of the COTR or inspector shall not be deemed to relieve the contractor from any requirements of this contract.

(c) The duties, responsibilities and limitations of the COTR are as follows:

(1) The COTR is authorized to take any action with respect to the following that could lawfully be taken by the Contracting Officer unless specifically prohibited by the terms of this contract.

Such duties include:

mailto:ippgroup@bos.frb.org

(i) Verifying that the contractor performs the technical requirement of this contract in accordance with its terms, conditions, and specifications.

(ii) Performing, or causing to be performed, inspections necessary in connection with 3(a)(i) above and verifying that the contractor has corrected any noted deficiencies.

(iii) Monitoring the contractor's performance, notifying the contractor of deficiencies observed during surveillance and directing appropriate corrective action.

(iv) Recording and reporting to the Contracting Officer incidents of faulty or non-conforming performance, work delays or problems.

(v) Coordinating site entry for contractor personnel.

(vi) Ensuring that Government-furnished property (if any) is timely available.

(vii) Maintaining liaison and direct communications with the contractor.

(2) The following limitations are placed on the authority of the COTR:

The COTR is not empowered to award, agree to, or sign any contract (including delivery or purchase orders) or modifications thereto.

The COTR may not obligate the payment of money or approve items of cost not specifically authorized by this contract.

The COTR may not take any action which may impact on contract or delivery order schedules, funds, or scope. All contractual agreements, commitments, or modifications, must be effected by the Contract Officer.

The COTR may not render a decision on any dispute or any question of fact under the Disputes Clause of the contract.

The COTR may not take any action with respect to termination, except to notify the Contracting Officer of circumstances which would appear to warrant such action.

1452.201-70 AUTHORITIES AND DELEGATIONS (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.236-71 Additive or Deductive Items (JUL 1996) So that the Government may obtain the most desirable features of work within the limit of its funds available at time of bid evaluation, award may be made to the bidder having the lowest total of the base bid and a combination of additive and deductive items. All bids shall be evaluated on the basis of the same additive and deductive bid items using the order of priority of the items listed in the schedule.

(End of provision)

H – Special Contract Requirements

I – Contract Clauses

52.204-13 System for Award Management Maintenance. (OCT 2018)

52.204-19 Incorporation by Reference of Representations and Certifications (DEC 2014)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021)

52.204-27 Prohibition on a ByteDance Covered Application (Jun 2023)

(a) Definitions. As used in this clause- Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)-

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L.

117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, “No TikTok on Government Devices” Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor’s employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23-13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. (NOV 2015)

52.215-8 Order of Precedence - Uniform Contract Format. (OCT 1997)

52.219-6 Notice of Total Small Business Set-Aside. (NOV 2020)

52.222-3 Convict Labor. (JUN 2003)

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work (MAY 2014)

52.222-6 Construction Wage Rate Requirements. (AUG 2018)

52.222-7 Withholding of Funds. (MAY 2014)

52.222-8 Payrolls and Basic Records. (JUL 2021)

52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (MAY 2014)

52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

(MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (MAY 2014)

52.222-21 Prohibition of segregated facilities. (APR 2015)

52.222-26 Equal Opportunity. (SEP 2016)

52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015)

52.222-36 Equal Opportunity for Workers with Disabilities (JUN 2020)

52.222-50 Combating Trafficking in Persons. (NOV 2021)

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026

(JAN 2022)

(a) Definitions. As used in this clause—

United States means the 50 states, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.).

Worker –

(1) (i) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 14026, and–

(A) Whose wages under such contract are governed by the Fair Labor Standards Act ( 29 U.S.C. chapter 8), the Service Contract Labor Standards statute ( 41 U.S.C. chapter 67), or the Wage Rate Requirements (Construction) statute ( 40 U.S.C. chapter 31, subchapter IV);

(B) Other than individuals employed in a bona fide executive, administrative, or professional capacity, as those terms are defined in 29 CFR part 541; and

(C) Regardless of the contractual relationship alleged to exist between the individual and the employer.

(ii) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).

(iii) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor’s Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.

(2) (i) A worker performs on a contract if the worker directly performs the specific services called for by the contract; and

(ii) A worker performs in connection with a contract if the worker's work activities are necessary to the performance of a contract but are not the specific services called for by the contract.

(b) Executive Order Minimum wage rate. (1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $15.00 per hour beginning January 30, 2022.

http://uscode.house.gov/ http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/

(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2023, and annually thereafter, to meet the applicable annual E.O.

minimum wage. The Administrator of the Department of Labor’s Wage and Hour Division (the Administrator) will publish annual determinations in the Federal Register no later than 90 days before the effective date of the new E.O. minimum wage rate. The Administrator will also publish the applicable E.O. minimum wage on https://www.sam.gov (or any successor website), and a general notice on all wage determinations issued under the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, that will provide information on the E.O. minimum wage and how to obtain annual updates. The applicable published E.O. minimum wage is incorporated by reference into this contract.

(3) (i) The Contractor may request a price adjustment only after the effective date of the new annual E.O. minimum wage determination. Prices will be adjusted only for increased labor costs (including subcontractor labor costs) as a result of an increase in the annual E.O.

minimum wage, and for associated labor costs (including those for subcontractors). Associated labor costs shall include increases or decreases that result from changes in social security and unemployment taxes and workers’ compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.

(ii) Subcontractors may be entitled to adjustments due to the new minimum wage, pursuant to paragraph (b)(2). Contractors shall consider any subcontractor requests for such price adjustment.

(iii) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (b)(3)(i) of this clause, and will not provide duplicate price adjustments with any price adjustment under clauses implementing the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute.

(4) The Contractor warrants that the prices in this contract do not include allowance for any contingency to cover increased costs for which adjustment is provided under this clause.

(5) A pay period under this clause may not be longer than semi-monthly, but may be shorter to comply with any applicable law or other requirement under this contract establishing a shorter pay period. Workers shall be paid no later than one pay period following the end of the regular pay period in which such wages were earned or accrued.

(6) The Contractor shall pay, unconditionally to each worker, all wages due free and clear without subsequent rebate or kickback. The Contractor may make deductions that reduce a worker’s wages below the E.O. minimum wage rate only if done in accordance with 29 CFR 23.230, Deductions.

(7) The Contractor shall not discharge any part of its minimum wage obligation under this clause by furnishing fringe benefits or, with respect to workers whose wages are governed by the Service Contract Labor Standards statute, the cash equivalent thereof.

https://www.sam.gov/

(8) Nothing in this clause shall excuse the Contractor from compliance with any applicable Federal or State prevailing wage law or any applicable law or municipal ordinance or any applicable contract establishing a minimum wage higher than the E.O. 14026 minimum wage. However, wage increases under such other laws or municipal ordinances are not subject to price adjustment under this subpart.

(9) The Contractor shall pay the E.O. minimum wage rate whenever it is higher than any applicable collective bargaining agreement(s) wage rate.

(10) The Contractor shall follow the policies and procedures in 29 CFR 23.240(b) and

23.280 for treatment of workers engaged in an occupation in which they customarily and regularly receive more than $30 a month in tips.

(c) (1) This clause applies to workers as defined in paragraph (a). As provided in that definition–

(i) Workers are covered regardless of the contractual relationship alleged to exist between the contractor or subcontractor and the worker;

(ii) Workers with disabilities whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c) are covered; and

(iii) Workers who are registered in a bona fide apprenticeship program or training program registered with the Department of Labor’s Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship, are covered.

(2) This clause does not apply to–

(i) Fair Labor Standards Act (FLSA)-covered individuals performing in connection with contracts covered by the E.O., i.e. those individuals who perform duties necessary to the performance of the contract, but who are not directly engaged in performing the specific work called for by the contract, and who spend less than 20 percent of their hours worked in a particular workweek performing in connection with such contracts;

(ii) Individuals exempted from the minimum wage requirements of the FLSA under 29 U.S.C. 213(a) and 214(a) and (b), unless otherwise covered by the Service Contract Labor Standards statute, or the Wage Rate Requirements (Construction) statute. These individuals include but are not limited to-

(A) Learners, apprentices, or messengers whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(a) ;

(B) Students whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(b) ; and http://uscode.house.gov/ http://uscode.house.gov/

(C) Those employed in a bona fide executive, administrative, or professional capacity (29 U.S.C. 213(a)(1) and 29 CFR part 541).

(d) Notice. The Contractor shall notify all workers performing work on, or in connection with, this contract of the applicable E.O. minimum wage rate under this clause. With respect to workers covered by the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, the Contractor may meet this requirement by posting, in a prominent and accessible place at the worksite, the applicable wage determination under those statutes. With respect to workers whose wages are governed by the FLSA, the Contractor shall post notice, utilizing the poster provided by the Administrator, which can be obtained at www.dol.gov/agencies/whd/government-contracts, in a prominent and accessible place at the worksite. Contractors that customarily post notices to workers electronically may post the notice electronically provided the electronic posting is displayed prominently on any Web site that is maintained by the contractor, whether external or internal, and customarily used for notices to workers about terms and conditions of employment.

(e) Payroll Records. (1) The Contractor shall make and maintain records, for three years after completion of the work, containing the following information for each worker:

(i) Name, address, and social security number;

(ii) The worker’s occupation(s) or classification(s);

(iii) The rate or rates of wages paid;

(iv) The number of daily and weekly hours worked by each worker;

(v) Any deductions made; and

(vi) Total wages paid.

(2) The Contractor shall make records pursuant to paragraph (e)(1) of this clause available for inspection and transcription by authorized representatives of the Administrator.

The Contractor shall also make such records available upon request of the Contracting Officer.

(3) The Contractor shall make a copy of the contract available, as applicable, for inspection or transcription by authorized representatives of the Administrator.

(4) Failure to comply with this paragraph (e) shall be a violation of 29 CFR 23.260 and this contract. Upon direction of the Administrator or upon the Contracting Officer's own action, payment shall be until such time as the noncompliance is corrected.

(5) Nothing in this clause limits or otherwise modifies the Contractor’s payroll and recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the https://www.acquisition.gov/far/www.dol.gov/agencies/whd/government-contracts

Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, or any other applicable law.

(f) Access. The Contractor shall permit authorized representatives of the Administrator to conduct investigations, including interviewing workers at the worksite during normal working hours.

(g) Withholding. The Contracting Officer, upon his or her own action or upon written request of the Administrator, will withhold funds or cause funds to be withheld, from the Contractor under this or any other Federal contract with the same Contractor, sufficient to pay workers the full amount of wages required by this clause.

(h) Disputes. Department of Labor has set forth in 29 CFR 23.510, Disputes concerning contractor compliance, the procedures for resolving disputes concerning a contractor’s compliance with Department of Labor regulations at 29 CFR part 23. Such disputes shall be resolved in accordance with those procedures and not the Disputes clause of this contract. These disputes include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the Department of Labor, or the workers or their representatives.

(i) Antiretaliation. The Contractor shall not discharge or in any other manner discriminate against any worker because such worker has filed any complaint or instituted or caused to be instituted any proceeding under or related to compliance with the E.O. or this clause, or has testified or is about to testify in any such proceeding.

(j) Subcontractor compliance. The Contractor is responsible for subcontractor compliance with the requirements of this clause and may be held liable for unpaid wages due subcontractor workers.

(k) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (k) in all subcontracts, regardless of dollar value, that are subject to the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, and are to be performed in whole or in part in the United States.

(End of clause)

52.223-5 Pollution Prevention and Right-to-Know Information. (MAY 2011)

52.223-6 Drug-Free Workplace. (MAY 2001)

52.225-9 Buy American – Construction Materials. (OCT 2022)

(a) Definitions. As used in this clause-

Commercially available off-the-shelf (COTS) item-

(1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued);

or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means-

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if-

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 55 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material.

In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph

(d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute or Balance of Payments Program.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction Material Description

Unit of Measure Quantity Price

(Dollars)*

Item 1:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

Item 2:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed.

Attach copy of response; if oral, attach summary. Include other applicable supporting information.

(End of clause)

52.225-13 Restrictions on Certain Foreign Purchases. (FEB 2021)

52.227-4 Patent Indemnity--Construction Contracts. (DEC 2007)

52.228-11 Individual Surety-Pledge of Assets. (FEB 2021)

52.228-13 Alternative Payment Protections. (JUL 2000)

The Contractor shall submit one of the following payment protections:

Payment Bond or Irrevocable Letter of Credit (ILC)

(a) The amount of the payment protection shall be 100 percent of the contract price.

(b) The submission of the payment protection is required within 10 days of contract award.

(c) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(d) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(e) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

52.228-14 Irrevocable Letter of Credit. (NOV 2014)

(b) Amount of required bonds. Unless the resulting contract price is valued at or below the threshold specified in Federal Acquisition Regulation 28.102-1(a) on the date of award of this contract, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds ( Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds ( Standard Form 25A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection.

(i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the:

U.S. Department of the Treasury, Financial Management, Service Surety Bond Branch, 3700 East West Highway, Room 6 F01, Hyattsville, MD 20782.

Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection ( 40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right https://www.acquisition.gov/far/part-28#FAR_28_102_1 https://www.gsa.gov/forms-library/performance-bond https://www.gsa.gov/forms-library/payment-bond http://www.fms.treas.gov/c570/ http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

(End of clause)

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.232-23 Assignment of Claims. (MAY 2014)

52.232-27 Prompt payment for construction contracts. (JAN 2017)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.233-1 Disputes. (MAY 2014)

52.236-1 Performance of Work by the Contractor (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least twelve (12%) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

52.236-2 Differing Site Conditions (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984)

52.236-5 Material and Workmanship. (APR 1984)

52.236-6 Superintendence by the Contractor (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.236-8 Other Contracts. (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984)

52.236-10 Operations and Storage Areas. (APR 1984)

52.236-11 Use and Possession Prior to Completion (APR 1984)

52.236-12 Cleaning Up. (APR 1984)

52.236-13 Accident Prevention. (NOV 1991)

52.236-17 Layout of Work. (APR 1984)

52.236-21 Specifications and Drawings for Construction (FEB 1997) Alternate II (APR 1984)

52.236-26 Preconstruction Conference. (FEB 1995)

52.243-5 Changes and Changed Conditions. (APR 1984)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

1452.201-70 Authorities and Delegations Notice to Contractors (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment. The COR for this contract will be:

Name: TBD Address:

Telephone Number:

Email Address:

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

Waive or agree to modification of the delivery schedule;

Make any final decision on any contract matter subject to the Disputes Clause;

Terminate, for any reason, the Contractor's right to proceed;

Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that is considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the

Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph

(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any actions(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of Notice)

1452.204-70 Release of Claims (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

1452.228-70 Liability Insurance (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension there of liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$200,000 each person* $500,000 each occurrence* $20,000 property damage*

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

J - LIST OF DOCUMENTS, EXHIBITS AND OTHER

Attachments List of Documents, Exhibits, and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

52.203-18 PROHIBITION ON CONTRACTING WITH ENTITIES THAT

REQUIRE CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS- REPRESENTATION (JAN 2017)

a) Definition. As used in this provision-

Internal confidentiality agreement or statement, subcontract, and subcontractor, are defined in the clause at 52.203- 19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

(b) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use funds appropriated (or otherwise made available) for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information.

(c) The prohibition in paragraph (b) of this provision does not contravene requirements applicable to Standard Form 312, (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(d) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with

Attachment Number Title

1 Sow/Specifications 2 Drawings 3 Bid Schedule 4 Safety Checklist 5 STC Table of Contents 6 STC Submittals Report 7 Wage Determination internal confidentiality agreements…