SF 1442 RFP 12441923R0044.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

1091448

USDA FOREST SERVICE

SPOC EAST

1400 INDEPENDENCE AVE SW MS-1138

WASHINGTON DC 20250-0001

JOE LIBBEY 603-217-7154

1x 07/26/2023

12441923R0044

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

This solicitation is a 100 percent competitive HUBZone set-aside.

The U.S. Department of Agriculture (USDA) Forest Service requires a Contractor for the reconstruction of the PR-191 main water distribution system. The work includes installation of approximately three miles of HDPE waterline.

NAICS: 221310- Water Supply and Irrigation Systems Size Standard $41 Million

Product Service Code: S114 Utilities - Water

Magnitude: Between $1,000,000 and $5,000,000

A bid guarantee of 5 percent of the offeror price is required in accordance with FAR provision 52.228-1 Bid Guarantee (SEP 1996)

Please review section H.5 Small Business Administration (SBA) Surety Bonds Guarantee

Program.

This contract is supported by funds from the 0816 Bipartisan Infrastructure Law, Continued ...

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

15 330 calendar days and complete it within ________________ ________________ calendar days after receiving

08/28/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 8/2014)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA FOREST SERVICE

SPOC EAST

1400 INDEPENDENCE AVE SW MS-1138

WASHINGTON DC 20250-0001

JOSH H. CHOI

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 8/2014) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 60

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

12441923R0044 please review H.4 Required Signage for Covered

Construction Contracts.

Site Visit: An organized site visit has been scheduled for August 14, 2023, at 0900AM Eastern

Time. Participants will meet at- El Yunque

National Forest Catalina Headquarters Office

Parking, Rio Grande Municipality, Puerto Rico.

To attend the site visit coordinate with the

Contract Specialist: Joe Libbey at joe.libbey@usda.gov

All site visit and proposal questions are due by

August 18, 2023, at 5:00PM Eastern Time. Submit all questions to Joe Libbey at joe.libbey@usda.gov.

Delivery: 330 Days After Notice to Proceed

Delivery Location Code: 43ZP

USDA FOREST SERVICE

SOUTHERN REGION

1720 PEACHTREE RD SW SUITE 876 SOU

ATLANTA GA 30309-2449 US

Period of Performance: 09/27/2023 to 08/22/2024

0001 PR 191 Rd Waterline Reconstruction Project: The

U.S. Department of Agriculture¿s (USDA) Forest

Service requires a Contractor for the reconstruction of the PR-191 main water distribution system. The work includes installation of approximately three miles of HDPE waterline.

0002 PR 191 Rd Waterline Reconstruction Project:

Option 1 complete all work below the valve near the Sierra Palm bridge to and including the valve below the new 10,000-gallon concrete water storage tank. The work includes the bypass around the new water storage tank with the pressure reducing valve, the new water storage tank, and fencing.

(Option Line Item)

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 60

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

12441923R0044

0003 PR 191 Rd Waterline Reconstruction Project:

Option 2 complete all work below the valve at the new water storage tank to Yokahu Tower. Work includes a side lateral to the Big Tree site.

(Option Line Item)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation: 12441923R0044 Project Title: PR 191 Rd Waterline Reconstruction Project

Table of Contents

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

B.2 SCHEDULE NOTES

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

C.2 PROJECT LOCATION

C.3 MAGNITUDE OF CONSTRUCTION PROJECT

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

F.2 OTHER REQUIREMENTS

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

G.2 CONTRACTING STAFF

SECTION H--SPECIAL CONTRACT REQUIREMENTS

H.1 USE OF PREMISES

H.2 ARCHAEOLOGICAL OR HISTORIC SITES

H.3 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION………………...13

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

J.1 ATTACHMENTS

PART IV-- INSTRUCTIONS

SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR

RESPONDENTS

L.1 PROVISIONS

SECTION M--EVALUATION FACTORS FOR AWARD

M.1 PROVISIONS

M.2 EVALUATION AND BASIS OF AWARD

M.3 EVALUATION CRITERIA

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

See Attachment 1. Price Schedule

B.2 SCHEDULE NOTES

a) Items labeled as optional are not required to be exercised by the government. If exercised, the contractor will be required to perform the optional work in accordance with the terms and conditions of this contract. The estimated optional items are contingent upon the availability of funds and no guarantee for this volume of work.

b) One award will be made from this solicitation, contractors must submit pricing for all items.

c) In accordance with FAR 19.1305 HUBZone set-aside procedures, competition is restricted to HUBZone small business concerns.

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

A. The work includes connection to the Palo Colorado well pumphouse and running a supply line to the Palo Colorado tank and then a distribution line from the Palo Colorado tank to Stone House, Bano de Oro, Bano Grande, and Palo Colorado. There is a bypass line from the Palo Colorado system that connects to the Caimitillo system. Work includes connection to the Caimitillo well pumphouse and running a new water waterline to the Caimitillo tank. From the Camitillo water storage tank a new distribution line will feed Caimitillo, Sierra Palm, and a new 10,000-gallon concrete storage tank for Yokahu Tower. From the new Yokahu tank a new distribution line shall run to Yokahu Tower.

Work includes installation of air release valves, water meter, waterline stream crossings, bridge anchors, pipe anchors, minor electrical repairs, valves, valve boxes, traffic control, erosion control, and other appurtenances to complete the work as shown on the drawings and indicated in the specifications. New waterline is HDPE pipe and much of the metal is stainless steel. General intent is for the waterline to be above ground when running through the general forest areas and below ground where visible to the public when running alongside the road and within administrative or recreation sites. Work does include horizontal directional drilling, replacement of concrete gutters, and asphalt patching. Work includes demolition of existing above ground pipe and non-used conduit that is visible to the public. The work is divided into a base bid item, and two option items and they are as described below.

1. Base Item: The general intent is to complete all work that is above and including the valve at Sierra Palm for the distribution line that goes to the new Yokahu water storage tank. Specifically, it includes the work from the Palo Colorado well to the Palo Colorado tank, from the Caimitillo well to the Caimitillo tank, the bypass line that connects the two systems, and the distribution lines to Stone House, Bano de Oro, Bano Grande, Palo Colorado, and Sierra Palm.

2. Option 1: The general intent of the item is to complete all work below the valve near the Sierra Palm bridge to and including the valve below the new 10,000-gallon concrete water storage tank. The work includes the bypass around the new water storage tank with the pressure reducing valve, the new water storage tank, and fencing.

3. Option 2: The general intent of the item is to complete all work below the valve at the new water storage tank to Yokahu Tower. Work includes a side lateral to the Big Tree site.

B. Quantities associated with these options are identified in the Schedule of Items.

C.2. PROJECT LOCATION

The project is located in the El Yunque National Forest, Rio Grande Municipality, Puerto Rico.

It is located approximately 6 miles south of Palmer, Puerto Rico. The project may be accessed from PR-191.

C.3 MAGNITUDE OF CONSTRUCTION PROJECT

In accordance with FAR 36.204, the magnitude of construction for this projected is currently estimated between $1,000,000 and $5,000,000.

452.211-72 Statement of Work/Specifications (FEB 1988) The Contractor shall furnish the necessary personnel, material, equipment, services, and facilities (except as otherwise specified), to perform the Statement of Work/General Requirements referenced in Section J.

452.211-73 Attachments to Statement of Work/Specifications (FEB 1988) The attachments to the Statement of Work/General Requirements listed in Section J are hereby made part of this solicitation and any resultant contract.

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

All shipments of materials, equipment and/or supplies shall be addressed to the Contractor and not to the Government.

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

The Government singularly identifies each project with a contract number at time of award. The contract number is a unique identifier to purposely and permanently represent an awarded project. The Government issued contract number is to be referenced on all official communication starting upon notice of award.

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

52.246-12 Inspection of Construction (AUG 1996)

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

52.211-13 Time Extensions (SEP 2000) 52.211-18 Variation in Estimated Quantity (APR 1984) 52.236-15 Schedules for Construction Contracts (APR 1984) 52.242-14 Suspension of Work (APR 1984)

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 330 days after the notice to proceed. The time stated for completion shall include final cleanup of the premises.

F.2 OTHER REQUIREMENTS

Bonds: Contractors are reminded that any amount awarded over $35,000 requires submission of a Payment Bond. Any amount over $150,000.00 requires both payment and performance bonds.

Bonds are due no later than 15 calendar days after award. Due to the project magnitude, both payment and performance bonds will be required.

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

452.215-73 Post Award Conference (NOV 1996) A post award conference with the successful offeror is required. It will be scheduled and held within _10_days after the date of contract award. The conference will be held at the Orchid Room in the Catalina Forest Service Headquarters Office Rio Grande, Puerto Rico.

G.2 CONTRACTING STAFF

All communications pertaining to contractual and/or administrative matters under this contract shall be sent to:

Contract Specialist: Joe Libbey at joe.libbey@usda.gov Contracting Officer’s Representative: Tania Martinez-Guzman at Tania.MartinezGuzman@usda.gov Alternate Contracting Officer’s Representative: Luis Martin Hidalgo at Luis.MartinHidalgo@usda.gov

SECTION H--SPECIAL CONTRACT REQUIREMENTS

H.1 USE OF PREMISES

(a) Before any camp, quarry, borrow pit, storage, detour, or bypass site, other than shown on the drawings, is opened or operated on USDA land or lands administered by the USDA, the Contractor shall obtain written permission from the Contracting Officer. A camp is interpreted to include a campsite or trailer parking area of any employee working on the project for the Contractor.

(b) Unless excepted elsewhere in the contract, the Contractor shall (i) provide and maintain sanitation facilities for the work force at the site and (ii) dispose of solid waste in accordance with applicable Federal, State and local regulations.

H.2 ARCHAEOLOGICAL OR HISTORIC SITES

If a previously unidentified archaeological or historic site(s) is encountered, the Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer Representative/Contracting Officer immediately.

H.3 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumen, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer Representative/Contracting Officer.

H.4 Required Signage for Covered Construction Contracts

This contract is supported by funds from the 0816 Bipartisan Infrastructure Law (also known as the Infrastructure Investment and Jobs Act), Therefore, the contractor must display signage on all covered contraction sites as described at https://www.usda.gov/style-guide/signage-guidelines for the duration of this contract’s period of performance.

H.5 Small Business Administration (SBA) Surety Bonds Guarantee Program

The U.S. Small Business Administration (SBA) guarantees bid, payment, and performance bonds for small and emerging contractors who cannot obtain surety bonds through regular commercial channels. SBA’s guarantee authorized pursuant to part B of title IV of the Small Business Investment Act of 1958, 15 U.S.C. 694a et seq., gives Sureties an incentive to provide bonding for small businesses and thereby assists small businesses in obtaining greater access to contracting opportunities.

SBA's guarantee is an agreement between a Surety and SBA that SBA will assume a certain percentage of the Surety's loss should a contractor default on the underlying contract. SBA is authorized to guarantee a Surety for a contract up to $6.5 million and, with the certification of a contracting officer of a Federal agency, up to $10 million. For more information about SBA's Surety Bond Guarantee Program, see https://www.sba.gov/funding-programs/surety-bonds

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

52.252-2 Clauses Incorporated by Reference (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR) Clauses:

https://www.acquisition.gov/browse/index/far (FAR clauses begin with 52) Department of Agriculture Acquisition Regulation (AGAR) Clauses:

https://www.acquisition.gov/agar (AGAR clauses begin with 452) Deviations to clauses may be viewed at: Policies & Regulations | USDA

52.202-1 Definitions (JUN 2020) 52.203-3 Gratuities (APR 1984) 52.203-5 Covenant against Contingent Fees (MAY 2014) 52.203-6 Restrictions on Subcontractor Sales to the Government (JUN 2020) 52.203-7 Anti-Kickback Procedures (JUN 2020) 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

(MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (JUN 2020) 52.203-13 Contractor Code of Business Ethics and Conduct (NOV 2021) 52.203-14 Display of Hotline Poster(s) (NOV 2021) 52.203-17 Contractor Employee Whistleblower Rights & Requirements to Inform Employees of Whistleblower Rights (JUN 2020) (Whistleblower Guidance to contractor employees) 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) 52.204-2 Security Requirements (MAR 2021) Alternate II (APR 1984) 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (MAY 2011) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) 52.204-13 System for Award Management Maintenance (OCT 2018) 52.204-19 Incorporation by Reference of Representations and Certifications (DEC 2014) 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021)

52.209-6 Protecting the Government's Interest when Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (NOV 2021) 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

(OCT 2018)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015) 52.210-1 Market Research (NOV 2021) 52.215-2 Audit and Records -- Negotiation (JUN 2020) 52.215-8 Order of Precedence—Uniform Contract Format (OCT 1997) 52.215-19 Notification of Ownership Changes (OCT 1997) 52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data (NOV 2021) 52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data – Modifications (NOV 2021) 52.219-3 Notice of Total HUBZone Set-Aside or Sole Source Award (OCT 2022) 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns

(OCT 2022)

52.219-14 Limitations on Subcontracting (OCT 2022) 52.222-3 Convict Labor (JUN 2003) 52.222-4 Contract Work Hours and Safety Standards -- Overtime Compensation (MAY 2018) 52.222-7 Withholding of Funds (MAY 2014) 52.222-8 Payrolls and Basic Records (JUL 2021) 52.222-9 Apprentices and Trainees (JUL 2005) 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) 52.222-11 Subcontracts (Labor Standards) (MAY 2014) 52.222-12 Contract Termination - Debarment (MAY 2014) 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations

(MAY 2014)

52.222-14 Disputes Concerning Labor Standards (FEB 1988) 52.222-15 Certification of Eligibility (MAY 2014) 52.222-21 Prohibition of Segregated Facilities (APR 2015) 52.222-26 Equal Opportunity (APR 2016) 52.222-27 Affirmative Action Compliance Requirements for Construction (APR 2015) 52.222-30 Construction Wage Rate Requirements-Price Adjustment (None or Separately Specified Pricing Method) (AUG 2018) 52.222-35 Equal Opportunity for Veterans (JUN 2020) 52.222-36 Equal Opportunity for Workers with Disabilities (JUN 2020) 52.222-37 Employment Reports on Veterans (JUN 2020) 52.222-40 Notification of Employee Rights Under National Labor Relations Act (DEC 2010) 52.222-44 Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment

(MAY 2014))

52.222-50 Combating Trafficking in Persons (NOV 2021) 52.222-54 Employment Eligibility Verification (MAY 2022)

52.222-55 Minimum Wages for Contractor Workers under Executive Order 14026 (JAN 2022) 52.222-62 Paid Sick Leave under Executive Order 13706 (JAN 2022) 52.223-2 Affirmative Procurement of Biobased Products under Service and Construction Contracts (SEP 2013) 52.223-3 Hazardous Material Identification and Material Safety Data Alt 1 (FEB 2021) 52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011) 52.223-6 Drug-Free Workplace (MAY 2001) 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) 52.223-15 Energy Efficiency in Energy Consuming Products (MAY 2020) 52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts (AUG 2018) 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) 52.223-20 Aerosols (JUN 2016) 52.223-21 Foams. (JUN 2016) 52.225-13 Restrictions on Certain Foreign Purchases (FEB 2021) 52.226-1 Utilization of Indian Organizations and Indian-Owned Economic Enterprises

(JUN 2000)

52.227-1 Authorization and Consent (JUN 2020) 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (JUN 2020) 52.227-4 Patent Indemnity -- Construction Contracts (DEC 2007) 52.228-2 Additional Bond Security (OCT 1997) 52.228-5 Insurance – Work on a Government Installation (JAN 1997) 52.228-12 Prospective Subcontractor Requests for Bonds (DEC 2022) 52.228-14 Irrevocable Letter of Credit (NOV 2014) 52.229-3 Federal, State, and Local Taxes (FEB 2013) 52.229-4 Federal, State, and Local Taxes (State and Local Adjustments) (FEB 2013) 52.232-5 Payments under Fixed-Price Construction Contracts (MAY 2014) 52.232-17 Interest (MAY 2014) 52.232-23 Assignment of Claims (MAY 2014) 52.232-27 Prompt Payment for Construction Contracts (JAN 2017) 52.232-33 Payment by Electronic Funds Transfer – System for Award Management (OCT 2018) 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) 52.233-1 Disputes (MAY 2014) Alt 1 (DEC 1991) 52.233-3 Protest after Award (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) 52.236-5 Material and Workmanship (APR 1984)

52.236-6 Superintendence by the Contractor (APR 1984) 52.236-7 Permits and Responsibilities (NOV 1991) 52.236-8 Other Contracts (APR 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (APR 1984) 52.236-10 Operations and Storage Areas (APR 1984) 52.236-11 Use and Possession Prior to Completion (APR 1984) 52.236-12 Cleaning Up (APR 1984) 52.236-13 Accident Prevention (NOV 1991) Alternate I (NOV 1991) 52.236-14 Availability and Use of Utility Services (APR 1984) 52.236-16 Quantity Surveys (APR 1984) Alternate 1 (APR 1984) 52.236-17 Layout of Work (APR 1984) 52.236-21 Specifications and Drawings for Construction (FEB 1997) Alternate I (APR 1984) Alternate II (APR 1984) 52.242-5 Payments to Small Business Subcontractors (JAN 2017) 52.242-13 Bankruptcy (JUL 1995) 52.243-4 Changes (JUN 2007) 52.244-2 Subcontracts (JUN 2020) 52.244-5 Competition in Subcontracting (DEC 1996) 52.244-6 Subcontracts for Commercial Products and Commercial Services (JUN 2023) 52.245-1 Government Property (SEP 2021) - Alt 1 (APR 2012) 52.245-9 Use and Charges (APR 2012) 52.246-21 Warranty of Construction (MAR 1994) Alternate I (MAR 1994) 52.248-3 Value Engineering – Construction (OCT 2020) 52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012) Alternate I (SEP 1996) 52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements) (APR 2012) 52.249-10 Default (Fixed-Price Construction) (APR 1984) Alternate I (APR 1984) 52.253-1 Computer Generated Forms (JAN 1991) 452.232-70 Reimbursement for Bond Premiums – Fixed-Price Construction Contracts (NOV

1996) 452.236-70 Additive or Deductive Items (FEB 1988) 452.236-71 Prohibition Against the Use of Lead-Based Paint (NOV 1996) 452.236-72 Use of Premises (NOV 1996) 452.236-73 Archaeological or Historic Sites (FEB 1988) 452.236-74 Control of Erosion, Sedimentation, and Pollution (NOV 1996) 452.236-76 Samples and Certificates (FEB 1988) 452.236-77 Emergency Response (NOV 1996)

52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023)

(a) Definitions. As used in this clause— Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)—

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use—

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L.

117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, “No TikTok on Government Devices” Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor’s employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23-13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

52.217-7 Option for Increased quantity – Separately Priced Line Item (MAR 1989) The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option CLINs 0002 and 0003 upon award of the contract or by written notice to the Contractor within 180 days after the notice to proceed is issued. The contractor will be given a 30 day notice.

52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)

(a) Definitions. As used in this clause—

“Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item.

Postconsumer material is a part of the broader category of “recovered material.”

“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall—

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to the Contracting Officer, Josh Choi at josh.choi@usda.gov.

52.225-9 Buy American Act-Construction Materials (OCT 2022)

(a) Definitions. As used in this clause— Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if– (A)The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all component used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C.chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

[Contracting Officer to list applicable excepted materials or indicate "none"]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable.

(A) For domestic construction material that is not a critical item or does not contain critical components.

(1) The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(2) For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(A)(2) of this clause will no longer apply as of January 1, 2030.

(B) For domestic construction material that is a critical item or contains critical components.

(1) The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds 55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(B)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(B)(2) of this clause will no longer apply as of January 1, 2030.

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1) (i)Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material.

However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction Material Description Unit of Measure Quantity Price (Dollars)* Item1 Foreign construction material _______ _______ _______ Domestic construction material _______ _______ _______ Item 2 Foreign construction material _______ _______ _______ Domestic construction material _______ _______ _______ [*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued)].

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] (End of clause)

52.228-1 Bid Guarantee (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds –

(1) To unsuccessful bidders as soon as practicable after the opening of bids, and (2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be _5_ percent of the bid price or $__NA____, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.228-11 Individual Surety - Pledge of Assets (FEB 2021) (DEVIATION MAY 2023)

(a) The Contractor shall obtain from each person acting as an individual surety on a performance bond or a payment bond - (1)A pledge of assets that meets the eligibility, valuation, and security requirements described in the Federal Acquisition Regulation (FAR) 28.203-1; and

(2) Standard Form 28, Affidavit of Individual Surety, [except that the words “being duly sworn, depose and say” on the Standard Form 28 are replaced with the word “affirm” and the Standard Form 28 is not required to be sworn and notarized in block 12].

(b)The Contracting Officer may release a portion of the security interest on the individual surety's assets based upon substantial performance of the Contractor's obligations under its performance bond. The security interest in support of a performance bond shall be maintained—

(1) Contracts for the construction, alteration, or repair of any public building or public work of the Federal Government exceeding $150,000 (40 U.S.C. 3131). Until completion of any warranty period, or for 1 year following final payment, whichever is later.

(2) Contracts subject to alternative payment protection (see FAR 28.102-1(b)(1)). For the full contract performance period plus 1 year.

(3) Other contracts not subject to the requirements of paragraph (b)(1) of this clause. Until completion of any warranty period, or for 90 days following final payment, whichever is later.

(c) A surety's assets pledged in support of a payment bond may be released to a subcontractor or supplier upon Government receipt of a Federal district court judgment, or a sworn statement by the subcontractor or supplier that the claim is correct along with a notarized authorization of the release by the surety stating that it approves of such release. The security interest on the individual surety's assets in support of a payment bond shall be maintained—

(1) Contracts for the construction, alteration, or repair of any public building or public work of the Federal Government exceeding $150,000 which require performance and payment bonds (40 U.S.C. 3131). For 1 year following final payment, or until resolution of all pending claims filed against the payment bond during the 1-year period following final payment, whichever is later.

(2) Contracts subject to alternative payment protection (see FAR 28.102-1(b)(1)). For the full contract performance period plus 1 year.

(3) Other contracts not subject to the requirements of paragraph (c)(1) of this clause. For 90 days following final payment.

(d)The Contracting Officer may allow the Contractor to substitute an individual surety, for a performance or payment bond, after contract award. The Contractor shall comply with the requirements of paragraph (a) of this clause within the timeframe established by the Contracting Officer.

52.228-15 Performance and Payment Bonds -- Construction (JUN 2020) (DEVIATION MAY 2023) (a)Definitions. As used in this clause -- “Original contract price” means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is valued at or below the threshold specified in Federal Acquisition Regulation 28.102-1(a) on the date of award of this contract, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance Bonds (Standard Form 25, EXCEPT THAT A SEAL IS NOT REQUIRED).

The penal amount of performance bonds at the time of contract award shall…