S02. 36C25023R0126.pdf

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014) STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within ____________ calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES NO

a. Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________

(hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

1 46

36C25023R0126

X

03-30-2023

757-21-101

701 AL

Department of Veterans Affairs

Network Contracting Office (NCO) 10

VA Healthcare System

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

Department of Veterans Affairs

Network Contracting Office (NCO) 10

VA Healthcare System

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

Stan Burdine (614) 388-7210

Project: 757-21-201, Repair Roads, Sidewalks and Parking Areas

Contractor shall provide all labor, equipment, supplies and supervision necessary for the Repair Roads, Parking Areas project at the Chalmers P. Wylie Columbus VA Ambulatory Care Center, 420 N. James Rd, Columbus, OH 43219.

Period of Performance: 60 Calendar Days after issuance of Notice to Proceed.

The project magnitude for the project is between $100,000 and $250,000.

NAICS: 237990, Other Heavy and Civil Engineering Construction. The business size standard is $39.5 million.

All work to be performed in accordance with the Drawings and Specifications included in this solicitation.

All work shall be coordinated with the Veterans Affairs (VA)Contracting Officer and the Contracting Officer's

Representative (COR).

All Bidders/Offerors shall insert bid(s) in the appropriate block(s) on the attached sheet titled "SF 1442 Block 17

Continuation on page 3." Bid(s) will be evaluated on price.

All Bidders/Offerors are required to complete the certification in VAAR 852.219-75 and that failure to do so shall deem the Offeror/Bidder Non-Responsive and the proposal/offer will not be accepted.

Site Visit and place of performance is at Chalmers P. Wylie VA Ambulatory Care Center (VAACC), 420 N. James Rd, Engineering Building, Columbus, OH 43219.

An organized site visit will be conducted in accordance with FAR 52.236-27.

Cut-off date and time to submit Requests for Information (RFI) is 04-14-2023 at 3:30 PM EST. RFIs shall be emailed to

Stanley Burdine at stanley.burdine@va.gov. No phone/fax inquiries will be accepted. Responses to the RFIs will be made via amendments to the solicitation via sam.gov.

This project is a 100% set-aside for a Service-Disabled Veteran Owned Small Business (SDVOSB). All bidders must be verified in VETBIZ and registered in SAM at the time of the offer due date and the time of award to be eligible for award. For eligibility under the NAICS, see VAAR 852.219-10 paragraph for performance requirements.

Public Law 105-339, Section 1534 provides "no agency may obligate or expend funds appropriated for the agency for a fiscal year to enter a contract described in Section 4212(a) of Title 38 with a contractor from which a report was required under Section 4212(d) of that title with respect to the preceding fiscal year, if such contractor did not submit such report."

14 60

X FAR 52.211-10

X

1 3PM EDT

04-28-2023

X

14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

PHONE: FAX:

28. NEGOTIATED AGREEMENT 29. AWARD Your

Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code)

(Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

(Type or print)

(4 copies unless otherwise specified)

(Type or print) (Type or print)

(Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror)

(To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

UEI Number:

Email:

Tax ID#:

"SEE PRICE SCHEDULE ON PAGE 6"

Department of Veterans Affairs

Network Contracting Office (NCO) 10

VA Healthcare System

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

36C250 Department of Veterans Affairs

Financial Services Center

Invoices to be Submitted Electronically www.ob10.com/us/en/veterans-affairs// e-Invoice Setup Info Phone 877-489-6135

Shelton Beasley

SF 1442 BLOCK 17 (CONTINUATION)

Project # 757-21-201

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within 120 calendar days after the date offers are due (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.).

Contractor’s Name: _______________________________

CAGE Code: _______________________________

UEI: _______________________________

The following proposals are submitted in lieu of completing block 17 on the attached SF 1442:

Line Item 1 (Base Bid): ___________________________________________

Line Item 2 (Alternate A): ___________________________________________

Line Item 3 (Alternate B): ___________________________________________

Line Item 4 (Alternate C): ___________________________________________

Line Item 5 (Alternate D): ___________________________________________

Line Item 6 (Alternate E): ___________________________________________

Line Item 7 (Alternate F): ___________________________________________

Table of Contents

PART I - THE SCHEDULE

SECTION A - SOLICITATION/CONTRACT FORM

A.1 SF 1442 SOLICITATION, OFFER, AND AWARD (Construction, Alteration, or

Repair)

A.2 SF 1442 SOLICITATION, OFFER, AND AWARD (CONSTRUCTION,

ALTERATION, OR REPAIR)– BACK

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE AND BONDS

A.3 FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC

2022)

A.4 FAR 52.204-24 REPRESENTATION REGARDING CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT

(NOV 2021)

A.5 FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984) ALTERNATE I (APR 1984)

A.6 FAR 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

A.7 FAR 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM

REREPRESENTATION (OCT 2022)

A.8 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY

SITE OF THE WORK (MAY 2014)

A.9 FAR 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO

ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

A.10 FAR 52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

A.11 FAR 52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022) ..20

A.12 FAR 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—

CONSTRUCTION MATERIALS (MAY 2014)

A.13 FAR 52.228-1 BID GUARANTEE (SEP 1996)

A.14 FAR 52.228-17 INDIVIDUAL SURETY—PLEDGE OF ASSETS (BID

GUARANTEE) (FEB 2021)

A.15 FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB

1995)

A.16 FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE

(FEB 1998)

A.17 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

A.18 VAAR 852.201-70 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 2022)

A.19 VAAR 852.204-70 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR

PERSONNEL (MAY 2020)

A.20 VAAR 852.209-70 ORGANIZATIONAL CONFLICTS OF INTEREST (OCT 2020)

A.21 VAAR 852.219-73 VA NOTICE OF TOTAL SET-ASIDE FOR VERIFIED

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESSES (NOV 2022)

A.22 VAAR 852.219-75 VA NOTICE OF LIMITATIONS ON SUBCONTRACTING--

CERTIFICATE OF COMPLIANCE FOR SERVICES AND CONSTRUCTION (NOV 2022)

A.23 VAAR 852.228-70 BOND PREMIUM ADJUSTMENT (JAN 2008)

A.24 VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND

VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009)

A.25 VAAR 852.232-70 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION

CONTRACTS (WITHOUT NAS– CPM) (NOV 2018)

A.26 VAAR 852.232-72 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS

(NOV 2018)

A.27 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE

RESOLUTION (OCT 2018)

A.28 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (OCT 2018)

A.29 VAAR 852.236-71 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION

(APR 2019)

A.30 VAAR 852.236-80 SUBCONTRACTS AND WORK COORDINATION (APR 2019)

A.31 VAAR 852.242-70 GOVERNMENT CONSTRUCTION CONTRACT

ADMINISTRATION (OCT 2020)

A.32 VAAR 852.242-71 ADMINISTRATIVE CONTRACTING OFFICER (OCT 2020) ..44

A.33 VAAR 852.243-70 CONSTRUCTION CONTRACT CHANGES—SUPPLEMENT

(SEP 2019)

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE

AND BONDS

**NOTE: A SINGLE AWARD MAY BE MADE ON LINE ITEM 1 (BASE BID), BUT IN

THE EVENT THE OFFER EXEEDS THE AVAILABLE FUNDS, A SINGLE AWARD MAY

BE MADE ON LINE ITEM 2, LINE ITEM 3, LINE ITEM 4, LINE ITEM 5, LINE ITEM 6 OR

LINE ITEM 7, IN THAT ORDER, BASED ON AVAILABLE FUNDING. OFFERORS

SHOULD QUOTE A PRICE ON EACH ITEM LISTED AND WILL NEED TO SUBMIT A

TOTAL COST FOR EACH LINE ITEM LISTED. THE PRICE FOR EACH LINE ITEM

SHOULD NOT REQUIRE ANY MATHEMATICAL CALCULATIONS TO BE

PERFORMED BY THE VA DETERMINE THE BIDDER’S PRICE.

LINE ITEM 1 (BASE BID): Work will replace damaged sidewalks, detectable warning strips, roads, and parking lots. The project will install detectable warning signs at all locations where sidewalks abut the road, repair exterior stairways and repair handicap accessible ramps. This project will also replace expansion joints and caulking in the roadway around the facility, repaving and adjacent sidewalk, curb, and gutter improvements, replace two manholes in the main driveway, re-strip the entire parking lot and install sidewalk between north and south section of the campus, running north and south along the west edge of the property. Replacing the damaged pavement and adding detectable warnings signs will enhance the safety of the veterans and the staff. All work shall be completed within 60 calendar days after receipt of

Notice to Proceed.

LINE ITEM 2 (Alternate A) West Campus Sidewalk: All Work in LINE ITEM 1 (BASE

BID) except: Do Not construct the west sidewalk as shown on sheets: CS104C, CG104C, CJ104C, AND CS501. All work shall be completed within 60 calendar days after receipt of

Notice to Proceed.

LINE ITEM 3 (Alternate B) North Parking Lot Striping: All work in LINE ITEM 1 (BASE

BID), LINE ITEM 2 Alternate A West Campus Sidewalk except: Do Not remove and replace pavement markings in the North Parking Lot. All work shall be completed within 60 calendar days of the Notice to Proceed.

LINE ITEM 4 (Alternate C) Site Lighting: All work in LINE ITEM 1 (BASE BID), LINE

ITEM 3 Alternate B, except: Do Not construct site lighting improvements as shown on sheet

ES104B. All work shall be completed within 60 calendar days after receipt of Notice to Proceed.

LINE ITEM 5 (Alternate D) Trailer Utilities: All work in LINE ITEM 1 (BASE BID), LINE

ITEM 4 Alternate C Site Lighting, except: Do Not construct electrical power for mobile trailers as shown on sheets EE020 and ES104A. All work shall be completed within 60 calendar days after receipt of Notice to Proceed.

LINE ITEM 6 (Alternate E) Engineering Building Interior Improvements: All work in

LINE ITEM 1 (BASE BID), LINE ITEM 5 Alternate D Trailer Utilities, except: Do Not perform work on engineering building Interior as shown on sheets construct electrical power for mobile trailers as shown on sheets SI002, SB103, SF103, SB501, AE001, AE002, AE003M AE101, AD103, AE103A,AE103B, AE113, AE203, AE303, AE503, AE603, AI103, EL103, EP103, FP103,FP103A, FP103B, HH003, HD103, HH103, HH113, HH503, HH603, PP03, PD103,PP103, PP603, PP903, TT003, TT013, and TT103. All work shall be completed within

60 calendar days after receipt of Notice to Proceed.

BID ITEM 7 (Alternate F) Engineering Building Addition: All work in LINE ITEM 1

(BASE BID), LINE ITEM 6 Alternate E Engineering Building Interior Improvements, except:

Do Not construct Engineering Building addition as shown on sheets CD103,CS103, CG103, CU103, CJ103 SI001, SI002, SB103, SF103, SB501, AE001, AE002, AE003M AE101, AD103, AE103A, AE103B, AE113, AE203, AE303, AE503, AE603, AI103, EL103, EP103, FP103, FP103A, FP103B, HH003, HD103, HH103, HH113, HH503, HH603, PP03, PD103, PP103, PP603, PP903, TT003, TT013, TT103, and EE020. All work shall be completed within 60 calendar days after receipt of Notice to Proceed.

A.3 FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS

(DEC 2022)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is

237990.

(2) The small business size standard is $39.5 Million.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition—

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management

(SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal

Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services—Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—

Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a

Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the

Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the

United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal

Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at

52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction

Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--

Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate.

(Basic, Alternates II and III.) This provision applies to solicitations containing the clause at

52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—

Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or

Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution

Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at

52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the

Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to

Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to

Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for

EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in

SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision) https://www.sam.gov/

A.4 FAR 52.204-24 REPRESENTATION REGARDING CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR

EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the

Offeror has represented that it ‘‘does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument’’ in paragraph (c)(1) in the provision at

52.204–26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212–3, Offeror Representations and Certifications–

Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it ‘‘does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services’’ in paragraph (c)(2) of the provision at 52.204–26, or in paragraph (v)(2)(ii) of the provision at 52.212–3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204–25, Prohibition on Contracting for

Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization

Act for Fiscal Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after

August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal

Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award

Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services.”

(d) Representations. The Offeror represents that—

(1) It [ ] will, [ ] will not provide covered telecommunications equipment or services to the

Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds “will’’ in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It [ ] does, [ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services.

The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds “does’’ in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the

Offeror has responded “will’’ in the representation in paragraph (d)(1) of this provision, the

Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model https://www.sam.gov/ number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded “does’’ in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph

(b)(2) of this provision.

(End of Provision)

A.5 FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION

OF WORK (APR 1984) ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 14 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 60 Calendar days after receipt of the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by To Be Determined. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the

Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of Clause)

A.6 FAR 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the

Contractor shall pay liquidated damages to the Government in the amount of $139.68 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

A.7 FAR 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM

REREPRESENTATION (OCT 2022)

(a) Definitions. As used in this clause—

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern—

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR

121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in

19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts—

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in

19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry

Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees if the acquisition—

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the

Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award

Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the

Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph

(c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

https://www.sba.gov/document/support--table-size-standards

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS

Code 237990 assigned to contract number .

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. The

Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of

13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: _____.]

(5) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The

Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of

13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: _____.]

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a veteran-owned small business concern.

(7) [Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that—

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the

Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each

HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the

HUBZone joint venture: _____.] Each HUBZone small business concern participating in the

HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[Contractor to sign and date and insert authorized signer's name and title.]

(End of Clause)

A.8 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—

SECONDARY SITE OF THE WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

A.9 FAR 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION

TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION

(FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action

Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the

Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

10.6 % 6.9 %

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance

Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action

Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order

11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for

Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

A.10 FAR 52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

(a) Definitions. As used in this clause—

“Active-duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,”

“disabled veteran,” “protected veteran,” “qualified disabled veteran,” and “recently separated veteran” have the meanings given at Federal Acquisition Regulation (FAR) 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans and requires affirmative action by the

Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts valued at or above the threshold specified in FAR 22.1303(a) on the date of subcontract award, unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

(End of Clause)

A.11 FAR 52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT

2022)

(a) Definitions. As used in this clause—

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is—

(i) A commercial product (as defined in paragraph (1) of the definition of ‘‘commercial product’’ at Federal Acquisition Regulation (FAR) 2.101;

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Component means any article, material, or supply incorporated directly into construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.

However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in…