RFQ FY21 DD Emergent Repairs (TJ).pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF. OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NAICS:

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8 (A)

EDWOSB

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

1305M220QNMAN01449

Drydock Repairs to NOAA Ship THOMAS JEFFERSON

TABLE OF CONTENTS

SECTION TITLE/DESCRIPTION PAGE

NUMBER

A SF 1449/Table of Contents 1

B Continuation of SF 1449 - Schedule of Supplies/Services 3

C Contract Clauses/Contract Terms and Conditions 5

D Documents, Exhibits, and Attachments 25

E RFQ Provisions 26

(1) Instructions to Offers

FAR 52.212-1, INSTRUCTIONS TO OFFERORS –

COMMERCIAL ITEMS by Reference (SF1449 block 27a)

(2) Evaluation Criteria

FAR 52.212-2, EVALUATION-COMMERCIAL ITEMS

(SF1449 block 27a)

(3) Offeror Representation and Certifications – Commercial Items FAR 52.212-3, (SF 1449 block 27a) 33

SECTION B: SCHEDULE OF SUPPLIES/SERVICES

SECTION B

SUPPLIES OR SERVICES AND PRICES

B.1 SPECIFICS:

1. The contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified) to perform all work in accordance with the Statement of Work/Specifications referenced as an attachment in Section D, “Documents, Exhibits, and Attachments”.

2. Ship checks will not be allowed during this time; however, detailed questions are encouraged and every attempt will be made to collect and share the desired information by August 28, 2020 10:00 A.M., Eastern Standard Time (EST) to Jessica Loftus (Jessica.Loftus@noaa.gov). All questions will be addressed by Addenda.

3. The Government anticipates award of all Base Items.

4. The NOAA Ship THOMAS JEFFERSON home port is located in Norfolk, Virginia.

The PLACE OF PERFORMANCE for the work specified herein shall be the CONTRACTOR’s FACILITY.

• This requirement has a geographical restriction to a one day (8-hour) transit from the ship’s home port of Norfolk, Virginia; or 88 nautical miles traveling at a cruising speed of 11 knots. This restriction is due to scheduling conflicts and the need for this necessary repair.

5. This is a Request for Quotations (RFQ). See Section E, for instructions for submission of quotes and the evaluation factors for award.

6. Federal Acquisition Regulation (FAR), Commerce Acquisition Regulations (CAR), and

NOAA Acquisition and Grants Office (AGO) or Eastern Acquisition Division (EAD) provisions and clauses that are included in this solicitation are annotated by the applicable acronym.

B.2 SCHEDULE OF SUPPLIES/SERVICES

PRICE SCHEDULE

BASE ITEMS

CLIN

SPEC

WORK

ITEM SPECIFICATION WORK ITEM TITLE UNIT QTY

UNIT

PRICE

EXTENDED

PRICE

0001 301 Temporary Services JB 1 $0.00

0002 302 Drydocking JB 1 $0.00

0003 303 EM2040 Transducer Replacement JB 1 $0.00

Total Base Items $0.00

ADDITIONAL ITEMS - GROWTH

ADDITIONAL ITEM REQUESTS (AIRs) These items relate to Growth Work. The Unit Price Column will be used throughout the life of the contract if growth work is added to the scope of the contract. If Additional Item Requests (AIRs) are issued, these items will be awarded at the quantities needed via a contract modification. The quantity shown is an estimate only and may be exceeded at the unit prices offered.

CLIN

SPEC

WORK

ITEM SPECIFICATION WORK ITEM TITLE UNIT QTY

UNIT

PRICE

EXTENDED

PRICE

0004 400

AIRS/Growth (estimated)

**Provide breakdown, as follows:

AIRs/Growth Labor Rate Unit Price: $________; Quantity: 225; Unit of Issue: Hour; Extended Price: $____________ HRS

EST.

225 $0.00

0005 400

AIRs/Growth Material Markup/Handling Fee Unit Price: $12,000.00; Quantity: 1; Unit of Issue:

Percent ________%;

Extended Price: [$12,000.00 X percentage quoted]: $______________ %

EST.

$12,000.00 $0.00

0006 N/A

Additional Temp Services (See CAR CLAUSE 1372.271-86)

Day EST 1 $0.00

0007 N/A Laydays (See CAR Clause 1372.271-89) Day EST 1 $0.00

Total Growth Items $0.00

OPTION ITEMS

Note: These items (0024 - 0034) may be exercised in accordance with FAR Clause 52.217-7 “OPTION FOR INCREASED

QUANTITY-SEPARATELY PRICED LINE ITEMS”.

CLIN

SPEC

WORK

ITEM SPECIFICATION WORK ITEM TITLE UNIT QTY

UNIT

PRICE

EXTENDED

PRICE

0008 501 Tunnel Thruster Servicing JB 1 $0.00

0009 502 Scuppers and Guards Modifications JB 1 $0.00

Total Option Items $0.00

BASE + OPTIONS $0.00

BASE + OPTIONS +GROWTH $0.00

SECTION C: CONTRACT CLAUSES

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR: www.acquisition.gov CAR: http://www.ecfr.gov/cgi-bin/text-idx?tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl NAM: http://www.ago.noaa.gov/acquisition/AcqManual/09_part1330-52.html

(End of Clause)

FAR PROVISION 52.212-4, INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS

(OCT 2018) is incorporated by reference with the following addenda (See SF1449, block 27a)

(a) CAR 1352.246-70 PLACE OF ACCEPTANCE (APR 2010)

The Contracting Officer or the duly authorized representative will accept supplies and/or services to be provided under this contract. (b) The place of acceptance will be on board NOAA Ship THOMAS

JEFFERSON.

CAR 1352.271-70 INSPECTION AND MANNER OF DOING WORK (APR 2010)

(c) CAR 1352.201-70 CONTRACTING OFFICER’S AUTHORITY (APR 2010)

CAR 1352.201-72 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (APR 2010)

(a) Mr. Neil Lamartin is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Phone Number: (757) 441-6369 Email: Neil.Lamartin@noaa.gov

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

CAR 1352.271-87 CHANGES – SHIP REPAIR (APR 2010)

CAR 1352.271-72 ADDITIONAL ITEM REQUIREMENTS (AIR) - GROWTH WORK (APR

2010)

(a) This clause applies to Additional Item Requirements (AIR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes - Ship Repair clause or mutually agreed upon by the parties. The contractor shall perform AIR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The AIR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling. The estimated quantity of labor hours and handling fees represent the Government's best estimate for growth that may be required throughout the contract performance period. All growth work shall be paid at the prices stated in the Schedule.

(b) The contractor shall take into account the potential for ordering all estimated AIR quantities in developing the Production Schedule. The ordering of any portion of the AIR quantities does not in itself warrant an extension to the original contract completion date; however, for planning purposes, the Government anticipates ordering AIR in accordance with the following schedule:

(1) No more than 75% of the hours during the first half of the contract period of performance.

(2) No more than 50% of the hours during the third quarter of the contract period of performance.

(3) No more than 30% of the hours during the fourth quarter of the contract period of performance.

(c) The AIR labor rate shall be a flat, hourly rate to cover the entire effort and shall be burdened to include:

(1) Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production: Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging.

(2) Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include: Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire Watch, General Labor (including general support of journeyman tasks), Cleaning (including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making).

(d) Additional Item Requirements do not include replacement work performed pursuant to the Inspection and Manner of Doing Work or Guarantees clauses.

(e) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(f) The contractor shall submit to the Contracting Officer the following information in all AIR proposals:

(1) Number of labor hours estimated; broken down by specific direct production labor category.

(2) Material estimates, individually broken out and priced. When requested by the Contracting Officer, material quotes shall be provided.

(3) Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer.

(4) Material/subcontractor handling fee and the basis for the fee.

(g) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

CAR 52.271-85 DOCUMENTATION OF REQUESTS FOR EQUITABLE

ADJUSTMENTS (APR 2010)

(f) FAR 52.242-15 STOP-WORK ORDER (AUG 1989)

FAR 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

(g) and (i) CAR 1352.271-71 METHOD OF PAYMENT AND INVOICING INSTRUCTIONS

FOR SHIP REPAIR (APR 2010)

(a) The Government will make payment under this contract based on a percentage of completion. The contractor may invoice for the percentage completed for each work item as work progresses. The amount invoiced shall be calculated based on prices stated in the Schedule, as follows: A work item may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that work item have no limitation as to the percentage of completion required before invoicing, but in no event may invoices be submitted more frequently than every 2 weeks, or for amounts less than $10,000, unless it is the final payment. The minimum percentage of completion (25%) to be reached prior to billing each work item may be waived by the Contracting Officer for large dollar work items on a case-by-case basis.

(b) Invoices submitted by the contractor which are deemed not proper, in accordance with FAR 52.232- 25, will be returned. Invoices shall include:

(1) Name and Address of the contractor;

(2) DUNS Number;

(3) Invoice Date;

(4) Contract Number/Modification Number;

(5) CLIN/Work Item Number, to include: Description, Quantity, Unit of Measure, Unit Price and

Extended Price;

(6) Shipping and Payment Terms; and,

(7) Contractor Point of Contact, including: Name, Title, Phone Number, and Mailing Address;

(8) The percentage of completion for each CLIN/work item identified;

(9) Name of the Contracting Officer;

(10) Ship name;

(11) The overall percentage and dollar amount previously billed, currently billed and unbilled.

(c) When invoicing for changed work, the contractor shall identify it as a contract change and shall identify the modification authorizing the change, and the CLIN/Work Item associated with the change.

(d) All items of work invoiced under this contract will be verified and confirmed by the Contracting Officer's Representative as accurate and complete and approved by the designated billing office before payment will be made.

(e) Invoices shall be submitted to the COR at Neil.Lamartin@noaa.gov and invoices.moc-a@noaa.gov.

The contractor shall simultaneously submit a copy of the invoice via email to Contract Specialist, Jessica Loftus, at Jessica.Loftus@noaa.gov.

Payment will be made by the designated payment office which is the Department of Commerce/NOAA Finance Systems Admin Branch/Rm. 1204, 20020 Century Blvd., Germantown, MD 20874.

(f) The contractor's final invoice submitted under the contract must be marked as follows: “THIS

INVOICE CONSTITUTES THE FINAL INVOICE - UPON PAYMENT OF THIS INVOICE NO

OTHER MONIES ARE DUE UNDER CONTRACT NUMBER (to be assigned at contract award)."

Note: Electronic submission of invoices and associated documentation via e-mail and/or fax is authorized and encouraged.

(j) FAR 52.247-34 F.O.B. DESTINATION (NOV 1991)

CAR 1352.271-79 LIABILITY AND INSURANCE (APR 2010)

CAR 1352.271-90 INSURANCE REQUIREMENTS (APR 2010)

(a) The contractor shall procure and thereafter maintain the following insurance:

(1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271-79. This insurance shall be for $1,000,000.00.

(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.

(3) Full coverage in accordance with the State Worker's Compensation law; and

(4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act.

(b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number (to be provided at the time of award) for repair/alteration of NOAA SHIP THOMAS JEFFERSON in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (date) and that each such policy contains the following clause:

"It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer."

(m) FAR 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND

DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $18,963.57 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(o) CAR 1352.271-88 GUARANTEES (APR 2010)

(a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 90 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 90-day period until its expiration.

(c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item.

(d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs.

(1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense.

(2) Where corrections and repairs are to be made by other than the contractor due to nonreturn of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract.

(e) The contractor's liability shall only extend for an additional 90-day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and Insurance clause.

(f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

(g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause.

(q) CAR 1352.209-73 COMPLIANCE WITH THE LAWS (APR 2010)

(r) CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

(w) CAR 1352.201-70 CONTRACTING OFFICER'S AUTHORITY (APR 2010)

(x) FAR 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

(y) FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND

REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR

2014)

(z) NOTICE OF POST-GOVERNMENT EMPLOYMENT RESTRICTIONS (OCT 2015)

By submission of an offer in response to a NOAA solicitation or acceptance of a contract, the contractor acknowledges the restriction on current NOAA employees regarding contact with offerors regarding prospective employment and the corresponding obligations for contractors who engage them. The contractor further acknowledges that it has provided notice to former NOAA employees who will provide service to NOAA under the contract of post-Government employment restrictions that apply to them. Such restrictions include, but are not limited to, those set forth in:

(a) 41 U.S.C. § 2103 regarding contacts between a federal employee working on a procurement and an offeror about prospective employment;

(b) 18 U.S.C. § 207 regarding the restrictions on former federal employees having contact with a federal agency on behalf of another person or entity concerning a specific party matter with which the former employee was involved as a federal employee or for which the former federal employee had official responsibility;

(c) 18 U.S.C. § 207 regarding the restrictions on former senior employees and senior political employees from having contact with his former federal agency on behalf of another person or entity concerning any official matter; and

(d) 41 U.S.C. § 2104 regarding the restrictions on a former federal employee involved in an acquisition over $10,000,000 from accepting compensation from a contractor.

(aa) NOAA/AGO SCHEDULE OF DELIVERABLES:

CONTRACT DELIVERABLES

ITE

M

DESCRIPTION QTY DUE DATE

DELIVER

TO

REFERENCE

Insurance Certificate

Within 2 days of contract award

See Block #7 of SF33

CAR 1352.271-79

and CAR

1352.271-90

Specification Deliverables (List

Not Inclusive)

Various

See Specification

COR

Specification

(ab) CAR 1352.270-70 PERIOD OF PERFORMANCE (APR 2010)

(a) The period of performance for work to be conducted on board NOAA ship THOMAS JEFFERSON will be five (5) calendar days, beginning on or about November 9, 2020 with a planned completion date of November 13, 2020, not including the ship’s transit time from its homeport in Norfolk, Virginia to and from the contractor’s facility. Once “notice to proceed (NTP)” is given by the Contracting Officer, the contractor is authorized to start ordering materials, aligning resources, etc., to prepare for the anticipated start date for work on board the vessel. Anticipated contract award date is on or about September 11, 2020 and a notice to proceed is anticipated to be issued on or about 5 days later.

(b) The NTP may be issued orally, by e-mail, or in writing by the Contracting Officer after receipt of the Contractor's insurance certificate. In no event will a delay in providing insurance certificate constitute a waiver of the completion date. Oral notification will be confirmed in writing by the Contracting Officer.

(ac) CAR 1352.271-73 SCHEDULE OF WORK (APR 2010)

(a) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within one (1) working day of the vessel's arrival at the contractor's facility:

(1) Production Schedule

(2) Work Package Network

(3) Total Manpower Loading Curve

(4) Trade Manning Curves

(5) Subcontracting List

(b) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(c) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than five (5) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR.

(d) Any unauthorized deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance, including, but not limited to, liquidated damages.

(ad) CAR 1352.271-75 DELIVERY AND SHIFTING OF THE VESSEL (APR 2010)

(a) The Government shall deliver the vessel to the contractor, at the location specified in the contract.

(b) Whether the specified location of performance is the contractor's own facility or any other authorized facility, it shall be understood to mean the fairway of the facility. The contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock, and, upon completion of all work, from the pier or dock to the fairway of the facility.

(c) While the vessel is in the possession of the contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the contractor without additional charge to the Government.

(ae) CAR 1352.271-76 PERFORMANCE (APR 2010)

(a) The contractor shall not commence work until a notice to proceed has been issued by the Contracting Officer.

(b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract.

(c) Without additional charge to the Government, and without specific requirement in the contract, the contractor shall:

(1) Make available, at the facility, to personnel of the vessel while in drydock or on a marine railway, sanitary facilities adequate for the number of personnel using them and acceptable to the Contracting Officer;

(2) Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to thevessel;

(3) Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and

(4) Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for personnel designated by the Government.

(d) Except as otherwise provided in the contract, the contractor shall furnish all necessary material, labor, supervision, services, equipment, tools, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work.

(e) The contractor shall conduct dock and sea trials of the vessel as required by the contract.

Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the contractor and the Government on board to determine whether the work provided by the contractor has been satisfactorily performed. Dock and sea trials not specified which the contractor requires for its own benefit shall not be undertaken by the contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the contractor. The contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials.

(af) FAR 52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE

ITEM (MAR 1989)

The Government requires the delivery of the numbered line items, identified in the Schedule as an option item in the quantity and at the price stated in the Schedule. The option quantities shown in Section B are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract period of performance. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of the essence initial notification will be provided verbally followed within 24 hours by a facsimile or e-mail of confirmation.

A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at time of award, during the contract period of performance or within six months after the date of award. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, no later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option CLIN shall be commenced as soon as proper sequencing permits. The exercise of any option item during the contract period of performance will not normally extend the contract performance period. The government shall give the contractor 30 days notice prior to exercising an option after the contract period of performance and within the six months after the date of award.

(ag) CAR 1352.245-70 GOVERNMENT FURNISHED PROPERTY (APR 2010)

(ah) FAR 52.203-3 GRATUITIES (APR 1984)

(ai) CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

(aj) NAM 1330-52.270-304 NOAA ACQUISITION AND GRANTS OFFICE

OMBUDSMAN (OCT 2016)

(a) The NOAA Acquisition and Grants Office (AGO) Ombudsman is available to organizations to promote responsible and meaningful exchanges of information.

Generally, the purpose of these exchanges will be to:

1. Allow contractors to better prepare for and propose on business opportunities.

2. Advise as to technologies and solutions within the marketplace that the Government may not be aware of, or is not fully benefiting

3. Identify constraints in transparency

(b) The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her.

Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA.

(ak) FAR 52.232-18 AVAILABILITY OF FUNDS (APR 1984)

***End addendum to FAR CLAUSE, 52.212-4, CONTRACT TERMS AND CONDITIONS – COMMERCIAL

ITEMS (OCT 2018)***

FAR 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT

STATUTES OR EXECUTIVE ORDERS -- COMMERCIAL ITEMS (MAR2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) (Section 89(a)(1)(A) of Pub. L. 115- 232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(5) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

XX (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

(2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

XX (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note).

(5) [Reserved]

(6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111- 117, section 743 of Div. C).

(7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

XX (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C.

6101 note).

XX (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

(10) [Reserved]

(11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (MAR 2020)

XX (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (MAR2020) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

(ii) Alternate I (MAR 2020) of 52.219-4.

(13) [Reserved]

(14) (i) 52.219-6, Notice of Total Small Business Aside (Mar 2020) (15 U.S.C. 644).

(ii) Alternate I (Mar 2020).

(iii) Alternate II (Nov 2011).

(15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Mar 2020) (15 U.S.C.

644).

(ii) Alternate I (Mar 2020) of 52.219-7.

(iii) Alternate II (Mar 2004) of 52.219-7.

XX (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C.

637(d)(2) and (3)).

XX (17) (i) 52.219-9, Small Business Subcontracting Plan (Mar 2020) (15 U.S.C. 637 (d)(4)).

(ii) Alternate I (Mar) of 52.219-9.

(iii) Alternate II (Nov 2016) of 52.219-9.

(iv) Alternate III (Nov 2016) of 52.219-9.

(v) Alternate IV (Aug 2018) of 52.219-9.

(18) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

(19) 52.219-14, Limitations on Subcontracting (Mar 2020) (15 U.S.C. 637(a)(14)).

XX (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

(21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set- Aside (Mar 2020) (15 U.S.C. 657f).

XX (22) 52.219-28, Post Award Small Business Program Representation (May 2020) (15 U.S.C. 632(a)(2)).

(23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Mar 2020) (15 U.S.C.

637(m)).

(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Mar 2020) (15 U.S.C. 637(m)).

XX (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

XX (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2020) (E.O. 13126).

XX (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

XX (28) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(ii) Alternate I (Feb 1999) of 52.222-26.

XX (29) (i) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(ii) Alternate I (July 2014) of 52.222-35.

XX (30) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ii) Alternate I (July 2014) of 52.222-36.

XX (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

XX (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

XX (33) (i) 52.222-50, Combating Trafficking in Persons (JAN 2019)

(22 U.S.C. chapter 78 and E.O. 13627).

(ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

(34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

(35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA- Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

(ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

XX (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693).

(37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).

(38) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514

(ii) Alternate I (Oct 2015) of 52.223-13.

(39) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514).

(ii) Alternate I (Jun 2014) of 52.223-14.

(40) 52.223-15, Energy Efficiency in Energy-Consuming Products (May 2020) (42 U.S.C. 8259b).

(41) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

(ii) Alternate I (Oct 2015) of 52.223-16.

XX (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513).

(43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

(44) 52.223-21, Foams (Jun 2016) (E.O. 13696).

(45) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(ii) Alternate I (Jan 2017) of 52.224-3.

XX (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

(47) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43).

(ii) Alternate I (May 2014) of 52.225-3.

(iii) Alternate II (May 2014) of 52.225-3.

(iv) Alternate III (May 2014) of 52.225-3.

(48) 52.225-5, Trade Agreements (Oct 2019) (19 U.S.C. 2501, et seq., 19 U.S.C.

3301 note).

XX (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

(52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

(53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)).

(54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C.

4505, 10 U.S.C. 2307(f)).

XX (55) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Oct 2018) (31 U.S.C. 3332).

(56) 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332).

(57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

(58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

XX (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C.

637(d)(13)).

(60) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

(ii) Alternate I (Apr 2003) of 52.247-64.

(iii) Alternate II (Feb 2006) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495)

(2) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67.).

(3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

(4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards --

Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C.206 and 41 U.S.C. chapter 67).

(5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

(6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-- Requirements (May 2014) (41 U.S.C. chapter 67).

(7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).

(8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O.

13658).

(9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O.

13706).

(10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(v) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C.

637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vi) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.

(vii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(viii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(ix) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(x) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(xi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(xii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xiii) 52.222-41, Service Contract Labor Standards (Aug 2018), (41 U.S.C.

chapter 67).

(xiv) (A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C.

chapter 78 and E.O. 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xvi) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xvii) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xviii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xix) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O.

13706).

(xx) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations.

(May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph

(e) of FAR clause 52.226-6.

(…