RFPWallpaper2026.pdf

THE TOWN OF GRANBY, CT – REQUEST FOR PROPOSAL (RFP)

For Granby Senior Center/Youth Services Building

Wallpaper Removal and Replacement RFP Issued June 1, 2026

GENERAL INFORMATION

The purpose and intent of this Request for Proposal (RFP) by the Town of Granby CT (“Town”) is to solicit sealed proposals from qualified independent contractors for the removal and replacement of existing wall covering (wallpaper) in a municipal building.

The Town seeks a professional contractor capable of completing the project in a timely manner, with minimal disruption to building operations, and in accordance with all applicable codes and safety standards.

The firm must provide full disclosure of all existing client relationships that currently or prospectively may give rise to conflicts of interest and disqualification.

PROJECT BACKGROUND

The selected contractor will be responsible for providing all labor, materials, equipment, and supervision necessary to:

• Remove existing wallpaper

• Prepare wall surfaces

• Install new wallpaper or wall covering as specified

• Ensure a clean, finished appearance suitable for a public municipal facility

SCOPE OF WORK

The proposal document should describe the following scope:

A. Pre-Construction

• Conduct a site visit to review existing conditions

• Assess for best replacement option: wallpaper or paint

• Identify wall conditions, repairs, or surface preparation needs

• Confirm measurements and material quantities

B. Wallpaper Removal

• Protect floors, fixtures, doors, and adjacent surfaces

• Remove existing wallpaper and adhesive

• Properly dispose of removed materials

C. Surface Preparation

• Repair minor wall imperfections (patching, sanding, smoothing)

• Prime walls as needed to ensure proper adhesion and finish

D. Wallpaper Installation/Painting

• Furnish and install new wallpaper or wall covering (Town will [select one]: provide materials / approve contractor-supplied materials)

• Ensure proper alignment, pattern matching, and seam finishing and/or cutting in, corners, and trim work.

E. Cleanup and Closeout

• Daily and final cleanup of work areas

• Removal of debris from the site

• Final walkthrough with Town representative

F. Project Locations

• Main Entryway – High Visibility public area

• Community Room – Multi-purpose room used for meetings and events

Contractor shall account for public use and coordinate work to minimize disruption.

MANDATORY SITE VISIT

The mandatory site visit is scheduled for Monday, June 15, 2026 at 9:30 AM. Meet at Granby Senior Center at 15 North Granby Road Granby CT 06035.

CONTRACTOR QUALIFICATIONS

Company Profile Three professional references Implementation Plan and Timeline Previous Experience with municipal projects Proof of required licenses and insurance

EVALUATION CRITERIA

Proposals will be evaluated based on the following requirements and criteria:

� Cost � Experience and qualifications � Quality of proposed materials and methods � Ability to meet schedule � Adherence to fire safety requirements � References

The Town reserves the right to reject any or all proposals and to select the proposal deemed to be in the best interest of the Town.

QUESTIONS AND CLARIFICATIONS

All questions regarding this Request for Proposals shall be submitted via email only to Sandra Yost, Director of Community Services, syost@granby-ct.gov. All questions shall be presented at least electronically by noon on Thursday, June 25, 2026 to allow for the preparation and distribution of addenda. Responses will be posted on the Town website no later than 4PM on Thursday, July 2, 2026. All respondents are responsible for checking the website for the presence and content of all addenda.

TERMS AND CONDITIONS

The Town Manager, acting on the behalf of the Town of Granby, reserves the right to reject any or all proposals in whole or part, to award any one service or group of services or all services, to negotiate with any or all companies submitting proposals, and to enter into an agreement with any company for any services mentioned in this RFP; if it is deemed to be in the best interest of the Town of Granby. All submitted proposals become the property of the Town of Granby and will not be returned.

The Town will evaluate and consider all responsive proposals received. It should be noted that the contract resulting from this RFP will be awarded to the respondent whose proposal is determined to be in the best interest of the Town. Therefore, the proposal offering the lowest cost may not necessarily be the proposal that is selected for award.

Process All vendors wishing to be considered for this purchase shall submit three (3) copies and one electronic version of their written responses based on the requirements set forth in this RFP document. The RFP document is available on the Town’s website at www.granby-ct.gov under Public Documents/RFQ and RFP’s (hereafter referred to as the Town’s website).

Proposals will be received until noon on Monday, July 13, 2026 in the Town Manager’s Office, 15 North Granby Road, Granby CT 06035. All proposals must be clearly marked on the outside of the envelope with: “Granby Community Services Department – Senior Center Upgrades.”

An electronic submission must also be provided, either on a flash drive and sent with the written responses or sent via email to the Town Manager’s Office, bmazzotta@granby-ct.gov. This must also be received by noon on Monday, July 13, 2026.

Proposals received by the Town will be reviewed for completeness and clarity. They will be evaluated in accordance with the Proposal Evaluation Criteria above and the contractors to be http://www.granby-ct.gov/ mailto:bmazzotta@granby-ct.gov interviewed, if any, will be determined. A decision on an award is anticipated within two weeks of receipt of the proposals.

General Requirements Reservation of Rights The Town reserves the right to waive informalities or to reject any or all proposals when such action is deemed to be in the best interests of the Town. The Town reserves the right to delete such items as it deems necessary from these proposals. Respondents are directed to be certain that they understand the terms and conditions as specified in this RFP. All exceptions of the respondent to the terms and specifications of this RFP shall be made in writing and submitted in full with the proposal. For all other terms and specifications, submission of a proposal constitutes acceptance by the respondent. It will be expected that all remaining terms and conditions expressed herein are acceptable and shall govern any resulting contract.

The Town reserves the sole right to reject proposals that contain exceptions which are unacceptable. In order to provide the requested services to the Town, the respondent must be able to demonstrate the expertise and flexibility necessary to successfully complete this project. All items related to the selection of the contractor for this award shall be completed to the satisfaction of the Town Manager. The Town shall not be responsible for any expenses incurred in preparing and submitting a response to this Request for Proposals. The Town further reserves the right to request information from individual respondents and to negotiate fees and/or other terms and conditions.

Nondiscrimination The firm shall agree and warrant that it will not discriminate of permit discrimination against any person or group of persons on the grounds of sex, race, color, religion, age, marital status, ancestry, national origin, past history of mental health disorder, mental disability, physical disability, or other basis in any manner prohibited by the laws of the United States, the State of Connecticut, or the Town of Granby.

Insurance Requirements The awarded Respondent shall be responsible for maintaining insurance coverage in force for the duration of the contract of the kinds and amounts listed below, with an insurance company with an AM Best Rating of A-VIII or better, licensed to write such insurance in the State of Connecticut and acceptable to the Town of Granby.

The insurer shall provide the Town of Granby with Certificates of Insurance, on a form acceptable to the Town, signed by an authorized representative of the insurance company prior to the commencement of performance of this award describing the coverage and providing that the insurer shall give the Town of Granby written notice of at least thirty (30) days in advance of any termination, expiration, or any and all changes in coverage.

Such insurance or renewals or replacements thereof shall remain in force during the Respondent’s responsibility under this award.

The Respondent, at the Respondent’s own cost and expense, shall procure and maintain all insurances required and shall include the Town of Granby as an Additional Insured on all such insurance, except Workers’ Compensation coverage. The Certificate of Insurance shall provide evidence of all required insurances, including Additional Insured and Waivers of Subrogation. The Respondent shall also provide its policy endorsement indicating the Town of Granby as an additional insured.

1. Workers' Compensation Insurance. The awarded Respondent shall carry workers' compensation insurance in accordance with the requirements of the laws of the State of Connecticut, and employer's liability limits of Five Hundred Thousand Dollars ($500,000.00) coverage for each accident, Five Hundred Thousand Dollars ($500,000.00) coverage for each employee by disease, Five Hundred Thousand ($500,000.00) policy limit coverage for disease.

2. Commercial General Liability. With respect to all operations which awarded respondent performs, it shall carry Commercial General Liability insurance providing for a total limit of One Million Dollars ($1,000,000.00) coverage per occurrence for each site or project for all damages arising out of bodily injury, personal injury, property damage, products/completed operations, and contractual liability coverage for the indemnification obligations arising under this Agreement. Each annual aggregate limit shall not be less than Three Million Dollars ($3,000,000.00). The limit may be provided through a combination of primary and umbrella/excess liability policies acceptable to The Town of Granby. Blanket Contractual Liability for liability assumed under this Agreement.

3. Automobile Liability. With respect to each owned, non-owned, or hired vehicles, the awarded Respondent shall carry Automobile Liability insurance providing One Million Dollars ($1,000,000.00).

4. Excess Liability Coverage. With respect to the coverage provided by the awarded Respondent for this Project, excess liability insurance will be provided in an amount not less than One Million Dollars ($1,000,000.00) per occurrence and annual aggregate basis.

5. Professional Liability. One Million Dollars ($ 1,000,000.00) coverage per occurrence for each site or project for all damages arising out of bodily injury, personal injury, and property damage.

6. Deductibles and Self-Insured Retentions: Any deductible or self-insured retention must be declared to and approved by the Town of Granby. All deductibles or self-insured retentions are the sole responsibility of the awarded Respondent to pay and/or to indemnify.

7. Errors and Omissions Insurance. The awarded Respondent shall provide and maintain Errors and Omissions Insurance with minimum limits of $2,000,000 per occurrence/annual aggregate. The policy shall not have a deductible greater than $50,000.00.

The Town of Granby shall be named as “Additional Insured.” Coverage is to be provided on a primary, noncontributory basis. Waiver of subrogation in favor of the Town of Granby is required on all applicable policies, including workers’ compensation. If any policy is written on a “Claims Made” basis, the policy must be continually renewed for a minimum of two (2) years from the completion date of the Contract. If the policy is replaced and/or the retroactive date is changed, then the expiring policy must be endorsed to extend the reporting period for claims for the policy in effect during the Contract for two (2) years from the completion date.

Defense, Hold Harmless and Indemnification The successful proposer agrees, to the fullest extent permitted by law, to defend, indemnify, and hold harmless the Town, its employees, officers, officials, agents, volunteers and independent contractors, including any of the foregoing sued as individuals (collectively, the “Town Indemnified Parties”), from and against all proceedings, suits, actions, claims, damages, injuries, awards, judgments, losses and expenses, including attorney’s fees, arising out of or relating, directly or indirectly, to the successful proposer’s malfeasance, misconduct, negligence or failure to meet its obligations under the RFP or the Contract. The successful proposer’s obligations under this section shall not be limited in any way by any limitation on the amount or type of the successful proposer’s insurance. Nothing in this section shall obligate the successful proposer to indemnify the Town Indemnified Parties against liability for damage arising out of bodily injury to persons or damage to property caused by or resulting from the sole negligence of the Town Indemnified Parties. In any and all claims against the Town Indemnified Parties made or brought by any employee of the successful proposer, or anyone directly or indirectly employed or contracted with by the successful proposer, or anyone for whose acts or omissions the successful proposer is or may be liable, the successful proposer’s obligations under this section shall not be limited by any limitation on the amount and type of damages, compensation or benefits payable by the successful proposer under workers’ compensation acts, disability benefit acts, or other employee benefits acts. The successful proposer shall also be required to pay any and all attorney’s fees incurred by the Town Indemnified Parties in enforcing any of the successful proposer’s obligations under this section, which obligations shall survive the termination or expiration of this RFP and the Contract.

As a municipal agency of the State of Connecticut, the Town will NOT defend, indemnify, or hold harmless the successful proposer.

These insurance requirements are not meant to be construed as a limitation of liability. The parties agree that the amounts of insurance under this Agreement do not, in any way, limit the Respondent’s liability to the Town of Granby by virtue of this promise to indemnify and hold the Town of Granby harmless so that in the event of any settlement of a claim or a judgment in an amount in excess of the amount of insurance coverage carried by the awarded Respondent, the Respondent shall be liable to the Town of Granby for the difference, plus all fees and expenses incurred in collecting same, all at the Respondent’s sole cost.

Freedom of Information All proposals and any related submittals to the Town are subject to the requirements of the State of Connecticut Freedom of Information Act, regardless of whether they are marked as confidential, proprietary, or in any other manner. By the act of submitting a bid, bidders agree that they will be subject to Connecticut General Statutes Section §1-200 et seq.

Award The Town intends, but is not required, to make an award as a result of this RFP. The award will be made to one vendor who is capable of completing the project or may subcontract the project.

In all cases, the awarded vendor will be responsible for the completion of all the work no matter how the project was contracted.

The selected firm must meet all municipal, state and federal AA and EEO practices and requirements including CHRO. MBEs/WBEs/SBEs are encouraged to apply.

Work Product Ownership All responses and submittals received as a result of this Request for Proposals shall become the property of the Town upon receipt. All work products provided to the Town following award shall also be the sole property of the Town upon receipt.

THE TOWN OF GRANBY IS AN EQUAL OPPORTUNITY/AFFIRMATIVE ACTION

EMPLOYER.