RFP 2026-02 Avenue A Alley Drainage Improvements 050626.pdf
PDF 134 KB Posted
- Attached to
- Downtown Pole Wrap Lighting Project
- Solicitation number
- 2026-02
- Issued by
- Glades County, Florida
About this file
This is a sealed bid advertisement issued by the City of Port St. Joe, Florida for the Avenue A Alley Drainage Improvements project (RFP 2026-02, Project #50190108). The project involves re-grading an alleyway located between N. Bay St. and Harbor St., running from Avenue A to Clifford Sims Drive, and includes the installation of a roadside swale, stormwater inlets, and drainage pipes to direct stormwater runoff to an existing ditch on the West side of N. Bay St. Sealed bids are due by 3:00 P.M. Eastern Time on Friday, June 12, 2026, at City Hall (305 Cecil G. Costin Sr. Blvd, Port St. Joe, Florida 32456), with public opening and reading at 3:05 P.M. the same day. Plans and specifications are available electronically at no charge from Shannon Renfro at Dewberry Engineers Inc. (srenfro@dewberry.com). The project timeline requires 60 days for substantial completion and 90 days for final completion from the Notice to Proceed. Questions must be submitted in writing to Josh Baxley at jbaxley@dewberry.com prior to Friday, May 29, 2026. All bids must remain firm for 60 days following the bid opening.
Liquidated damages are assessed at $500.00 per day for failure to meet the specified completion dates. All bidders must comply with Section 287.133(3) of the Florida Statutes regarding public entity crimes and must be properly licensed, registered, and regulated as contractors in the State of Florida. The City of Port St. Joe is an Equal Opportunity Employer offering handicapped accessibility and operates under Fair Housing guidelines. The municipality reserves the right to waive informalities, reject any or all bids, and select the bid deemed most advantageous to the City's interests.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| RFP 2026-02 Downtown Pole Wrap Lighting Project_Final.pdf | ||
| Pest Mowing.pdf |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
ADVERTISEMENT FOR BIDS-00010
AVENUE A ALLEY DRAINAGE IMPROVEMENTS PROJECT #50190108
NOTICE TO RECEIVE SEALED BIDS
RFP 2026-02
The City of Port St. Joe will receive sealed bids from any qualified person, company or corporation interested in constructing:
AVENUE A ALLEY DRAINAGE IMPROVEMENTS
The proposed project is located at the alleyway between N. Bay St. and Harbor St. running from Ave A to
Clifford Sims Dr in Port St Joe, Florida. The proposed improvements include re-grading the alleyway with the addition of a roadside swale, stormwater inlets and drainage pipes to convey the stormwater runoff to the existing ditch located on the West side of N. Bay St.
Plans and Specifications can be obtained by contacting Shannon Renfro at srenfro@dewberry.com with
Dewberry Engineers Inc., 324 Marina Drive, Port St. Joe, Florida 32456. The bid must conform to Section
287.133(3) Florida Statutes, on public entity crimes. There is no charge for electronic copies for the Plans and Specifications.
The completion date for this project will be 60 days for Substantial Completion and 90 days for Final
Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.
Please indicate on the envelope that this is a sealed bid, for the “AVENUE A ALLEY DRAINAGE
IMPROVEMENTS”.
Bids will be received until 3:00 P.M. Eastern Time, on Friday, June 12, 2026, at the City of Port St. Joe
City Hall, 305 Cecil G. Costin Sr. Blvd, Port St. Joe, Florida 32456opened and read aloud at 3:05 P.M.
Eastern Time. The City of Port St. Joe is an Equal Opportunity Employer/Handicapped Accessible/Fair
Housing Jurisdiction.
The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening.
Questions regarding the project must be submitted in writing to Josh Baxley at jbaxley@dewberry.com prior to Friday, May 29, 2026.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.
File details come from the government source that posted it. Updated .