RFB_Sample_Contract_-_Water_Tower_Riser_Valve.pdf

RFB Sample Contract CRTC – Replace Riser Valve on Water Tower SWIFT Event #2000016489 Rev. 07.01.2024 Department of Military Affairs

State of Minnesota Contract

SWIFT Contract Number:

This Contract is between the State of Minnesota, acting through the Department of Military Affairs (DMA) (“State”) and [Contractor] whose designated business address is [Contractor’s business address] (“Contractor”).

State and Contractor may be referred to jointly as “Parties.”

Recitals

1. State issued a solicitation identified as SWIFT Event No. 2000016489 on December 5, 2024 to a Replace Riser Valve on a 500,000-gallon Water Tower at the Camp Ripley Training Center (“Solicitation”);

2. Contractor provided a response to the Solicitation indicating its interest in and ability to provide the goods or services requested in the Solicitation; and

3. Subsequent to an evaluation in accordance with the terms of the Solicitation, the Parties desire to enter into a contract.

Accordingly, the Parties agree as follows:

Contract

Term of Contract

Effective date. December 19, 2024, or the date the State obtains all required signatures under Minn.

Stat. § 16C.05, subd. 2, whichever is later. The Contractor must not begin work under this Contract until this Contract is fully executed and the Contractor has been notified by the State’s Authorized Representative to begin the work.

Expiration date. February 28, 2025, or until all obligations have been satisfactorily fulfilled, whichever occurs first. The contract may be extended for up to an additional six months, in increments as determined by the State, through a duly executed amendment.

Contractor’s Duties The Contractor shall perform all duties described in this Contract to the satisfaction of the State.

Representations and Warranties

Under Minn. Stat. §§ 15.061 and 16C.03, subd. 3, the State is empowered to engage such assistance as deemed necessary.

Contractor warrants that it is duly qualified and shall perform its obligations under this Contract in accordance with the commercially reasonable standards of care, skill, and diligence in Contractor’s industry, Rev. 07.01.2024 Department of Military Affairs trade, or profession, and in accordance with the specifications set forth in this Contract, to the satisfaction of the State.

Contractor warrants that it possesses the legal authority to enter into this Contract and that it has taken all actions required by its procedures, by-laws, and applicable laws to exercise that authority, and to lawfully authorize its undersigned signatory to execute this Contract, or any part thereof, and to bind Contractor to its terms.

Time The Contractor must comply with all the time requirements described in this Contract. In the performance of this Contract, time is of the essence.

Compensation and Conditions of Payment

Compensation. The State will pay for performance by the Contractor under this Contract in accordance with the breakdown of costs as set forth in Exhibit D which is attached and incorporated into this Contract.

Conditions of Payment. All duties performed by the Contractor under this Contract must be performed to the State’s satisfaction and in accordance with all applicable federal, state, and local laws, ordinances, rules, and regulations including business registration requirements of the Office of the Secretary of State.

The Contractor will not receive payment for work found by the State to be unsatisfactory or performed in violation of federal, state, or local law.

Authorized Representative

State’s Authorized Representative: The State's Authorized Representative is Dean Berckes, Physical Plant Director (PPD), 15000 Highway 115, Little Falls, MN 56345, Ph: 320-616-3007, or his successor, or delegate, and has the responsibility to monitor the Contractor’s performance and the authority to accept the services delivered or goods received under this Contract. If the services are satisfactory, the State's Authorized Representative will certify acceptance on each invoice submitted for payment.

Contractor’s Authorized Representative: The Contractor's Authorized Representative is [name, title] at the following business address and telephone number: [insert business address and telephone number], or his/her successor. If the Contractor’s Authorized Representative changes at any time during this Contract, the Contractor must immediately notify the State.

Exhibits The following Exhibits are attached and incorporated into this Contract. In the event of a conflict between the terms of this Contract and its Exhibits, or between Exhibits, the order of precedence is first the Contract, and then in the following order:

Exhibit A: Contract Terms

• Exhibit A, Supplement 1: Prevailing Wage – Morrison County

Exhibit B: Insurance Requirements Exhibit C: Specifications, Duties, and Scope of Work Exhibit D: Pricing Exhibit E: Special conditions for Contract Work Involving Federal Funds

Rev. 07.01.2024 Department of Military Affairs

1. State Encumbrance Verification Individual certifies that funds have been encumbered as required by Minn. Stat. §§ 16A.15 and 16C.05

3. Department of Military Affairs Advisor With delegated authority

Print name: Print name:

Signature: Signature:

Title: Date: Title: Date:

SWIFT Contract No.:

2. Contractor The Contractor certifies that the appropriate person(s) have executed the Contract on behalf of the Contractor as required by applicable articles, bylaws, resolutions, or ordinances.

4. Buyer/Purchasing Agent As delegated by The Office of State Procurement

Print name: Print name:

Signature: Signature:

Title: Date: Title: Date:

Rev. 07.01.2024 Department of Military Affairs

Exhibit A: Contract Terms

Prompt Payment and Invoicing.

Prompt Payment. The State will pay the Contractor pursuant to Minn. Stat. § 16A.124, which requires payment within 30 days following receipt of an undisputed invoice, or merchandise or service, whichever is later.

Terms requesting payment in less than 30 days will be changed to read “Net 30 days.” Notwithstanding the foregoing, the State may pay the Contractor in advance for purchases as allowed pursuant to Minn. Stat. §16A.065.

The payment for each order will only be made for goods received or services actually performed that have been accepted by the ordering entity, and meet all terms, conditions, and specifications of the Contract and the ordering document.

Invoicing. At a minimum the invoice must meet the requirements found on Exhibit D which provides a list of minimum invoice requirements.

Assignment, Amendments, Waiver, and Contract Complete.

Assignment. The Contractor may neither assign nor transfer any rights or obligations under this Contract without the prior consent of the State and a fully executed assignment agreement, executed, and approved by the authorized parties or their successors.

Amendments. Any amendment to this Contract must be in writing and will not be effective until it has been executed and approved by the authorized parties or their successors.

Waiver. If the State fails to enforce any provision of this Contract, that failure does not waive the provision or its right to enforce it.

Contract Complete. This Contract contains all negotiations and agreements between the State and the Contractor. No other understanding regarding this Contract, whether written or oral, may be used to bind either party.

Termination.

Termination for Convenience. The State or Commissioner of Administration may cancel this Contract at any time, with or without cause, upon 30 days’ written notice to the Contractor. Upon termination for convenience, the Contractor will be entitled to payment, determined on a pro rata basis, for services or goods satisfactorily performed or delivered.

Termination for Breach. If the Contractor fails to perform according to the contract terms and conditions, the State is authorized to immediately cancel the Contract or purchase order, or any portion of it, and may obtain replacement goods or services and charge the difference of costs to the defaulting Contractor. In the event of default, the State reserves the right to pursue any other remedy available by law. A Contractor may be removed from the vendors list, suspended, or debarred from receiving a Contract for failure to comply with terms and conditions of the Contract, or for failure to pay the State for the cost incurred on the defaulted Contract.

Termination for Insufficient Funding. The State may immediately terminate this Contract if it does not obtain funding from the Minnesota Legislature, or other funding source; or if funding cannot be continued at a level sufficient to allow for the payment of the services addressed within this Contract. Termination must be by written notice to the Contractor. The State is not obligated to pay for any services that are provided after notice and effective date of termination. However, the Contractor will be entitled to payment, determined on a pro rata basis, Rev. 07.01.2024 Department of Military Affairs for services satisfactorily performed to the extent that dedicated funds are available. The State will not be assessed any penalty if the Contract is terminated because of the decision of the Minnesota Legislature, or other funding source, not to appropriate funds. The State must provide the Contractor notice of the lack of funding. This notice will be provided within a reasonable time of the State’s receiving notice.

Force Majeure.

Neither party shall be responsible to the other or considered in default of its obligations within this Contract to the extent that performance of any such obligations is prevented or delayed by acts of God, war, riot, disruption of government, or other catastrophes beyond the reasonable control of the party unless the act or occurrence could have been reasonably foreseen and reasonable action could have been taken to prevent the delay or failure to perform. A party relying on this provision to excuse performance must provide the other party prompt written notice of the inability to perform and take all necessary steps to bring about performance as soon as practicable.

Indemnification.

In the performance of this Contract, the Indemnifying Party must indemnify, save, and hold harmless the State, its agents, and employees, from any claims or causes of action, including attorney’s fees incurred by the State, to the extent caused by Indemnifying Party’s:

• Intentional, willful, or negligent acts or omissions; or

• Actions that give rise to strict liability; or

• Breach of contract or warranty.

The Indemnifying Party is defined to include the Contractor, Contractor’s reseller, any third party that has a business relationship with the Contractor, or Contractor’s agents or employees, and to the fullest extent permitted by law.

The indemnification obligations of this section do not apply in the event the claim or cause of action is the result of the State’s sole negligence. This clause will not be construed to bar any legal remedies the Indemnifying Party may have for the State’s failure to fulfill its obligation under this Contract.

Nothing within this Contract, whether express or implied, shall be deemed to create an obligation on the part of the State to indemnify, defend, hold harmless or release the Indemnifying Party. This shall extend to all agreements related to the subject matter of this Contract, and to all terms subsequently added, without regard to order of precedence.

Governing Law, Jurisdiction, and Venue.

Minnesota law, without regard to its choice-of-law provisions, governs this Contract. Venue for all legal proceedings out of this Contract, or its breach, must be in the appropriate state or federal court with competent jurisdiction in Ramsey County, Minnesota.

Contract Use by State Agencies.

To the extent applicable, the Contract does not prohibit state agencies from using their delegated purchasing authority to procure similar goods and services from other sources.

Warranty.

The Contractor warrants to the ordering entity that materials and equipment furnished under the Contract will be free from defects not inherent in the quality required or permitted, and that the work will conform to the requirements of the contract. Work not conforming to these requirements, including substitutions not properly approved and authorized in writing may be considered defective. The Contractor’s warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the Contractor, improper or insufficient

Rev. 07.01.2024 Department of Military Affairs maintenance, improper operation, or normal wear and tear and normal usage. If requested, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment used.

All installation materials and labor shall be guaranteed for a period of one (1) year following the date of final acceptance. During the first year following acceptance, the Contractor shall, upon notification by the ordering entity of any malfunctions, make necessary repairs, including labor, travel, and materials, at the Contractor’s expense.

Delivery.

Contractor is obligated to deliver within the quoted lead times. If delivery is not made within that time frame, the State reserves the right to deem the Contractor in default.

Risk of Loss.

The State is relieved of all risks of loss or damage to the goods and equipment during periods of transportation, installation by the Contractor, or while in the possession of the Contractor or its agent.

Purchase Orders.

The parties agree that there is no minimum order requirements or charges to process an individual purchase order unless otherwise stated in the Contract. The Purchase Order number must appear on all documents (e.g., invoices, packing slips, etc.).

Equipment Specifications.

All equipment must meet the contract specifications and all federal and State safety codes and regulations in effect at the date of manufacture. All equipment must be Original Equipment Manufacturer (OEM) equipment unless otherwise stated in the contract.

Items Offered as New.

All products, materials, supplies, replacement parts, and equipment offered and furnished must be new, of current manufacturer production, and must have been formally announced by the manufacturer as being commercially available, unless otherwise stated in this Contract.

Subcontracting and Subcontractor Payment.

Subcontracting Allowed. A subcontractor is a person or company that has been awarded a portion of the Contract by Contractor. Only subcontractors that have been approved by the State’s Authorized Representative can be used for this Contract.

After the effective date of the Contract, the Contractor shall not, without prior written approval of the State’s Authorized Representative, subcontract for the performance of any of the Contractor’s obligations that were not already approved for subcontracting when the Contract was awarded. During this Contract, if an approved subcontractor is determined to be performing unsatisfactorily by the State’s Authorized Representative, the Contractor will receive written notification that the subcontractor can no longer be used for this Contract.

The provisions of the Contract shall apply with equal force and effect to all approved subcontractors engaged by the Contractor. Notwithstanding approval by the State, no subcontract shall serve to terminate or in any way affect the primary legal responsibility of the Contractor for timely and satisfactory performances of the obligations contemplated by the Contract.

Subcontractor Payment. Contractor must pay any subcontractor in accordance with Minn. Stat. § 16A.1245.

Rev. 07.01.2024 Department of Military Affairs

Data Disclosure.

Under Minn. Stat. § 270C.65, subd. 3 and other applicable law, the Contractor consents to disclosure of its social security number, federal employer tax identification number, and Minnesota tax identification number, already provided to the State, to federal and state agencies, and state personnel involved in the payment of state obligations. These identification numbers may be used in the enforcement of federal and state laws which could result in action requiring the Contractor to file state tax returns, pay delinquent state tax liabilities, if any, or pay other state liabilities.

Government Data Practices.

The Contractor and State must comply with the Minnesota Government Data Practices Act, Minn. Stat. Ch. 13, (or, if the State contracting party is part of the Judicial Branch, with the Rules of Public Access to Records of the Judicial Branch promulgated by the Minnesota Supreme Court as the same may be amended from time to time) as it applies to all data provided by the State under this Contract, and as it applies to all data created, collected, received, stored, used, maintained, or disseminated by the Contractor under this Contract. The civil remedies of Minn. Stat. § 13.08 apply to the release of the data governed by the Minnesota Government Practices Act, Minn. Stat. Ch. 13, by either the Contractor or the State.

If the Contractor receives a request to release the data referred to in this clause, the Contractor must immediately notify and consult with the State’s Authorized Representative as to how the Contractor should respond to the request. The Contractor’s response to the request shall comply with applicable law.

Intellectual Property Rights.

Definitions. For the purpose of this Section, the following words and phrases have the assigned definitions:

“Documents” are the originals of any databases, computer programs, reports, notes, studies, photographs, negatives, designs, drawings, specifications, materials, tapes, disks, or other materials, whether in tangible or electronic forms, prepared by the Contractor, its employees, agents, or subcontractors, in the performance of this Contract.

“Pre-Existing Intellectual Property” means intellectual property developed prior to or outside the scope of this Contract, and any derivatives of that intellectual property.

“Works” means all inventions, improvements, discoveries (whether or not patentable), databases, computer programs, reports, notes, studies, photographs, negatives, designs, drawings, specifications, materials, tapes, and disks conceived, reduced to practice, created, or originated by the Contractor, its employees, agents, and subcontractors, either individually or jointly with others in the performance of this Contract. “Works” includes Documents.

Ownership. The State owns all rights, title, and interest in all of the intellectual property rights, including copyrights, patents, trade secrets, trademarks, and service marks in the Works and Documents created and paid for under this Contract. The Documents shall be the exclusive property of the State and all such Documents must be immediately returned to the State by the Contractor upon completion or cancellation of this Contract. To the extent possible, those Works eligible for copyright protection under the United States Copyright Act will be deemed to be “works made for hire.” The Contractor assigns all right, title, and interest it may have in the Works and the Documents to the State. The Contractor must, at the request of the State, execute all papers and perform all other acts necessary to transfer or record the State’s ownership interest in the Works and Documents.

Pre-existing Intellectual Property. Each Party shall retain ownership of its respective Pre-Existing Intellectual Property. The Contractor grants the State a perpetual, irrevocable, non-exclusive, royalty free license for

Rev. 07.01.2024 Department of Military Affairs

Contractor’s Pre-Existing Intellectual Property that are incorporated in the products, materials, equipment, deliverables, or services that are purchased through the Contract.

Obligations.

Notification. Whenever any invention, improvement, or discovery (whether or not patentable) is made or conceived for the first time or actually or constructively reduced to practice by the Contractor, including its employees and subcontractors, in the performance of this Contract, the Contractor will immediately give the State’s Authorized Representative written notice thereof, and must promptly furnish the State’s Authorized Representative with complete information and/or disclosure thereon.

17.4.2 Representation. The Contractor must perform all acts and take all steps necessary to ensure that all intellectual property rights in the Works and Documents are the sole property of the State, and that neither Contractor nor its employees, agents, or subcontractors retain any interest in and to the Works and Documents.

The Contractor represents and warrants that the Works and Documents do not and will not infringe upon any intellectual property rights of other persons or entities.

17.4.3 Indemnification. Notwithstanding any other indemnification obligations addressed within this Contract, the Contractor will indemnify; defend, to the extent permitted by the Attorney General; and hold harmless the State, at the Contractor’s expense, from any action or claim brought against the State to the extent that it is based on a claim that all or part of the Works or Documents infringe upon the intellectual property rights of others. The Contractor will be responsible for payment of any and all such claims, demands, obligations, liabilities, costs, and damages, including but not limited to, attorney fees. If such a claim or action arises, or in the Contractor’s or the State’s opinion is likely to arise, the Contractor must, at the State’s discretion, either procure for the State the right or license to use the intellectual property rights at issue or replace or modify the allegedly infringing works or documents as necessary and appropriate to obviate the infringement claim. This remedy of the State will be in addition to and not exclusive of other remedies provided by law.

Copyright.

The Contractor shall save and hold harmless the State of Minnesota, its officers, agents, servants, and employees, from liability of any kind or nature, arising from the use of any copyrighted or noncopyrighted compositions, secret process, patented or non-patented invention, article or appliance furnished or used in the performance of the Contract.

Assignment of Antitrust Rights.

Upon the request of the State of Minnesota, Contractor will irrevocably assign to State any state or federal antitrust claim or cause of action that the Contractor now has, or which may accrue to the Contractor in the future, in connection with any goods, services, or combination provided by Contractor under the terms of this Contract.

Contractor’s Documents.

Any licensing and maintenance agreement, or any order-specific agreement or document, including any pre-installation, linked or “click through” agreement that is allowed by, referenced within or incorporated within the Contract whenever the Contract is used for a State procurement, whether directly by the Contractor or through a Contractor’s agent, subcontractor or reseller, is agreed to only to the extent the terms within any such agreement or document do not conflict with the Contract or applicable Minnesota or Federal law, and only to the extent that the terms do not modify, diminish or derogate the terms of the Contract or create an additional financial obligation to the State. Any such agreement or document must not be construed to deprive the State of its sovereign immunity, or of any legal requirements, prohibitions, protections, exclusions, or limitations of liability applicable to this Contract or afforded to the State by Minnesota law. A State employee’s decision to choose “accept” or an equivalent option associated with a “click-through” agreement does not constitute the State’s concurrence or acceptance of terms if such terms are in conflict with this section.

Rev. 07.01.2024 Department of Military Affairs

State Audits.

Under Minn. Stat. § 16C.05, subd. 5, the Contractor’s books, records, documents, and accounting procedures and practices relevant to this Contract are subject to examination by the State, the State Auditor, or Legislative Auditor, as appropriate, for a minimum of six years from the expiration or termination of this Contract.

Publicity and Endorsement.

Publicity. Any publicity regarding the subject matter of this Contract must identify the State as the sponsoring agency and must not be released without prior written approval from the State’s Authorized Representative. For purposes of this provision, publicity includes notices, informational pamphlets, press releases, information posted on corporate or other websites, research, reports, signs, and similar public notices prepared by or for the Contractor individually or jointly with others, or any subcontractors, with respect to the program, publications, or services provided resulting from this Contract.

Endorsement. The Contractor must not claim that the State endorses its products or services.

Debarment by State, its Departments, Commissions, Agencies, or Political Subdivisions.

Contractor certifies that neither it nor its principals is presently debarred or suspended by the Federal government, the State, or any of the State’s departments, commissions, agencies, or political subdivisions. Contractor’s certification is a material representation upon which the Contract award was based. Contractor shall provide immediate written notice to the State’s Authorized Representative if at any time it learns that this certification was erroneous when submitted or becomes erroneous by reason of changed circumstances.

Federal Funds.

Compliance with Federal Requirements. Federal money will be used or may potentially be used to pay for all or part of the goods, construction, or services under the Contract. The Contractor is responsible for compliance with all federal requirements imposed on the funds and accepts full financial responsibility for any requirements imposed by the Contractor’s failure to comply with federal requirements.

Certification regarding Debarment, Suspension, Ineligibility, and Voluntary Exclusion. Federal money will be used or may potentially be used to pay for all or part of the work under the Contract, therefore Contractor certifies that it is in compliance with federal requirements on debarment, suspension, ineligibility, and voluntary exclusion specified in the solicitation document implementing Executive Order 12549. Contractor’s certification is a material representation upon which the Contract award was based.

Contingency Fees Prohibited.

Pursuant to Minn. Stat. § 10A.06, no person may act as or employ a lobbyist for compensation that is dependent upon the result or outcome of any legislation or administrative action.

Certification of Nondiscrimination (in accordance with Minn. Stat. § 16C.053).

If the value of this Contract, including all extensions, is $50,000 or more, Contractor certifies it does not engage in and has no present plans to engage in discrimination against Israel, or against persons or entities doing business in Israel, when making decisions related to the operation of the vendor's business. For purposes of this section, "discrimination" includes but is not limited to engaging in refusals to deal, terminating business activities, or other actions that are intended to limit commercial relations with Israel, or persons or entities doing business in Israel, when such actions are taken in a manner that in any way discriminates on the basis of nationality or national origin and is not based on a valid business reason.

Non-discrimination (in accordance with Minn. Stat. § 181.59).

The Contractor will comply with the provisions of Minn. Stat. § 181.59.

Rev. 07.01.2024 Department of Military Affairs

E-Verify Certification (in accordance with Minn. Stat. § 16C.075).

For services valued in excess of $50,000, Contractor certifies that as of the date of services performed on behalf of the State, Contractor and all its subcontractors will have implemented or be in the process of implementing the federal E-Verify Program for all newly hired employees in the United States who will perform work on behalf of the State. Contractor is responsible for collecting all subcontractor certifications and may do so utilizing the E-Verify Subcontractor Certification Form. All subcontractor certifications must be kept on file with Contractor and made available to the State upon request.

Hazardous Substances.

To the extent that the goods to be supplied to the State by the Contractor contain or may create hazardous substances, harmful physical agents, or infectious agents, as set forth in applicable State and federal laws and regulations, the Contractor must provide the State with Material Safety Data Sheets regarding those substances. A copy must be provided upon request. Goods and containers supplied to the State must be labeled in compliance with state and federal laws, rules, and regulations.

These terms apply to goods supplied under this contract:

Products Containing Triclosan Banned. The Contractor must comply with Minn. Stat. § 145.945.

Products Containing Certain Types of Polybrominated Diphenyl Ether Banned. The Contractor must comply with Minn. Stat. § 325E.385-325E.388).

Coal Tar Sealant Use and Sale Prohibited. The Contractor must comply with Minn. Stat. § 116.202.

Products Containing Mercury. The Contractor must comply with Minn. Stat. 116.92.

Survival of Terms.

The following clauses survive the expiration or cancellation of this Contract: Indemnification; State Audits;

Government Data Practices; Intellectual Property; Publicity and Endorsement; Governing Law, Jurisdiction, and Venue; and Data Disclosure. Any other Contract term that expressly states or by its nature shall survive, shall survive.

Subcontracting.

Only subcontractors that have been approved by the State’s Authorized Representative can be used for this Contract. See attachments to Exhibit A, Supplements 2, and 3, Responsible Contractor forms.

After the effective date of the Contract, the Contractor shall not, without submitting Supplement 3 to Exhibit A and receiving prior written approval of the State’s Authorized Representative, subcontract for the performance of any of the Contractor’s obligations that were not already approved for subcontracting when the Contract was awarded.

During this Contract, if an approved subcontractor is determined to be performing unsatisfactorily by the State’s Authorized Representative, the Contractor will receive written notification that the subcontractor can no longer be used for this Contract.

The provisions of the Contract shall apply with equal force and effect to all approved subcontractors engaged by the Contractor. Notwithstanding approval by the State, no subcontract shall serve to terminate or in any way affect the primary legal responsibility of the Contractor for timely and satisfactory performances of the obligations contemplated by the Contract.

Subcontractor Payment.

In accordance with Minn. Stat. § 16A.1245, the Contractor shall, within ten (10) days of receipt of payment from the State, pay all subcontractors and suppliers having an interest in the Contract their share of the payment for undisputed services provided by the subcontractors or suppliers. The Contractor is required to pay interest of 1-1/2 percent per month or any part of a month to the subcontractor on any undisputed amount not paid on time to the subcontractor. The minimum monthly interest penalty payment for an unpaid, undisputed balance of $100 or more will be $10. For an unpaid balance of less than $100, the amount will be the actual penalty due. A subcontractor that https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fosp.admin.mn.gov%2Fsites%2Fosp%2Ffiles%2Fpdf%2Feverifysubcertform.doc&wdOrigin=BROWSELINK https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fosp.admin.mn.gov%2Fsites%2Fosp%2Ffiles%2Fpdf%2Feverifysubcertform.doc&wdOrigin=BROWSELINK

Rev. 07.01.2024 Department of Military Affairs takes civil action against the Contractor to collect interest penalties and prevails will be entitled to its costs and disbursements, including attorney’s fees that were incurred in bringing the action. The Contractor agrees to take all steps necessary to comply with said statute. A consultant is a subcontractor under the Contract. In the event the Contractor fails to make timely payments to a subcontractor or supplier, the State may, at its sole option and discretion, pay a subcontractor or supplier any amounts due from the Contractor and deduct said payment from any remaining amounts due the Contractor. Before any such payment is made to a subcontractor or supplier, the State shall provide the Contractor written notice that payment will be made directly to a subcontractor or supplier. If there are no remaining outstanding payments to the Contractor, the State shall have no obligation to pay or to see to the payment of money to a subcontractor except as may otherwise be required by law.

Prevailing Wage.

All State funded or partially State funded work against this contract is subject to the prevailing wage requirements pursuant to Minnesota Statutes 177.41 to 177.44 and corresponding Minnesota Rules 5200.1000 to 5200.1120 as established by the Minnesota Department of Labor and Industry. Specifically, all contractors and all tiers of subcontractors must pay all laborers and mechanics the established prevailing wages for work performed under the contract. Failure to comply with the aforementioned may result in civil or criminal penalties.

Work under this contract includes, but is not limited to, plumbers, pipefitters, and general construction workers. See https://www.revisor.mn.gov/rules/?id=5200.1102 and https://www.revisor.mn.gov/rules/?id=5200.1100.

The Contractor and Subcontractor shall furnish to the ordering entity all payrolls, of all workers on the project, via email as attachments, to the email address provided on the purchase order. If an email address is not included on the purchase order, contact the ordering entity to obtain the appropriate email address.

The Contractor and Subcontractor must submit the State of Minnesota Prevailing Wage Payroll Report and Statement of Compliance Form within fourteen (14) days after the end of each pay period. The forms are available on the Office of State Procurement (OSP) website at https://mn.gov/admin/osp/vendors/overview-for-vendors/. No other payroll forms will be accepted to meet this requirement.

The Contractor and Subcontractor must complete the Prevailing Wage Payroll Report in Microsoft Excel, and the Statement of Compliance in an Adobe PDF format. The subject line of the email must provide the company name, contract/purchase order number, and pay period ending dates.

The Department of Labor and Industry has a web page with Frequently Asked Questions about prevailing wages at http://www.dli.mn.gov/business/employment-practices/prevailing-wage-information

For questions regarding the Prevailing Wage Laws, contact the Department of Labor and Industry at 651.284.5091.

CPV Requirements.

CPV members are responsible to confirm if they are subject to rules, regulations, or ordinances which establish the prevailing wage rate as defined in Minn. Stat. § 177.42.

Compliance with Tax Law Requirements.

The State cannot make final payment to the Contractor until the Contractor demonstrates that it and all its subcontractors have complied with the Income Tax withholding requirements of Minnesota Statutes, section 290.92 for wages paid for work performed under the contract. To establish compliance, the Contractor must submit a “Contractor Affidavit” either online or in paper form (IC134) to the Minnesota Department of Revenue. The Contractor will receive written certification of compliance when the Department of Revenue determines that all withholding tax returns have been filed and all withholding taxes attributable to the work performed on the contract have been paid. The Contractor must then provide this written certification to the Architect/Engineer to receive final payment.

https://www.revisor.mn.gov/rules/?id=5200.1102 https://www.revisor.mn.gov/rules/?id=5200.1100 https://mn.gov/admin/osp/vendors/overview-for-vendors/ http://www.dli.mn.gov/business/employment-practices/prevailing-wage-information

Rev. 07.01.2024 Department of Military Affairs

Every subcontractor working on the Project must submit an approved “Contractor Affidavit” from the Minnesota Department of Revenue to the Contractor before the Contractor can file its own Contractor Affidavit. The Contractor is strongly encouraged to obtain the certification from each Contractor immediately following the Subcontractor’s completion of work on the project. Delays in completing the forms until after the project is complete may result in significant additional work for the Contractor in collecting the required forms.

The Department of Revenue, in association with the Department of Employment and Economic Development, offers a free seminar to help contractors understand tax law requirements. The Department strongly urges the Contractor and all subcontractors to attend the “Employment Taxes & Employer Responsibilities Seminar” or similarly offered classes. You can find a schedule and more information on the Department’s website at:

http://www.revenue.state.mn.us/businesses/withholding/Pages/EducationandOutreach.aspx

Complying with this requirement is considered part of the work under this Contract. Contractor delay in complying with this requirement may cause the State to delay final payment and Contract Acceptance. The State may also report non-compliance to the Department of Revenue, which may result in enforcement action by the Department of Revenue.

Workmanship and Licenses.

Employ personnel skilled and experienced for the specific task required. Licensed journeymen shall be employed where required by law. Workmanship shall be of the highest quality and performed in a neat and expeditious manner. Qualified supervision shall be at the site when work is progressing.

All Contractors shall conform to the labor laws of the State of Minnesota and all other laws, ordinances, and legal requirements affecting their work in Minnesota.

Response Time.

Upon receipt of a purchase order, the Contractor shall contact the ordering entity where work is to be performed or materials to be delivered within 7 calendar days acknowledging the receipt of order and to schedule work start dates. In the event the ordering entity determines that expedited action is required, the Contractor shall respond within 72 hours. Orders requiring expedited action will indicate “expedited action response required” on the purchase order. If after an installation date has been established and the ordering entity requires a delay in the work, the ordering entity may, without penalty, delay installation for a period mutually agreed upon by both parties.

Once the project is started, work is to proceed on a continuous basis. Interruptions in finishing a project must be approved by the ordering entity.

All products must be installed with a minimum of interruption to the normal business operation. All work will comply with the applicable national, state, and local codes and regulations. If normal service must be disrupted, the Contractor must consult with and obtain the approval of the ordering entity on how the service disruption will be handled prior to scheduling the work. Service Center assistance must be available 7 days a week, 24 hours a day. The Contractor must be able to provide first response to all service calls within one (1) hour. First response is defined as a returned phone call, or diagnostic and troubleshooting, and/or providing anticipated resolution.

Delivery, Storage and Handling.

The Contractor shall be responsible to inspect all components on delivery to ensure that no damage occurred during shipping or handling for furnish and installation projects. For equipment only purchases, the ordering entity shall be responsible to inspect all components on delivery. Materials must be stored in original undamaged packaging in such a manner to ensure proper ventilation and drainage, and to protect against damage, weather, vandalism, and theft until ready for installation.

http://www.revenue.state.mn.us/businesses/withholding/Pages/EducationandOutreach.aspx

Rev. 07.01.2024 Department of Military Affairs

Utilities.

Contractor shall protect above and below grade utilities in conformance with Minnesota Department of Transportation (MnDOT) Specification 1507 and shall contact Gopher One Call at 651-454-0002 / 800-252-1166 (website: www.gopherstateonecall.org) to locate on-site utilities. Contractor shall provide the ordering entity with the Gopher State One Call locates confirmation number.

Fire Safety Instruction for Contractors.

Contractors are required to adhere to all current codes, standards and safety rules that are in effect at the time of the work being performed. These include, but are not limited to, building codes, electrical codes, safety codes, and ordering entity’s personnel/property protection codes. Contractors are responsible for obtaining the ordering entity’s personnel/property protection requirements from the facility in which they are performing the work.

Contractor will also implement a “hot-work” and/or “impairment” safety program during the performance of their work if applicable.

Right to Inspect and Require Work.

Any work performed that is not in conformance with the specifications of the Contract, or the legal requirements governing the work, shall be subject to rejection. All rejected work shall be immediately replaced or modified at the Contractor’s expense so as to conform to the Contract. If the State determines that the work being performed by the Contract is not in strict conformance with the Contract, the State shall have the right to order the work of the Contractor wholly or partially stopped, or suspended until any nonconforming work has been corrected. Such stoppage or suspension shall not invalidate or modify any terms of the Contract and no extra compensation or reimbursement will be allowed to the Contractor by reason of such stoppage or suspension.

Conduct.

All employees of the Contractor(s) shall conduct themselves in a professional and courteous manner at all times.

Personnel deemed unacceptable by the State shall be replaced immediately. The State reserves the right to reject any employee.

Safety.

The ordering entity agrees to furnish safe and free access to all areas of work covered by this Contract for the purpose of executing the terms of this Contract. At its option, the ordering entity may request, and the Contractor will comply, that a member of the Contractor’s staff be removed from working on projects for unsafe practices, violations of the Contract procedures, or other problems.

The Contractor shall take all reasonably necessary steps to provide for the safety of, and prevent damage, injury, or loss to:

• All persons

• The building and all other real or personal property at the work site.

• All equipment at the building, under the care, custody, or control of the Contractor or any of its employees.

The Contractor shall promptly notify the ordering entity if, during the term of the Contract, the Contractor observes or otherwise learns of any conditions which:

• In the Contractor’s judgment, poses a threat to the safety of person or property;

• Adversely affects the equipment; or

• Is in violation of any applicable codes or regulations.

Administrative Personnel Changes.

The Contractor must notify the State’s Authorized Representative of changes in the Contractor’s key administrative personnel, in advance and in writing. Any employee of the Contractor who, in the opinion of the State of Minnesota, is unacceptable, shall be removed from the project upon written notice to the Contractor. In the event that an http://www.gopherstateonecall.org/

Rev. 07.01.2024 Department of Military Affairs employee is removed pursuant to a written request from the State’s Authorized Representative, the Contractor shall have 10 working days in which to fill the vacancy with an acceptable employee.

Damage.

At its expense, the Contractor shall promptly remedy and repair all damage or loss to any property caused by the Contractor. The Contractor shall not be liable for any loss, delay, injury, or damage, whether direct or consequential, that may be caused by conditions beyond its control relating to acts of government, strikes, lockouts, fire explosion, theft, riot, civil commotion, war, malicious mischief, floods, or other acts unforeseen, or other situations beyond the Contractor’s control. The Contractor shall not be responsible for damage or loss attributable to the fault or negligence of the ordering entity. The Contractor shall not be held liable for back charges if the delay of response time is caused by strikes, any preference or priority allocation order issued by the government, or any unforeseeable cause beyond the Contractor’s control, or any cause the State determines justifies the delay.

Hazardous Materials.

If hazardous materials are suspected or discovered during work operations, stop work, and notify the ordering entity. Hazardous materials include, but are not limited to, asbestos containing materials, lead, PCB’s, pollutants, contaminated soil, and mercury. Do not proceed with work until a written notice to continue work on the project is received by the ordering entity.

Delays.

The Contractor shall notify the ordering entity immediately of any prospective delays in the completion of the projects. Such notice shall be given in writing as soon as the contractor recognizes the prospect of delay. The ordering entity must approve all such requests.

Work Not Permitted or Work Requiring Ordering Entity Approval.

Repair work, new installations or extension of an existing system covered by this Contract does not extend to modification of building structural, mechanical, or electrical components, even though this work may be incidental to – and or necessary for – repair/modification unless approved in advance by ordering entity or already specified by the Contract.

Change Orders.

The Contractor can only proceed with work beyond the work authorized by a purchase order if the ordering entity has approved the change and a Change Orders is being issued. The ordering entity may authorize change orders in writing or verbally.

The ordering entity may require, or the Contractor may make a written request (describing the nature of the proposed change) for certain changes in the scope of work described in a purchase order. If the ordering entity agrees to the changes and the costs for the changes, a Change Order will be issued. Change Orders will only be considered if they are based on materially different work conditions that could not have been expected from available information at the time the original purchase order was issued. Verbal authorizations for a Change Order must be followed up with a written Change Order as soon as possible.

Security.

Agencies will include their security requirements, if any, on each purchase order that they issue. Some Agencies require that the Contractor and its employees entering their facilities possess a current photo identification card or no entry will be allowed. Some secure facilities require that all vehicles entering and leaving the facility be searched.

The Contractor and its employees shall note that introducing contraband upon the grounds of such secure facilities is a violation of State Law and could result in prosecution.

Rev. 07.01.2024 Department of Military Affairs

Removed Items and Clean-Up.

The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. Upon completion of the work, the Contractor shall remove and legally dispose of waste materials, rubbish, the Contractor’s tools, equipment, machinery, and surplus materials from and about the project premises and surrounding area daily. The cost of cleanup performed by the ordering entity as a result of the Contractor’s failure to provide the cleanup required by this solicitation shall be deducted at the actual cost to the State from the Contract sum.

When removal and disposal of non-hazardous debris is performed on a job site, receipt for disposal and manifest documentation must be included with the final invoice.

Submittals.

Contractor must submit all documents as required by the contract. Documents required to be submitted include, but are not limited to:

• Minnesota Department of Revenue online “Contractor Affidavit” form or paper IC134 form as required by the Compliance with Tax Laws Requirement clause in Exhibit A of the Contract. Email the State of Minnesota Prevailing Wage Payroll Report and Statement of Compliance form as required by the Contract to the address listed on the purchase order.

Rev. 07.01.2024 Department of Military Affairs

Exhibit A, Supplement 1

MINNESOTA DEPARTMENT OF LABOR AND INDUSTRY PREVAILING WAGES FOR STATE FUNDED CONSTRUCTION PROJECTS

Construction Type: Commercial County Number: 49 County Name: MORRISON Effective: 2023-12-26 Revised: 2024-02-05

This project is covered by Minnesota prevailing wage statutes. Wage rates listed below are the minimum hourly rates to be paid on this project.

These rates will apply for the term of the awarded contracts.

All hours worked in excess of eight (8) hours per day or forty (40) hours per week shall be paid at a rate of one and one half (1 1/2) times the basic hourly rate. Note:

Overtime pay after eight (8) hours on the project must be paid even if the worker does not exceed forty (40) hours in the work week.

105 WATCH PERSON FOR RATE CALL 651-284-5091 OR EMAIL

DLI.PREVWAGE@STATE.MN.US

106 BLASTER FOR RATE CALL 651-284-5091 OR EMAIL

107* PIPELAYER (WATER, SEWER,

AND GAS)

2023-12-26 32.95 21.79 54.74

2024-05-01 35.73 22.49 58.22

Violations should be reported to:

Department of Labor and Industry Prevailing Wage Section 443 Lafayette Road N St Paul, MN 55155

(651) 284-5091 DLI.PrevWage@state.mn.us

* Indicates that…