RFB 2024 _ 06 _ Revere Street Groundwater Wel.pdf

12453 Highway 92, Woodstock, GA 30188 770‐592‐6000 ∙ www.woodstockga.gov

REQUEST FOR BIDS

For

REVERE ST GROUNDWATER WELL SITE

RFB NUMBER

2024 – 06

RELEASED:

December 14, 2023

DUE:

January 23, 2024 10:00 A.M. EST

For all questions about this RFB contact:

Martyn Detz Purchasing Coordinator 770‐592‐6000 Ext 1205 https://vrapp.vendorregistry.com/Vendor/Register/Index/woodstock‐city‐ga‐vendor‐registration

RFB Number 2024 – 06 Page 2

TABLE OF CONTENTS

1.0 PURPOSE OF SOLICITATION

1.1 PURPOSE OF BID

1.2 RFB SUBMISSION

1.3 SCHEDULE OVERVIEW

1.4 PRE‐BID / SITE VISIT

1.5 RFB COSTS

1.6 RFB QUESTIONS/COMMUNICATIONS

1.7 RFB AMENDMENTS

1.8 NON‐COLLUSION AFFIDAVIT

1.9 COMPLIANCE WITH LAWS

1.10 BID & AWARD BASIS

1.11 REQUIRED BONDS AND INSURANCE

1.12 TIME OF COMPLETION AND LIQUIDATED DAMAGES

1.13 TAXES, FEES, CODE COMPLIANCE AND LICENSING

1.14 REFERENCES AND PROPRIETARY INFORMATION

1.15 ILLEGAL IMMIGRATION REFORM AND ENFORCEMENT ACT OF 2011

1.16 ANTI‐BOYCOTT OF ISRAEL

2.0 SCOPE OF WORK

2.1 TYPE OF GOOD/SERVICE AND OBJECTIVES:

2.2 PROJECT GENERAL NOTES

2.2.1 ENVIRONMENTAL REQUIREMENTS

2.2.2 MEASURES AND WEIGHTS

2.2.3 BUILDINGS AND SHANTIES

2.3 BRAND NAME

2.4 DELIVERY TIME

2.5 AWARD AND PRICING INFORMATION

2.6 PAYMENT TO CONTRACTOR AND RETAINAGE

3.0 BID FORMAT

4.0 OTHER ITEMS

4.1 TERMS AND CONDITIONS

4.2 REJECTION OF BIDS/CANCELLATION OF RFB

4.3 BID WITHDRAWAL

4.4 MISCELLANEOUS

EXHIBIT A CONTRACTOR INFORMATION FORM

EXHIBIT B E‐VERIFY AFFIDAVIT WITH INSTRUCTIONS

EXHIBIT C BID PROPOSAL FORM

EXHIBIT D ITEMIZED PRICING SHEET

EXHIBIT E SITE PLANS

EXHIBIT F TECHNICAL SPECIFICATIONS

EXHIBIT G CONTRACT

EXHIBIT H VENDOR CONFLICT OF INTEREST

RFB Number 2024 – 06 Page 3

1.0 PURPOSE OF SOLICITATION

1.1 Purpose of Bid

The City of Woodstock, Georgia, herein referred to as the City, is accepting bids from qualified contractors for the purpose of installation of a well pump and construction of a treatment building along Revere Drive. This includes but is not limited to installation of a well pump, treatment building, water main piping and valves, electrical/controls, chemical feed systems, SMART system, erosion control, fenced enclosure, grassing and related appurtenances, hereinafter referred to as the “Project”. The well has already been drilled and the riser pipe has been installed; the riser pipe will need to be extended during installation.

1.2 RFB Submission

Interested parties must submit proposals electronically through Vendor Registry to the City of Woodstock, Georgia by the due date for their proposals to be considered. Vendor Registry can be found directly at https://vrapp.vendorregistry.com/Vendor/Register/Index/woodstock‐city‐ ga‐vendor‐registration or by visiting the City of Woodstock’s website.

Fax and e‐mail responses are not acceptable.

Responses to this RFB will be accepted until 10:00 a.m. (EST) on January 23, 2024 through

Vendor Registry.

The City of Woodstock, Georgia reserves the right to reject any and all responses resulting from this RFB. Late responses will not be accepted. If company response is sent or routed to City offices, the submission requirement has not been met and any such response will not be evaluated and will be disqualified from consideration.

1.3 Schedule Overview

This Request for Bids is scheduled as follows:

December 14, 2023

January 4, 2024, 3:00 P.M.

January 11, 2024, 5:00 P.M.

January 16, 2024, 5:00 P.M.

Release of RFB

Pre‐bid/ Site Meeting

Question Deadline

Responses Posted

January 23, 2024, 10:00 A.M. Bids Due Date

January 23, 2024, 10:01 A.M. Public Opening

February 2024 RFB and Contract Award

RFB Number 2024 – 06 Page 4

1.4 Pre‐Bid / Site Visit

A pre‐bid conference / site visit (not mandatory) for all bidders will be held at the job site located at 502 Revere Street on January 4th at 3:00 pm.

1.5 RFB Costs

All costs incurred in the preparation and presentation of responses to the RFB shall be completely absorbed by the RFB respondent. All documents submitted as part of the RFB will become property of the City. Requests for specific material to be returned will be considered. Any material submitted that is confidential must be clearly marked as such.

1.6 RFB Questions/Communications

All questions about this RFB and submission requirements must be submitted in writing through Vendor Registry. The City’s representative listed in this section will serve as the primary contact for this RFB.

Martyn Detz

Purchasing Coordinator

12453 Highway 92

Woodstock, Georgia 30188

770‐592‐6000 ext. 1205 https://vrapp.vendorregistry.com/Vendor/Register/Index/woodstock‐city‐ga‐vendor‐ registration

Any unauthorized contact shall not be responded to and may result in the disqualification of the responder’s submittal. Answers to questions submitted via Vendor Registry will be communicated to respondents via Vendor Registry.

Communications by companies, its agents, employees, and/or representatives regarding its bids or intention to submit a bid in response to this RFB with any employee, agent, or representative of the City of Woodstock, other than the representative listed in Section 1.5, may be considered inappropriate communications.

If any such inappropriate communications are deemed to hinder, influence and/or alter the competitive bid process, the City, in an effort to ensure a fair and equitable review and selection process, reserves the right to decline consideration of the offender’s sealed bid.

1.7 RFB Amendments

It is the responsibility of respondents to check Vendor Registry or the Georgia Procurement

Registry for RFB information and addendums.

RFB Number 2024 – 06 Page 5

1.8 Non‐Collusion Affidavit

By submitting a bid, the respondent represents and warrants that no official or employee of the City has an interest, directly or indirectly, in the bid or in the final contract award. The respondent further understands bids will be rejected if there is any evidence of collusion with another respondent.

Respondent certifies that this qualification, offer, or bid is made without prior understanding, agreement, or connection with any corporation, firm, or person submitting a qualification, offer, or bid for the same materials, supplies, services, or equipment and is in all respects fair and without collusion or fraud. Respondent understands collusive bidding is a violation of state and federal law and can result in fines, prison sentences, and civil damage awards. Respondent agrees to abide by all conditions of this qualification, offer, or bid.

Furthermore, the respondent certifies that the firm has not divulged to, discussed or compared his bid with other respondents and has not colluded with any other respondent or parties to this bid whatsoever. Also, respondent certifies, and in the case of a joint bid each party thereto certifies as to his/her own organization, that in connection with this bid:

Any prices and/or cost data submitted have been arrived at independently, without consultation, communication, or agreement, for the purpose of restricting competition, as to any matter relating to such prices and or cost data, with any other respondent or with any competitor;

Any prices and/or cost data quoted for this bid have not been knowingly disclosed by the respondent and shall not knowingly be disclosed by the respondent prior to the scheduled opening directly or indirectly to any other respondent or to any competitor;

No attempt has been made or shall be made by the qualifier to induce any other person or firm to submit a bid for the purpose of restricting competition;

The only person or persons interested in this bid, principal/principals is/are named therein and that no person other than therein mentioned has any interest in his bid or in the contract to be entered into; and

No person or agency has employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or established commercial agencies maintained by the Purchaser for the purpose of doing business

1.9 Compliance with Laws

Respondents agree to be bound by applicable Federal, State and Local laws, regulations and directives.

RFB Number 2024 – 06 Page 6

1.10 Bid & Award Basis

The City reserves the right to accept or reject any and all bids or any or parts of a bid wherein its judgment, it will be in the best interest of the City; waive any technicalities/informalities in the RFB document and bid process; and to qualify and award any or all of this contract in any manner in which the City, acting in the sole and exclusive exercise of its discretion, deems to be in the City’s best interest. If no acceptable bid is received, the City also reserves the right to re‐ solicit bids, at its sole discretion.

1.11 Required Bonds and Insurance

No bid may be withdrawn for a period of sixty (60) days after time has been called on the date of opening.

All bids must be accompanied by a certified check or bid bond of a reputable bonding company authorized to do business in the State of Georgia, in an amount equal to at least five percent

(5%) of the total amount of the bid.

Upon the award of this RFB, the contractor shall provide the City with:

A 100% project value performance and payment bonds pursuant to O.C.G.A. § 36‐91‐70 and 90.

Worker’s Compensation – Statutory (for the State of Georgia and the State of domicile of the Contractor).

Manufacturers’ and Contractor’s Liability, covering operations performed by or for the

Contractor, with limits of not less than Bodily Injury – $500,000/$1,000,000. Property

Damage ‐ $500,000.

Contractor Liability, covering liability of others assumed by the Contractor elsewhere in the contract under “Hold Harmless” Agreements or similar assumptions of liability.

Evidence of required bonds and insurance shall be presented prior to the execution of the

Contract. The Bonding Company must be licensed to do business in the State of Georgia, licensed to do business by the Georgia Secretary of State, authorized to do business in Georgia by the Georgia Insurance Department, listed in the Department of the Treasury’s Publication of

Companies Holding Certificates of Authority as Acceptable Surety of Federal Bonds and as

Acceptable Reinsuring Companies and have an A.M. Best rating of A‐, Class VI or Higher.

Insurance policies to be carried under the agreement shall not be changed or canceled without prior written notification to the City of Woodstock, Georgia.

RFB Number 2024 – 06 Page 7

1.12 Time of Completion and Liquidated Damages

Bidder hereby agrees to commence work under this contract on or before a date to be specified in a written "Notice to Proceed" of the City and to fully complete the project within ninety (90) consecutive calendar days; bidder further agrees to pay as liquidated damages the sum of $250 per each consecutive calendar day that the Contractor shall be in default after the date stipulated in the Contract for completing work.

1.13 Taxes, Fees, Code Compliance and Licensing

The firm shall be responsible for the payment of any required taxes or fees associated with the execution of this contract. The firm shall also be responsible for compliance with all applicable codes and statutes.

1.14 References and Proprietary Information

Submission of a bid authorizes the City to make inquiries concerning the respondent and its officers to any persons or firms deemed appropriate by the City. Any proprietary information that the respondent does not want disclosed to the public shall be so identified on each page in which it is found. Data or information so identified will be used by the City solely for the purpose of evaluation and contract negotiations only.

1.15 Illegal Immigration Reform and Enforcement Act of 2011

By providing a qualification or bid, qualifier/bidder certifies that he/she is in compliance with

O.C.G.A. § 13‐10‐90 and 91, et seq. No qualification or bid will be considered by the City unless it is accompanied with a signed, notarized affidavit (EXHIBIT B) from the qualifier/bidder attesting to the following:

a) The affiant has registered with and is authorized to use and uses the federal work authorization program

b) The user identification number and date of authorization for the affiant; and

c) The affiant will continue to use the federal work authorization program throughout the contract period; and

The affiant will contract for the physical performance of services in satisfaction of such contract only with subcontractors who present an affidavit to the contractor with the same information required in subparagraphs (a), (b) and (c) of this paragraph.

1.16 Anti‐Boycott of Israel

By signing and submitting this bid and pursuant to O.C.G.A. § 50‐5‐85, respondent/bidder certifies that it is not currently engaged in, and agrees that for the duration of this agreement, it will not engage in a boycott of Israel.

RFB Number 2024 – 06 Page 8

2.0 SCOPE OF WORK

2.1 Type of Good/Service and Objectives:

The City of Woodstock, Georgia, herein referred to as the City, is accepting bids from qualified contractors for the purpose of installation of a well pump and construction of a treatment building along Revere Drive. This includes but is not limited to installation of a well pump, treatment building, water main piping and valves, electrical/controls, chemical feed systems, SMART system, erosion control, fenced enclosure, grassing and related appurtenances, hereinafter referred to as the “Project”. The well has already been drilled and the riser pipe has been installed; the riser pipe will need to be extended during installation.

The contractor shall be responsible for furnishing all materials, labor, and equipment.

The work to be completed consists of the below listed goods and services which shall meet or exceed the specification below:

‐ Well Pump and Installation

‐ Treatment Building

‐ Water Main piping and Valves

‐ Electrical and controls

‐ Chemical Feed systems

‐ SMART System

‐ Perimeter Fenced Enclosure and Gate

‐ Erosion control and Grassing

‐ Access Drive

‐ Work hours are from 7 am to 7 pm Monday – Saturday; 12 – 6 pm on Sundays

‐ Shall conform to federal, state, and local requirements and regulations.

2.2 Project General Notes

See Exhibit E engineer drawing for full details on the project general notes and maintenance of traffic guidelines.

‐ On sheet 10, “Pipe Transition Detail,” it says see detail page 12. That is for the Thrust Blocks details and table on sheet 12. The connection of the 4 to the 16 would be a standard tap.

‐ On sheet 13, there is a note on the CMU Wall Construction Detail that says, “Paint to be coordinated with the City.” The exterior walls of the well houses have painted board and batten cover just like your other well houses. The City picks the color of the paint.

See Exhibit F for full list of technical specifications.

See Exhibit G for a draft of the contract.

RFB Number 2024 – 06 Page 9

The new well has been pretested for performance. The current water rate is 85 gpm.

See Exhibit I for tables from testing.

Water can be provided via a nearly fire hydrant.

For City of Woodstock Standard development Regulations see – http://library.municode.com/ga/woodstock/codes/land_development_code

There are no geo‐technical reports available to the contractor.

No requirements for underground electrical. Use underground rated cables and mark above the wire run with tape.

No building permits or fees required.

On Site testing of the soil compaction is required.

The City has already paid for the 3 phase power from GA Power Co.

Copies of Specifications and Construction Drawings may be obtained from Rindt‐McDuff Associates, Inc. (Gainesville office). The Information for Bidders, Drawings, and Specifications may be examined or requested from the below mentioned contact:

Rindt‐McDuff Associates, Inc.

445 Bradford Street NW Gainesville, GA 30501 Phone: (770) 531‐5109 Fax: (770) 531‐5112 Email: brindt@rindt.com Contact: Brian Rindt, P.E.

2.2.1 Environmental Requirements

Reference Clean Air and Water Acts.

A. Air Pollution

1. The CONTRACTOR shall be responsible for any necessary burning permits.

B. Stream Pollution

1. Conduct all work in such a manner as to prevent stream siltation.

2. No discharges for untreated or partially treated wastewater to streams is allowed.

RFB Number 2024 – 06 Page 10

2.2.2 Measures and Weights

To aid the ENGINEER in determining all quantities, the CONTRACTOR shall, whenever so requested, provide scales, equipment, and assistance for weighing or for measuring any of the materials.

It is understood and agreed that a "ton" shall mean the short ton of two thousand (2,000) pounds. Weights and measures of quantity for payment will be the actual weight or actual measure, and no special or trade or so‐termed customary allowances will be made, nor will any material which is lost or misplaced be included for payment.

2.2.3 Buildings and Shanties

No shanties, camps, or buildings for the housing of men employed on the WORK shall be erected on land owned or leased by the OWNER without written permission of the OWNER. Should permission be asked and granted, the CONTRACTOR must comply with all Local and County regulations regarding the construction and maintenance of such buildings.

2.2.4 Construction Clearing

Whole clearing of construction rights‐of‐way, easements, or construction sites will not be allowed. Clearing shall be minimized, and the CONTRACTOR shall make every effort to save trees, shrubs and bushes that are within the construction limits. Timber which is cut shall remain the property of the land owner where the cutting occurred.

All trees within the working easements shown on the CONTRACT DOCUMENTS are property of the existing land owners. If the property owner wishes to keep the timber, the CONTRACTORS shall cut the timber in reasonable lengths and stack such timber on OWNER's property. If the property owner does not wish to keep the timber, the timber shall become the property of the CONTRACTOR and shall be removed from the site and disposed of at the CONTRACTOR's expense. All stumps, rubbish, and other material, not suitable as timber, shall be removed from the site at the CONTRACTOR's expense.

We do not plan on keeping the timber from this site.

2.3 Brand Name

Unless otherwise specified, the items in this bid have been identified, described, and referenced by a brand name or trade name/mark that is intended to be descriptive, but not restrictive, and is used to indicate the quality and characteristics of products that may be offered.

Other products may be considered for award if such products are clearly identified in the bid and are determined by the City to meet its needs in all respects. It shall be the responsibility of the bidder(s), including the bidder whose product is referenced, to indicate the brand name and model or series number of the product offered and to furnish with their bid such specifications, catalog pages, brochures, or other data that will provide an adequate basis for determining the quality and functional capabilities of the product offered.

RFB Number 2024 – 06 Page 11

However, the City may elect to purchase brand name products or services when the goods comprise a major brand system, program, or service previously selected by the City and due to operation effectiveness, future enhancements or additions, or maintenance and storage of spare parts preclude the mixing of brands, manufactures, etc.

Any information provided should be properly labeled. The City reserves the right to request product demonstrations and/or samples from any bidders prior to bid award. Failure to provide the requested data or product demonstrations and/or samples may be considered valid justification for rejection of bid.

2.4 Delivery Time

This is a time sensitive project. All work must be completed within 180 days after a notice to proceed has been issued, pending any unnatural weather occurrence.

The contractor shall coordinate construction dates and times with the City of Woodstock, Georgia Public Works Director.

Available work hours shall be in accordance with City ordinance; Shall conform to federal, state and local requirements and regulations.

2.5 Award and Pricing Information

The City intends to award to a single Contractor. The City may award the entire project or portions of the project to a single Contractor.

Pricing should be itemized for the project. The Bid Proposal Form and Itemized Pricing Sheet in Exhibit D must be completed and returned with bid submittal.

Pricing shall be valid for a period of 60 days after submission date.

The Contract will be awarded to the lowest, responsive, responsible Bidder as determined by the review committee and as approved by City Council.

2.6 Payment to Contractor and Retainage

All work must be approved prior to the release of payment.

The Contractor shall submit a progress payment request after thirty (30) days for the completed work. The City shall make a progress payment to the Contractor on the basis of a duly certified and approved progress payment for the work performed during the thirty (30) days under this contract, but to insure the proper performance of this Contract, the City shall retain five percent (5%) of the amount of each pay app as retainage if such work is satisfactory and completed on schedule as determined with the City.

3.0 BID FORMAT

1. Exhibit A: Contractor Information Sheet ‐ If the firm has branch offices, state the office that will have management responsibility for the work to be carried out.

RFB Number 2024 – 06 Page 12

2. Completed Exhibit B: E‐Verify Affidavit with Instructions.

3. Pricing should be itemized as specified on the pricing sheet for the City in Exhibit D. The Bid Proposal Form and Lump Sum Pricing Sheet must be completed and returned with bid submittal.

4. A copy of the firm’s Public Liability Insurance, Workers’ Compensation and Commercial General Liability Insurance.

5. Annotated list of references (with addresses and telephone numbers).

6. Copy of Georgia Business License

7. Bid bonds (5% of total bid amount)

a. 100% project value performance and payment bond (pending contract award)

A clear, concise bid in the specified bid format is requested with all the necessary information included. Responses to this RFB will be accepted until 10:00 a.m. (EST) on January 23, 2024 through Vendor Registry. Bids will be publicly opened and read aloud virtually via GoTo

Meetings on January 23, 2024, 10:01 A.M.

4.0 OTHER ITEMS

4.1 Terms and Conditions

1. The City of Woodstock, Georgia hereby requests bids for the goods and services inclusive of the services requested in the RFB.

2. City of Woodstock, Georgia reserves the right to evaluate the firm’s bids. Only those firms who, in the opinion of the City, meet the minimum necessary bids will have their price and contract/agreement evaluated.

3. All bids, fee schedules and other documents furnished to the City of Woodstock, Georgia are subject to the Georgia Open Records Act.

4. Termination: The contract will be subject to the terms and conditions included in the

Service Agreement. The City of Woodstock, Georgia reserves the right to cancel the agreement with cause, due to nonperformance and/or violation of contract terms.

5. The City shall be notified of business name change(s) in writing within thirty (30) days of changes.

6. The City shall be notified and approve of key personnel change(s) in writing prior to any changes.

4.2 Rejection of Bids/Cancellation of RFB

The City of Woodstock, Georgia reserves the right to reject any or all bids, to waive any irregularity or informality in a bid, and to accept or reject any item or combination of items, when to do so would be to the advantage of the City.

RFB Number 2024 – 06 Page 13

It is also within the right of the City to reject bids that do not contain all elements and information requested in this document. The City reserves the right to cancel this RFB at any time. The City will not be liable for any cost/losses incurred by the Offerors throughout this process.

4.3 Bid Withdrawal

A submitted bid may be withdrawn prior to the due date by a written request to the City representative listed in Section 1.5. A request to withdraw a bid must be signed by an authorized individual of the submitting company.

4.4 Miscellaneous

This RFB and any agreements related thereto must comply, inter alia, with all City laws and charters and are subject to all requisite City approvals including, but not limited to, City

Management and City Council.

The City reserves the right to release modifications to this RFB or supplements to it from time to time. Firms are responsible for periodically checking Vendor Registry or the Georgia

Procurement Registry for such modifications or supplements.

This Section Intentionally Left Blank

RFB Number 2024 – 06 Page 14

EXHIBIT A CONTRACTOR INFORMATION FORM

See following page.

City of Woodstock

12453 Hwy 92 • Woodstock, GA • 30188 • 770-592-6000 • www.woodstockga.gov

CONTRACTOR INFORMATION

Firm Name:

Contact Person:

Firm Address:

Phone:

Fax:

Email:

With this packet, please also provide a W-9 and Certificate of Insurance for the company/firm.

Signature – Authorized Officer or Agent Date http://www.woodstockga.gov/

RFB Number 2024 – 06 Page 15

EXHIBIT B E‐VERIFY AFFIDAVIT WITH INSTRUCTIONS

See following page(s).

INSTRUCTIONS

CONTRACTOR AFFIDAVIT AND AGREEMENT

By executing this affidavit, the undersigned contractor verifies its compliance with O.C.G.A. § 13- 10-91, stating affirmatively that the individual, firm, or corporation which is contracting with the City of Woodstock, Georgia (the “City”) has registered with and is participating in a federal work authorization program commonly known as E-Verify, or any subsequent replacement program, in accordance with the applicable provisions and deadlines established in O.C.G.A. § 13-10-91.

Furthermore, the undersigned contractor will continue to use the federal work authorization program throughout the contract period and the undersigned contractor will contract for the physical performance of services in satisfaction of such contract only with subcontract who present an affidavit to the contractor with the information required by O.C.G.A. § 13-10-91(b). Contractor hereby attests that its federal work authorization user identification number and date of authorization are as follows:

Federal Work Authorization User Identification Number

Date of Authorization

Name of Contractor

Name of Project Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on __________________, 201____ in ________________ (city), ______ (state).

Signature of Authorized Officer or Agent

Printed Name and Title of Authorized Officer or Agent

Subscribed and Sworn before me this the________ day of _______________, 201____, Notary Public My Commission Expires INSTRUCTIONS ONLY - C

OM

PLE

TE

FOLLOWING PAGE

E-Verify/Company ID Issued by the E-Verify Program

Date E-Verify/Company ID was issued by E-Verify

Contractor's Company/Firm Name

Name of project or type of service provided

City of Woodstock, Georgia http://www.woodstockga.gov/ welchcl Highlight welchcl Highlight

CONTRACTOR AFFIDAVIT AND AGREEMENT

By executing this affidavit, the undersigned contractor verifies its compliance with O.C.G.A. § 13- 10-91, stating affirmatively that the individual, firm, or corporation which is contracting with the City of Woodstock, Georgia (the “City”) has registered with and is participating in a federal work authorization program commonly known as E-Verify, or any subsequent replacement program, in accordance with the applicable provisions and deadlines established in O.C.G.A. § 13-10-91.

Furthermore, the undersigned contractor will continue to use the federal work authorization program throughout the contract period and the undersigned contractor will contract for the physical performance of services in satisfaction of such contract only with subcontract who present an affidavit to the contractor with the information required by O.C.G.A. § 13-10-91(b). Contractor hereby attests that its federal work authorization user identification number and date of authorization are as follows:

Federal Work Authorization User Identification Number

Date of Authorization

Name of Contractor

Name of Project

Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on _______________, 202____ in ________________ (city), _________ (state).

Signature of Authorized Officer or Agent

Printed Name and Title of Authorized Officer or Agent

Subscribed and Sworn before me this the________ day of _______________, 202____, Notary Public My Commission Expires http://www.woodstockga.gov/

RFB Number 2024 – 06 Page 16

EXHIBIT C BID PROPOSAL FORM

Proposal of_________________________ (hereinafter called "Bidder") a contractor organized and existing under the laws of the State of ______________ , * an individual, a corporation, or a partnership doing business as __________________________.

TO: City of Woodstock, Georgia (Hereinafter referred to as "City")

The Bidder, in compliance with your invitation for bids for the work as described in Section 2.0 of

RFB 2024 – 06

THE REVERE PRODUCTION WELL AND TREATMENT BUILDING

having examined the scope of work with related documents and the site of the proposed work, and being familiar with all of the conditions surrounding the scope of work of the proposed Project, including the availability of materials and labor, hereby proposes to furnish all labor, materials, and supplies, and to construct the Project in accordance with the Contract Documents, within the time set forth herein, and at the prices stated in the bid submission. These prices are to cover all expenses incurred in performing the work required under this Contract, of which this bid is a part.

Amount shall be shown in figures. The prices in the bid submittal shall include all labor, materials, removal, overhead, profit, insurance, etc., to cover the finished work of the project as stated in the contract.

Total Price: $ _____________________________

Bidder hereby agrees to commence work under this Contract on or before a date to be specified in a written "Notice to Proceed" of the City and to fully complete the Project within ONE‐HUNDRED AND

EIGHTY (180) consecutive calendar days; bidder further agrees to pay as liquidated damages the sum of $250 per each consecutive calendar day that the Contractor shall be in default after the date stipulated in the contract for completing the work.

Bidder understands that the City reserves the right to reject any or all bids and to waive any informalities in the bidding.

The Bidder agrees that this bid shall be good and may not be withdrawn for a period of 60 calendar days after the scheduled closing time for receiving bids.

RFB Number 2024 – 06 Page 17

The Bidder declares that he understands that the quantities shown on the bid are subject to adjustment by either increase or decrease, and that should the quantities of any of the items of work be increased, the undersigned proposes to do the additional work at the unit prices stated herein; and should the quantities be decreased, he also understands that payment will be made on actual quantities at the unit price bid and will make no claim for anticipated profits for any decrease in the quantities and that actual quantities will be determined upon completion of work, at which time adjustment will be made to the Contract amount by direct increase or decrease.

The full name and residence of persons or parties interested in the foregoing bids, as principals, are named as follows:

The____ day of_______________ , 20____ .

Signature:

Printed:

Title:

RFB Number 2024 – 06 Page 18

EXHIBIT D LUMP SUM PRICING SHEET

Please use ‘Exhibit D’ as provided in a separate document file.

WELL SITE LUMP SUM BID

No. Description Quantity Units Unit Price Total Price

Temporary Erosion Control in accordance with construction plans, including but not limited to: Silt Fence (Type C), Riprap Check Dams (Cd), Straw Mulch Stabilization (Dsl), Temporary Grassing (Ds2), Construction Exits (Co) and Temporary Grassing.

1 LS $___________ $___________

2 Well Pump and Installation 1 LS $___________ $___________

3 Treatment Building 1 LS $___________ $___________

4 Water Main Piping and Valves 1 LS $___________ $___________

5 Electrical and Controls 1 LS $___________ $___________

6 Chemical Feed Systems 1 LS $___________ $___________

7 SMART System 1 LS $___________ $___________

8 Perimeter Fenced Enclosure and Gate 1 LS $___________ $___________

9 Erosion Control and Grassing (Ds3) 1 LS $___________ $___________

10 Access Drive 1 LS $___________ $___________

All else for a complete installation as shown on the plans 1 LS

LUMP SUM AMOUNT: $

LUMP SUM AMOUNT AMOUNT (IN WORDS):

LUMP SUM ALLOWANCE AMOUNTS

The Bidder shall include in the sum of all lump sum bids the lump sum allowances identified below.

Payment will be in accordance with the General Conditions. Any unused balance of the allowances shall revert to the Owner upon completion of the project.

No. Description Quantity Unit Lump Sum Price

(in figures) Total Price (in figures)

1 Allowance for correction of unforeseen utility conflicts and utility relocation.

As determined by Owner

N.A. $25,000 $25,000

2 Allowance for Owner initiated miscellaneous work.

As determined by Owner

N.A. $25,000 $25,000

TOTAL BID AMOUNT: $

TOTAL BID AMOUNT (IN WORDS):

Note: Payment will only be made for the items, listed within the Bid Schedule. Bidder/Contractors shall include any/all costs for work incidental to a pay item within the applicable pay items. For any/all work for which a specific pay item is not provided, the bidder/contractor shall distribute the costs for such among the items for which payment is allowed. After the Contract is awarded, the Contractor shall only be paid for the pay items listed. Failure of a bidder/contractor to include/ distribute any/all costs for the complete work within the items listed shall not be considered sufficient reason for additional payment to the Contractor.

BIDDER hereby agrees to commence work under this contract on or before a date to be specified in a written "Notice to Proceed" from the OWNER and to fully complete WORK within a total construction time of 150 consecutive calendar days for the date specified in this "Notice to Proceed". BIDDER acknowledges receipt of the following addenda:

Addenda No. Date Received

BIDDER agrees to perform all of the construction of the project complete with appurtenances and accessory work described in the Specifications and shown on the Drawings for the above scheduled price.

BIDDER agrees that their bid shall be good and may not be withdrawn for a period of 60 calendar days after the scheduled closing time for receiving bids.

Upon receipt of the written notice of the acceptance of this bid, BIDDER will execute the formal Contract attached within ten (10) days and deliver a surety bond or bonds, as required by the General Conditions.

The bid security attached in the sum of five (5%) percent of the total bid is to become the property of the OWNER in the event the Contract and bond are not executed within the time set forth, as liquidated damages for the delay and additional expense to the OWNER caused thereby.

Respectfully Submitted: Name:

Address:

FEDERAL TAX NO. OR.:

SOCIAL SECURITY NO.

Signature (Principal):

Title:

Date:

ATTEST:

Signature:

Corporate Secretary/Partner/Notary (SEAL)

Name:

(Please type)

NOTE: Attest for a corporation must be by the corporate secretary; for a partnership by another partner; for an individual by a Notary.

RFB Number 2024 – 06 Page 19

EXHIBIT E SITE PLANS

ARNOLD MILL ROAD

WASHINGTON AVE

RU

BE

S

CR

EE

K

INDEPENDENCE WAY

R E

V E

R E

D R

IV

E

H E

R

IT

A G

E R

O W

COLONY CT

N E

E S

E R

O A

D

EDINBURGH LANE

GRAND OAKS DR

MELROSE CIR

WAVERLY PL

GRAND OAKS LN

GRAND OAKS DR

JEFFERSON DR

HAMILTON DR

N E

E S

E R

O A

D

MIDDLETON PASS

ROKEBY DR

POTOMAC CT

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(r ev er e si te )\D ra w in gs

\R

-1

C ov er .d w g

5/

/2

:3

8p m e le br on

DRAWING INDEX

SHEET DESCRIPTION

COVER

EXISTING CONDITIONS

SITE PLAN

GRADING PLAN

HYDRAULIC GRADE

MECHANICAL PROFILE

MECHANICAL PLAN

EROSION CONTROL PLAN

ES &PC PLAN DETAILS

MECHANICAL DETAILS

MECHANICAL DETAILS

CONSTRUCTION DETAILS

CONSTRUCTION DETAILS

CONSTRUCTION DETAILS

ELECTRICAL PLAN AND NOTES

ELECTRICAL PLAN AND NOTES

CONTACTS

OWNER/DEVELOPER: CIVIL ENGINEER:

CONSTRUCTION PLANS FOR PERMITTING

24 HR CONTACT:

MIKE STONEBRIDGE

(770) 592-6250

RMA CONTACT:

BRIAN RINDT

770-361-6535

FOR

CITY OF WOODSTOCK, GEORGIA

LOCATED IN CHEROKEE COUNTY, GEORGIA

LAND LOT(S): 1063

DISTRICT 15th

CONSTRUCTION PLANS

DISTURBED AREA = 0.11 ACRES

SITE MAP

N.T.S.

N

LOCATION MAP

N.T.S.

Sheet No.

LAND SURVEYOR:

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

WELL NO. 6 REVERE DRIVE - PUMP HOUSE

POWER:

SITE

www.RINDT.com

334 Cherokee Street - Marietta, Ga. 30060 Phone: (770) 427-8123

IE: 872.08

IE: 872.51

W

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

28"Ø 15"Ø

27"Ø

WALL

W

ALL

CONCRETE SWALE

36" CMP

GRAVEL

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

878870

R

EV

ER

E

D R

IV

E

' R

/W

2 @ 10"Ø

Toe

MCE

Toe 24"Ø

TREES TO BE

REMOVED (TYP.)

LIMITS OF

DISTURBANCE

CONTRACTOR TO

PROTECT EXISTING

WATER SERVICES

CONTRACTOR TO REPLACE ANY

GRAVEL TO EXISTING CONDITIONS

LIMITS OF

DISTURBANCE

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

RINDT-M

CDUFF ASSO

CIATES

N

GRAPHIC SCALE

( IN FEET )

1 inch = ft.10

10 5 10 20 40 Pr oj ec t N o:

Sheet No.

C he ck ed

D es ig n:

D ra w n:

Sc al e:

R

-1

/8

/2

D at e:

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(re ve re s ite

)\D ra w in gs \R

-1

D es ig n.

dw g

5/

/2

:3 9p m e le br on

N o.

R ev is io ns D at e

R

-1

D es ig n.

dw g

In iti al

PR

O

D U

C

TI

O N

W

EL

LS

A

N D

T R

EA

TM

EN

T

BU

IL

D

IN

G S

C

IT

Y O

F W

O O

D

ST

O C

K ww w.

RI

ND

T.

co m

4 C he ro ke e S tre et

- M ar iet ta, G a.

Ph on e:

(7

) 4

-8

AA

B

BA

R BA

R

1" =1

0'

EX

IS

TI

N G

C O

N D

IT

IO

N S

D

EM

O

LI

TI

O N

P

LA

N

WSK-D1 PRODUCTION WELL

N:1491637.6995 E:2195569.9350

ELEVATION: 867.0

A. PROTECTION:

1. PERFORM DEMOLITION SO AS TO PREVENT DAMAGE TO ADJACENT

IMPROVEMENTS AND TREES TO REMAIN.

2. PROTECT NEW OR EXISTING WORK FROM DAMAGE DURING DEMOLITION

OPERATIONS.

3. PROTECT EXISTING SITE APPURTENANCES AND LANDSCAPING TO REMAIN.

4. DAMAGES: WITHOUT COST TO THE OWNER AND WITHOUT DELAY, REPAIR ANY

DAMAGES CAUSED TO FACILITIES TO REMAIN.

5. CONTRACTOR TO MAINTAIN ONE LANE OF TRAFFIC AT ALL TIMES.

6. CONTRACTOR TO ESTABLISH TEMPORARY SUPPORT FOR EXISTING UTILITIES

AND MAINTAIN IT THROUGHOUT CONSTRUCTION AS NEEDED.

7. CONTRACTOR TO MAINTAIN UTILITY SERVICE DURING CONSTRUCTION, WITH

MINIMAL INTERRUPTION.

8. CONTRACTOR TO BE RESPONSIBLE FOR THE REPAIR OF ANY DAMAGED CURB

OR DRIVEWAYS DURING CONSTRUCTION.

B. REMOVAL & DISPOSAL OF DEMOLISHED MATERIALS:

1. ALL DEMOLISHED OR REMOVED ITEMS AND MATERIALS SHALL BE CONSIDERED

SCRAP EXCEPT FOR THOSE INDICATED TO REMAIN, THOSE INDICATED TO BE

REINSTALLED, THOSE INDICATED TO BE SALVAGED, AND HISTORICAL ITEMS.

2. CONSTRUCTION OR ITEMS INDICATED TO REMAIN SHALL BE PROTECTED

AGAINST DAMAGE DURING DEMOLITION OPERATIONS.

3. PROMPTLY DISPOSE OF MATERIALS RESULTING FROM DEMOLITION

OPERATIONS. DO NOT ALLOW MATERIALS TO ACCUMULATE ON SITE.

4. TRANSPORT MATERIALS RESULTING FROM DEMOLITION OPERATIONS AND

LEGALLY DISPOSE OF OFF-SITE.

5. OFF-SITE DISPOSAL LOCATION SHALL NOT BE WITHIN ONE-HALF MILE OF ANY

PORTION OF THE PROJECT SITE OR WITHIN SIGHT OF THE PROJECT SITE.

6. DO NOT BURN REMOVED MATERIALS ON PROJECT SITE.

7. REMOVE EXISTING VEGETATION AS REQUIRED.

C. POLLUTION CONTROLS:

1. CONTROL THE SPREAD OF DUST AND DIRT WITH PRACTICAL MEANS.

2. OBSERVE ENVIRONMENTAL PROTECTION REGULATIONS.

3. DO NOT ALLOW WATER USAGE THAT RESULTS IN FREEZING OR FLOODING.

4. DO NOT ALLOW ADJACENT IMPROVEMENTS TO REMAIN TO BECOME SOILED BY

DEMOLITION OPERATIONS.

D. CLEANING:

1. REMOVE TOOLS AND EQUIPMENT. DISPOSE OF SCRAP.

2. LEAVE EXTERIOR AREAS FREE OF DEBRIS.

3. CLEAN SOIL, SMUDGES, AND DUST FROM SURFACES TO REMAIN.

4. RETURN STRUCTURES AND SURFACES TO REMAIN TO CONDITION EXISTING

PRIOR TO COMMENCEMENT OF DEMOLITION.

DEMOLITION NOTES

SOIL SERIES

W

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

WALL

W

ALL

CONCRETE SWALE

36" CMP

GRAVEL

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

R

EV

ER

E

D R

IV

E

' R

/W

16" DIP

4" DIP

4" DIP

X X

XXX

X X

X X

X X

X

X X X X

X

16" DIP

4" DIP

TAP INTO EXISTING

WATER MAIN

6' CHAIN LINK FENCE

FENCE GATE

FENCE GATE

4" GATE VALVE

4" X 16" MJ REDUCER (TYP.)

SEE DETAIL PAGE 10

2" DIP DRAIN TO DAYLIGHT

(BOTTOM OF 16" PIPE)

2" DIP BLOWOFF

TO DAYLIGHT

THRUST BLOCK (TYP.)

SEE DETAIL PAGE 12

2" GATE VALVE

2" GATE VALVE

WELL SHED (SEE DETAIL SHEET 13)

4" DIP BLOW OFF

6" PVC DRAIN

4" D

IP

RINDT-M

CDUFF ASSO

CIATES

N

Pr oj ec t N o:

Sheet No.

C he ck ed

D es ig n:

D ra w n:

Sc al e:

R

-1

/8

/2

D at e:

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(re ve re s ite

)\D ra w in gs \R

-1

D es ig n.

dw g

5/

/2

:3 9p m e le br on

N o.

R ev is io ns D at e

R

-1

D es ig n.

dw g

In iti al

PR

O

D U

C

TI

O N

W

EL

LS

A

N D

T R

EA

TM

EN

T

BU

IL

D

IN

G S

C

IT

Y O

F W

O O

D

ST

O C

K ww w.

RI

ND

T.

co m

4 C he ro ke e S tre et

- M ar iet ta, G a.

Ph on e:

(7

) 4

-8

AA

B

AA

B BA

R

1" =1

0'

SI

TE

P

LA

N

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

1. CONTRACTOR TO MAINTAIN AT LEAST ONE LANE OF TRAFFIC AT ALL TIMES.

CONTRACTOR TO REOPEN ALL LANES AFTER WORK HOURS, PLATED OR OTHERWISE. IF

ALL LANES CANNOT BE REOPENED, CONTRACTOR SHALL PLACE VARIABLE MESSAGE

SIGNS ON BOTH SIDES OF LANE CLOSURE AND ALERT DCDOT.

2. ALL CONCRETE FORMWORK AND REINFORCING BARS TO BE INSPECTED BY THE FIELD

REPRESENTATIVE IN CONJUNCTION WITH THE CONTRACTOR'S REPRESENTATIVE BEFORE

CONCRETE IS POURED.

3. CONTRACTOR TO ESTABLISH TEMPORARY SUPPORT FOR EXISTING UTILITIES AND

MAINTAIN IT THROUGHOUT CONSTRUCTION.

4. CONTRACTOR TO MAINTAIN UTILITY SERVICES DURING CONSTRUCTION, WITH MINIMAL

INTERRUPTION.

5. CONTRACTOR TO BE RESPONSIBLE FOR THE PROTECTION AND NECESSARY REPAIR OF

ANY DAMAGED CURB OR DRIVEWAYS DURING CONSTRUCTION.

6. CONTRACTOR TO COORDINATE WITH CONFLICTING UTILITIES AND PAY FOR ANY

RELOCATION EXPENSES AS PART OF THIS CONTRACT.

7. CONTRACTOR TO USE A PROFESSIONAL SURVEYOR TO STAKE OUT PROJECT.

8. ALL BURIED PIPES TO BE INSPECTED BY THE ENGINEER PRIOR TO COVER.

9. ALL CONCRETE SHALL BE CLASS C, 3,000 PSI AT 28 DAYS COMPRESSIVE STRENGTH

WITH A MAXIMUM SLUMP OF 4" UNLESS NOTED OTHERWISE. ALL EXPOSED CONCRETE TO

HAVE A FINE BROOM FINISH.

10. ALL MATERIALS SHALL BE NEW UNLESS USED/SALVAGED MATERIALS ARE AUTHORIZED

BY THE OWNER.

11. NECESSARY BARRICADES, SUFFICIENT LIGHTS, SIGNS AND OTHER TRAFFIC CONTROL

METHODS AS MAY BE NECESSARY FOR THE PROTECTION AND SAFETY OF THE PUBLIC,

SHALL BE PROVIDED AND MAINTAINED THROUGHOUT THE CONSTRUCTION PROCESS.

SITE NOTES

SITE PIPING NOTES

WELL HOUSE

15' X 20'

GRAPHIC SCALE

( IN FEET )

1 inch = ft.10

10 5 10 20 40

W

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

O H

E

WALL

W

ALL

CONCRETE SWALE

36" CMP

GRAVEL

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

W W

878870

R

EV

ER

E

D R

IV

E

' R

/W

16" DIP

4" DIP

4" DIP

X X

XXX

X

X X

X X

X

X

X X X X

X

16" DIP

4" DIP

LIMITS OF DISTURBANCE

LIMITS OF DISTURBANCE

4" D

IP

RINDT-M

CDUFF ASSO

CIATES

N

Pr oj ec t N o:

Sheet No.

C he ck ed

D es ig n:

D ra w n:

Sc al e:

R

-1

/8

/2

D at e:

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(re ve re s ite

)\D ra w in gs \R

-1

D es ig n.

dw g

5/

/2

:3 9p m e le br on

N o.

R ev is io ns D at e

R

-1

D es ig n.

dw g

In iti al

PR

O

D U

C

TI

O N

W

EL

LS

A

N D

T R

EA

TM

EN

T

BU

IL

D

IN

G S

C

IT

Y O

F W

O O

D

ST

O C

K ww w.

RI

ND

T.

co m

4 C he ro ke e S tre et

- M ar iet ta, G a.

Ph on e:

(7

) 4

-8

AA

B

AA

B BA

R

1" =1

0' G

R

AD

IN

G

P

LA

N

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

GENERAL GRADING NOTES

WELL HOUSE

15' X 20'

GRAPHIC SCALE

( IN FEET )

1 inch = ft.10

STATIC WATER LEVEL = 6.7'

BELOW TOP OF CASING

DRAW DOWN WATER LEVEL = 78'

BELOW TOP OF CASING

WELL WSK-D1

TOP OF CASING ELEVATION = 878.0

EXISTING GRADE ELEVATION = 876.0

12" DIA. BOREHOLE

82' DEPTH

82' OF 8" STEEL CASING

SUBMERSIBLE TURBINE PUMP

PUMP TOP AT ELEV. 780

SUBMERSIBLE LEVEL TRANSMITTER AT ELEV. 785

BOTTOM OF WELL ELEVATION = 376.0

8" BORE HOLE FROM 82 TO 300 FT

AVERAGE MAXIMUM WATER

SYSTEM PRESSURE = 1242

AVERAGE MINIMUM WATER

SYSTEM PRESSURE = 1229

6" BORE HOLE FROM 300 - 500 FT

Pr oj ec t N o:

Sheet No.

C he ck ed

D es ig n:

D ra w n:

Sc al e:

R

-1

/8

/2

D at e:

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(re ve re s ite

)\D ra w in gs \R

-1

D es ig n.

dw g

5/

/2

:3 9p m e le br on

N o.

R ev is io ns D at e

R

-1

D es ig n.

dw g

In iti al

PR

O

D U

C

TI

O N

W

EL

LS

A

N D

T R

EA

TM

EN

T

BU

IL

D

IN

G S

C

IT

Y O

F W

O O

D

ST

O C

K ww w.

RI

ND

T.

co m

4 C he ro ke e S tre et

- M ar iet ta, G a.

Ph on e:

(7

) 4

-8

AA

B

AA

B BA

R

AS

S

H O

W N

H

YD

R

AU

LI

C

G R

AD

E

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

VERTICAL SCALE: 1" = 30'

HORIZONTAL SCALE: N.T.S.

PROVIDED BY EMERY & GARRET GROUNDWATER INVESTIGATIONS

UTILITY HEATER

12" SQ. WALL FAN

12" ABOVE F.F.

SHELVES

CHEMICAL PUMP

12"x12"

DRAIN

INLET

CHLORINE

ANALYZER LEVEL

MONITOR

ELEC. PANELS

FLOURIDE CAUSTIC

10' WIDE ROLL

UP DOOR

G

2" DIP

SHELVES

M CVG D

6" HDPE PIPE DRAIN TO

DAYLIGHT W/ SCREEN 6" DIP BLOW OFF TO

DAYLIGHT W/ SCREEN

4" DIP PIPE

TO CITY

PRESSURE

GAUGE

GATE

VALVE TURBINE

METER

SILENT

CHECK

VALVE

DIAPHRAGM

VALVE

GATE

VALVE

CHLORINECHLORINE

4' X 4' CONCRETE

LANDING

FROM WELL

SAMPLE

TAP

4" DIP 4" DIP

TAP

Pr oj ec t N o:

Sheet No.

C he ck ed

D es ig n:

D ra w n:

Sc al e:

R

-1

/8

/2

D at e:

M :\P ro je ct s\

\r2

7-ci ty o f w oo ds to ck ge ne ra l s er vi ce s\ w el l n o.

(re ve re s ite

)\D ra w in gs \R

-1

D es ig n.

dw g

5/

/2

:3 9p m e le br on

N o.

R ev is io ns D at e

R

-1

D es ig n.

dw g

In iti al

PR

O

D U

C

TI

O N

W

EL

LS

A

N D

T R

EA

TM

EN

T

BU

IL

D

IN

G S

C

IT

Y O

F W

O O

D

ST

O C

K ww w.

RI

ND

T.

co m

4 C he ro ke e S tre et

- M ar iet ta, G a.

Ph on e:

(7

) 4

-8

AA

B

AA

B BA

R

3/ 4"

=1

M

EC

H

AN

IC

AL

P

LA

N

UTILITIES MAY EXIST WHICH ARE NOT SHOWN ON THE PLANS AND THE EXISTING UTILITY LINES THAT ARE SHOWN ARE APPROXIMATE LOCATIONS ONLY. CONTRACTOR SHALL FIELD VERIFY ALL EXISTING

UTILITY LINE LOCATIONS PRIOR TO ANY CONSTRUCTION. THE CONTRACTOR SHALL ALSO BE

RESPONSIBLE FOR COORDINATING WITH ALL UTILITY COMPANIES HAVING UTILITIES WITHIN OR

ADJACENT TO THE WORK AREA. THE CONTRACTOR SHALL COORDINATE CLOSELY WITH THESE

UTILITY COMPANIES AS NECESSARY REGARDING MODIFICATIONS TO EXISTING SYSTEMS OR

ADAPTATIONS FOR NEW SERVICE CONNECTIONS. ANY DEVIATIONS FROM THE NEW UTILITY DESIGN LOCATIONS SHOWN IN THESE PLANS SHALL BE REPORTED TO THE PROJECT ENGINEER PRIOR TO CONSTRUCTION. ANY AND ALL DAMAGE TO EXISTING UTILITY LINES RESULTING FROM CONTRACTOR

NEGLIGENCE SHALL BE REPAIRED SOLELY AT CONTRACTOR EXPENSE.

UTILITY DISCLAIMER

NOTES:

1. STATIC PRESSURE @ WELL HOUSE PIPE (AT F.F.E.): 148-156 PSI

2. THE…