Public_Construction_Bond_(25).doc
DOC document 29 KB Posted
- Attached to
- Kellogg Park Nature Center State and local contract opportunity
- Solicitation number
- 25-07
- Issued by
- Bay County, Florida
About this file
This is a Public Construction Bond document issued by the Board of County Commissioners of Walton County, Florida, establishing bonding requirements for a construction contract. The bond secures the principal contractor's performance obligations and payment responsibilities for a construction project dated 2025. The document requires the principal to perform all work according to contract specifications within prescribed timelines, make prompt payments to all laborers and material suppliers, and guarantee all work and materials for the duration specified in the contract. A mandatory pre-bid meeting is scheduled for Tuesday, October 15, 2024, at 10:00 am, with bid submissions due by Thursday, November 14, 2024, at 2:00 pm. The contract term extends for 45 calendar days from the purchase order date, with liquidated damages assessed at $100 per day for late completion.
The bond amount and specific project details are to be completed at execution. All claims against the bond must comply with notice and time limitations established under Section 255.05(2) of the Florida Statutes. The surety's obligation remains valid regardless of any modifications to contract documents or changes in contract compliance procedures. Venue for any litigation arising from the bond is established in Walton County, Florida. The project is funded through the American Rescue Plan Act Local Assistance and Tribal Consistency Fund. Bidders must submit a 5% bid bond along with required certifications including Anti-Collusion Clause, Conflict of Interest Disclosure, and Drug Free Workplace certification. Contractors must hold Florida licensure as Building or General Contractors and comply with E-Verify requirements. The County reserves the right to reject any or all bids and will award the contract to the lowest responsive, responsible bidder.
View the file
Other files for this state and local contract opportunity
Show all 46
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SEQ CHAPTER \h \r 1PUBLIC CONSTRUCTION BOND
BOARD OF COUNTY COMMISSIONERS,
WALTON COUNTY, FLORIDA
BY THIS BOND, We _________________________________________________, as Principal and ___________________________________________, a corporation, as Surety, whose address is , , Florida , are bound to Walton County, Florida, a political subdivision of the State of Florida, hereinafter referred to as "COUNTY", in the sum of ______________________________ DOLLARS ($________________), for the payment of which, we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that the Principal:
1.
Performs the Contract dated ________________, 2025, between Principal and County for the construction of:
the Contract being made a part of this bond by reference, at the times and in the manner prescribed in the Contract, and
2.
Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials, or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract; and
3.
Pays County all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that County sustains because of a default by Principal under the Contract; and
4.
Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise, it remains in full force.
Any claims made against this bond shall be made in accordance with the notice and time limitations specified in Section 255.05(2), Florida Statutes.
Any changes in or under the Contract Documents and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect surety's obligation under this bond.
Venue for any litigation resulting from this bond shall be Walton County, Florida.
Signed and sealed this ____ day of __________________, 2025.
ATTEST: PRINCIPAL
By:__________________________
By: ____________________ (SEAL)
[PRINT NAME & TITLE]
ATTEST: SURETY
By:__________________________
By: _________________________
[PRINT NAME & TITLE]
Page of 2
File details come from the government source that posted it. Updated .