Public_Construction_Bond_(25).doc
DOC document 29 KB Posted
- Attached to
- Kellogg Park Nature Center State and local contract opportunity
- Solicitation number
- 25-07
- Issued by
- Bay County, Florida
About this file
The document is a Public Construction Bond for the Walton County Board of County Commissioners in Florida, serving as a legal instrument to guarantee contractual performance. While the bond itself does not specify a specific project, it outlines standard bonding requirements for a construction contract, including performance guarantees, payment protections for claimants supplying labor and materials, and provisions for potential losses or damages. The bond is designed to ensure the principal contractor fulfills contractual obligations, with a venue for any potential litigation set in Walton County, Florida.
The related state and local contract opportunity involves the Bay County Board of County Commissioners seeking qualified vendors to demolish and reconstruct an ADA-compliant beach access point (Beach Access #16) in accordance with VBA Design drawings. The project is funded through the American Rescue Plan Act's Local Assistance and Tribal Consistency Fund, with a contract term of 45 calendar days and liquidated damages of $100 per day for late completion. Bidders must be Florida-licensed Building or General Contractors, submit comprehensive documentation including an Anti-Collusion Clause and 5% bid bond, and comply with E-Verify requirements. The contract will be awarded to the lowest responsive, responsible bidder, with the County reserving the right to reject any or all submissions.
View the file
Other files for this state and local contract opportunity
Show all 46
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SEQ CHAPTER \h \r 1PUBLIC CONSTRUCTION BOND
BOARD OF COUNTY COMMISSIONERS,
WALTON COUNTY, FLORIDA
BY THIS BOND, We _________________________________________________, as Principal and ___________________________________________, a corporation, as Surety, whose address is , , Florida , are bound to Walton County, Florida, a political subdivision of the State of Florida, hereinafter referred to as "COUNTY", in the sum of ______________________________ DOLLARS ($________________), for the payment of which, we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that the Principal:
1.
Performs the Contract dated ________________, 2025, between Principal and County for the construction of:
the Contract being made a part of this bond by reference, at the times and in the manner prescribed in the Contract, and
2.
Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials, or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract; and
3.
Pays County all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that County sustains because of a default by Principal under the Contract; and
4.
Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise, it remains in full force.
Any claims made against this bond shall be made in accordance with the notice and time limitations specified in Section 255.05(2), Florida Statutes.
Any changes in or under the Contract Documents and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect surety's obligation under this bond.
Venue for any litigation resulting from this bond shall be Walton County, Florida.
Signed and sealed this ____ day of __________________, 2025.
ATTEST: PRINCIPAL
By:__________________________
By: ____________________ (SEAL)
[PRINT NAME & TITLE]
ATTEST: SURETY
By:__________________________
By: _________________________
[PRINT NAME & TITLE]
Page of 2
File details come from the government source that posted it. Updated .