Public_Construction_Bond_(25).doc
DOC document 29 KB Posted
- Attached to
- Beach Amusements and Activities
- Solicitation number
- 25-26
- Issued by
- Walton County, Florida
About this file
This is a Public Construction Bond document issued by the Board of County Commissioners for Walton County, Florida, in connection with the SR 83 (US 331) Landscaping Improvements project. The bond secures the principal contractor's performance of a construction contract for landscaping improvements along the scenic corridor median from SR 30 (US 98) to north of Chat Holley Road. The project encompasses comprehensive landscaping work involving sod replacement and irrigation installation across approximately 256,500 square feet of area. A mandatory pre-bid conference is scheduled for October 27, 2025, at 10:00 am, with bid submissions due on November 17, 2025, at 3:00 pm. The contract duration is 60 days for substantial completion with an additional 30 days for punch list completion. The project is a joint collaboration between Walton County and the Florida Department of Transportation (FDOT), with an estimated total project cost of approximately $670,000.
The bond requires the principal contractor to maintain performance and payment bonds, comply with all contract terms, promptly pay all claimants supplying labor, materials, or supplies, and guarantee all work and materials for the specified contract period. The bond amount and specific surety corporation details are to be completed upon contract execution. The contract structure includes six line items: mobilization, maintenance of traffic, removal of existing sod and site preparation, Zoysia sod installation, irrigation system components and installation, and a 10% owner's contingency. Payment will be structured in two progress payments upon substantial completion of Phase 1 and Phase 2, with liquidated damages of $1,685 per calendar day assessed for project delays. Contractors must maintain a full-time on-site superintendent, provide all necessary licenses and permits, maintain required insurance coverage, and comply with federal, state, and local regulations, including Florida-friendly landscaping principles and specific technical requirements such as Rain Bird pressure compensating emitters and PVC piping.
View the file
Other files
Show all 40
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SEQ CHAPTER \h \r 1PUBLIC CONSTRUCTION BOND
BOARD OF COUNTY COMMISSIONERS,
WALTON COUNTY, FLORIDA
BY THIS BOND, We _________________________________________________, as Principal and ___________________________________________, a corporation, as Surety, whose address is , , Florida , are bound to Walton County, Florida, a political subdivision of the State of Florida, hereinafter referred to as "COUNTY", in the sum of ______________________________ DOLLARS ($________________), for the payment of which, we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that the Principal:
1.
Performs the Contract dated ________________, 2025, between Principal and County for the construction of:
the Contract being made a part of this bond by reference, at the times and in the manner prescribed in the Contract, and
2.
Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials, or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract; and
3.
Pays County all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that County sustains because of a default by Principal under the Contract; and
4.
Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise, it remains in full force.
Any claims made against this bond shall be made in accordance with the notice and time limitations specified in Section 255.05(2), Florida Statutes.
Any changes in or under the Contract Documents and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect surety's obligation under this bond.
Venue for any litigation resulting from this bond shall be Walton County, Florida.
Signed and sealed this ____ day of __________________, 2025.
ATTEST: PRINCIPAL
By:__________________________
By: ____________________ (SEAL)
[PRINT NAME & TITLE]
ATTEST: SURETY
By:__________________________
By: _________________________
[PRINT NAME & TITLE]
Page of 2
File details come from the government source that posted it. Updated .