Price Schedule_CSM Supporting Guam.pdf

PART I PRICE SCHEDULE

SECTION 00010 - SUPPLIES OR SERVICES AND PRICES

PRICE SCHEDULE

Item Estimated Unit No. Description Quantity Unit Price Amount

Base

All cost in connection with the Supplies and Services Contract. The base bid includes the labor cost, other direct cost and program support for the duration of 01 Oct 2025 to 31 Aug 2026.

JOB

OPTION

All cost of labor, other direct cost and program support for the duration of 01 Sep 2026 to 28 Feb 2027.

program support for the duration of 01 Mar 2027 to 29 Feb 2028.

program support for the duration of 01 Mar 2028 to 30 Sep 2028.

All cost of labor, other direct cost and program support for the duration of 01 Oct 2028 to 30 Jun 2029. SSM Post Construction

All costs in connection with the Facilities and Equipment including work covered under Base Bid Items 0001, 0002, 0003, 0004, and 0005.

TOTAL ESTIMATED PROJECT AMOUNT $_____________

NOTES TO OFFERORS

Offerors must quote on all items. Failure to quote on all items may be cause for rejection of the proposal.

Optional Items may be exercised at any time within 1,155 calendar days after the date of receipt of Notice to Proceed. The Contracting Officer may exercise the Optional Items by written notice to the Contractor, postmarked within the period specified above. The Government may exercise any, all or none of the listed Optional Items in any order.

Evaluation of Options:

Except when it is determined not to be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

VARIATION IN ESTIMATED QUANTITIES: If the quantity of a unit-price item in this contract is an estimated quantity and the actual quantity of the unit-price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.