Pigeon_Abatement_Services.pdf

CITY OF TUCSON

REQUEST FOR QUOTE

240266

PIGEON ABATEMENT SERVICES

Due Date: Tuesday, December 3, 2024

City of Tucson

255 W Alameda St

Tucson, AZ 85701

Procurement portal https://secure.procurenow.com/portal/tucson-az

Public Portal https://secure.procurenow.com/portal/tucson-az/projects/129593

PUBLISH DATE: November 15, 2024 https://secure.procurenow.com/portal/%7Bproject.government.code%7D https://secure.procurenow.com/portal/%7Bproject.government.code%7D/projects/%7Bproject.id%7D https://secure.procurenow.com/portal/%7Bproject.government.code%7D/projects/%7Bproject.id%7D

CITY OF TUCSON REQUEST FOR QUOTE NO. 240266

BUSINESS SERVICES DEPARTMENT Page 2 of 27 SHARED SERVICES PROCUREMENT DIVISION RESPONSIBLE CONTRACT OFFICER: Maria Hartke

255 W. ALAMEDA, 6TH FLOOR, TUCSON, AZ 85701 PH: (520) 837-3826

Attachments:

A - OFFER_AND_ACCEPTANCE

B - HUD-Form-5370-C, Section II C - 240226, Solicitation Price Page

BUSINESS SERVICES DEPARTMENT Page 3 of 27

A. Notice of Request for Quotation

I. INTRODUCTION:

The City of Tucson, Business Services Department, Shared Services – Procurement Division (“Procurement Division”) is requesting quotes from qualified firm(s) for the purpose of establishing a Service Agreement for Pigeon Abatement Services, as per the Scope of Work.

II. AWARD OF SERVICE AGREEMENT(Contract):

A. Unless otherwise provided within this Request for Quotation, the City reserves the right to award by individual line item, by group of line items, or as a total, whichever is deemed most advantageous to the City.

B. Notwithstanding any other provision of the Service Agreement, the City reserves the right to:

1. waive any immaterial defect or informality; or

2. reject any or all quotes, or portions thereof; or

3. reissue a Request for Quote.

C. A response to the Request for Quotation is an offer to contract with the City based upon the terms, conditions, and Specifications contained in the City’s Request for Quote. Quotes do not become Contracts unless and until they are executed by the City’s Director of Business Services or authorized representative. The Service Agreement has its inception in the award, eliminating a formal signing of a separate Contract. All of the terms and conditions of the Service Agreement are contained in this Request for Quotation document, unless any of the terms and conditions are modified by an Amendment.

BUSINESS SERVICES DEPARTMENT Page 4 of 27

B. Introduction

B.1. Summary

The City of Tucson is seeking for a qualified firm or personal to provide Pigeon Abatement Services to all city locations on an as-needed basis. Pigeon Abatement services shall be used to properly, but humanely, control the nuisance populations of pigeons. This includes the installation, maintenance, and repair of physical deterrent systems to dissuade the pigeons from congregating and nesting on City buildings. The Contractor will also assist City staff in cleaning pigeon droppings from areas requiring such physical deterrents. Facilities Management intends to award to to one (1) vendor with an estimated total spend of $50K.

B.2. Contact Information

Maria Hartke Contract Officer 255 W Alameda St Tucson, AZ 85701 Email: maria.hartke@tucsonaz.gov Phone: (520) 837-3826 Department:

EGSD

B.3. Timeline mailto:maria.hartke@tucsonaz.gov tel:(520)837-3826

BUSINESS SERVICES DEPARTMENT Page 5 of 27

Release Project Date November 15, 2024

Question Submission Deadline November 26, 2024, 2:00pm

Proposal Submission Deadline December 3, 2024, 2:00pm

BUSINESS SERVICES DEPARTMENT Page 6 of 27

C. Scope of Services

C.1. Scope of Work

Scope of Work

A. The Contractor must be responsible to provide, whether scheduled and on an as-needed basis per the City representative request, to include prevention, elimination, monitoring, maintenance, repair, and installation of all abatement control services.

B. Treatment may be needed across varies City locations where abatement is deemed necessary. Vendor must be prepared and fully equipment to help manage areas requested;

Including but not limited to roofing, entryways, awnings, ledges, overhangs, gutters, and installed solar panels.

1. The City will not supply any equipment necessary to ensure job completion and is the responsibility of the vendor; I.e scissor or boom lifts.

Services

A. At the request of City representative(s), the Vendor shall respond within 48 hours of a work request and provide a complete and thorough inspection of the requested site visit.

B. Vendor will submit a detailed written report on areas inspected, evidence found, and recommended treatment and ratification to treat infestation.

a. The vendor will be required to provide communication of when the project will begin and time frame of completion. Vendor will be clear on any issues with product inventory or servicing staff that may delay or prohibit the treatment from being completed.

b. The Contractor shall ensure a designated site for the installation of a specified pigeon deterrent system.

C. The City will require a physical copy of the report/ (via email) before work is commenced and shall provide:

a. The date and time work will begin.

b. Description of the repair performed, and specific action taken.

i. Any drawings or charts deemed necessary.

c. Date and time work will be completed.

d. Work Order Number.

D. With the approval of the City to proceed forward with treatment, the Vendor shall clean the site thoroughly from all pigeon droppings.

1. The vendor is responsible for properly disposing of droppings, as part of site preparation for new installations.

E. City Representative will inspect with the Vendor on all newly completed work and repair.

Ensuring clear communication on arrival times, designated work time, and completion work.

BUSINESS SERVICES DEPARTMENT Page 7 of 27

1. If the vendor leaves the site before approved completed work, Vendor will be required to turn for all necessary changes/modifications for completion upon request of City representative.

2. The City requests that all work is documented by the Vendor at the time of completion for approval, if City representative not on-site.

F. For all current abatement systems, the vendor in similar nature, be expected to a clean, repair, or maintain any treatment deemed necessary at site locations across the city.

Materials

A. The possible systems include, but are not limited to:

1. Netting, spikes, wire, glue and other methods as agreed upon by the City Representative and the Contractor

2. Cabling and hog rings for solar panels

Warranty

A. The Contractor shall ensure that all replacement/repair parts and labor shall be guaranteed for a minimum of ninety (90) days, if additional warranty time is offered by the manufacturer, that greater warranty time frame shall prevail and be extended to the City of Tucson.

Invoicing

A. Invoices for the City shall be delivered with the original work order report, at the time of completion or delivery within one (1) business day to the email of the City Representative and to the City's payables team.

B. The City will not provide payment via a pcard and will be distributed through the vendor profile, via Workday, upon contract award.

1. A copy of the invoice submitted shall be emailed to EGSD-Payables@tucsonaz.gov mailto:EGSD-Payables@tucsonaz.gov

BUSINESS SERVICES DEPARTMENT Page 8 of 27

D. Vendor Questionnaire

D.1. Delivery Timeline* Delivery is promised within how many calendar days after receipt of an order.

*Response required

D.2. Sales Tax Percent* What percentage is the tax rate that applies to this project for you?

*Response required

D.3. Prompt Payment Discount Terms* Please explain your terms below.

The price(s) herein can be discounted by _______%, if payment is made within ______ days. These payment terms shall apply to all purchases and to all payment methods.

*Response required

D.4. Tucson Business License* Does your firm have a City of Tucson Business License? If yes, please provide a copy of your City of Tucson Business license.

☐ Yes

☐ No

*Response required

D.5. Credit Cards

Credit Card Accepted* Will payment be accepted via commercial credit card?

☐ Yes

☐ No

*Response required

Online Payment Accepted If yes, can commercial payment(s) be made online?

☐ Yes

☐ No

Third Party Will a third party be processing the commercial credit card payment(s)?

☐ Yes

BUSINESS SERVICES DEPARTMENT Page 9 of 27

☐ No

Transaction fees If yes, indicate the percentage per transaction ___________ (as allowable, per Section 5.12.2 of the MasterCard Transaction Processing Rules).

Credit Card Acceptance Consideration If “no” to above, will consideration be given to accept the card? ____Yes ____No

☐ Yes

☐ No

D.6. Forms to be completed

Technical Proposal Please upload your Vendor Response to Evaluation Criteria (if applicable).

Pricing Proposal Please upload your Pricing Proposal (if applicable).

Offer and Acceptance Form* Please upload the signed Offer and Acceptance Form.

*Response required

BUSINESS SERVICES DEPARTMENT Page 10 of 27

E. Special Terms and Conditions

E.1. Term and Renewal

The term of the Contract shall commence upon award and shall remain in effect for a period of one (1) year, unless terminated, canceled or extended as otherwise provided herein. The Contractor agrees that the City of Tucson shall have the right, at its sole option, to renew the Contract for four (4) additional one year periods or portions thereof. In the event that the City exercises such rights, all terms, conditions and provisions of the original Contract shall remain the same and apply during the renewal period with the possible exception of price and minor scope additions and/or deletions.

E.2. Price Adjustment

The City will review fully documented requests for price adjustment only at the time of Contract renewal and/or extension and will be a factor in the extension review process. The City will determine whether the requested price adjustment or an alternate option, is in the best interest of the City. Any price adjustment will be effective upon the effective date of the Contract extension.

BUSINESS SERVICES DEPARTMENT Page 11 of 27

F. Insurance

F.1. The Contractor agrees to

A. Obtain insurance coverage of the types and amount required in this section and keep such insurance coverage in force throughout the life of this contract. All policies will contain an endorsement providing that written notice be given to the City at least thirty (30) calendar days prior to termination, cancellation, or reduction in coverage in any policy.

B. The Commercial General Liability, Commercial Automobile Liability and umbrella policies where applicable will include the City as an additional insured with respect to liability arising out of the performance of this contract. Such additional insured shall be covered to the full limits of liability purchased by the Contractor, even if those limits of liability are in excess of those required by this Contract. The Contractor agrees that the insurance hereunder will be primary and that any insurance carried by the City will be excess and not contributing.

C. Provide and maintain minimum insurance limits as applicable.

F.2. Commercial General Liability

Policy shall include Bodily Injury, Property Damage, Personal Injury and Broad Form Contractual Liability:

Each Occurrence: $1,000,000

General Aggregate: $2,000,000

Products & Completed Operations Aggregate: $2,000,000

Personal and Advertising Injury: $1,000,000

Blanket Contractual Liability: $1,000,000

F.3. Commercial Automobile Liability

Policy shall include Bodily Injury and Property Damage, for any owned, Hired, and/or Non-owned vehicles used in the operation, installation and maintenance of facilities under this agreement.

Combined Single Limit: $1,000,000

F.4. Worker's Compensation (Applicable to the State of Arizona)

Per Occurrence: Statutory

Employer's Liability: $1,000,000

Disease Each Employee: $1,000,000

Disease Policy Limit: $1,000,000

*Sole Proprietor/Independent Contractor designation is given to those who desire to waive their rights for workers’ compensation coverage and benefits as outlined in ARS§ 23-901 and specifically ARS §

BUSINESS SERVICES DEPARTMENT Page 12 of 27

23-961 (O). If applicable, please request the Sole Proprietor/Independent Contractor form from the Contract Officer listed in the solicitation.

F.5. Claims Made Insurance Coverage

If any or part of the required insurance is written on a claims-made basis, any policy retroactive date must precede the date of the contract and the Contractor must maintain such coverage for a period not less than three (3) years following contract expiration, termination or cancellation.

F.6. Additional Insurance Requirements

All Policies, excluding Employment Practices Liability and Professional Liability (Errors & Omissions), shall include or be endorsed to include the following provisions:

A. A waiver of subrogation endorsement in favor of the City of Tucson, for losses arising from work performed by or on behalf of the Contractor (Including Worker’s Compensation).

B. The insurance afforded the contractor shall be primary insurance and that any insurance carried by the City of Tucson and its agents, officials or employees shall be excess and not contributory.

C. Coverage provided by the Contractor shall not be limited to the liability assumed under the indemnification provisions of this Contract.

F.7. Notice of Coverage Modifications

Any changes material to compliance with this contract in the insurance policies above shall require (10) days written notice from the contractor to the City of Tucson. Such notice shall be sent directly to the Procurement Division.

F.8. Acceptability of Insurers

Contractors insurance shall have an “A.M. Best” rating of not less than A-VII. The City of Tucson in no way warrants that the required minimum insurer rating is sufficient to protect the Contractor from potential insurer insolvency.

F.9. Verification of Coverage

Contractor shall furnish the City of Tucson with certificates of insurance (ACORD form or equivalent approved by the City of Tucson) as required by this Contract. The certificates for each insurance policy are to be signed by an authorized representative.

All certificates and endorsements are to be received and approved by the City of Tucson before work commences. Each insurance policy required by this Contract must be in effect at or prior to commencement of work and remain in effect for the duration of the contract and two (2) years after completion. Failure to maintain the insurance policies as required by this Contract, or to provide evidence of renewal upon the City’s request, is a material breach of contract.

All certificates required by this Contract shall be sent directly to the Procurement Division.

BUSINESS SERVICES DEPARTMENT Page 13 of 27

The City of Tucson project/contract number and project description shall be noted on the certificate of insurance. The City of Tucson reserves the right to require complete copies of all insurance policies required by this Contract at any time.

F.10. Subcontractors

Contractors’ certificate(s) shall include all subcontractors as insureds under its policies or Contractor shall furnish to the City of Tucson separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to the minimum requirements identified above.

F.11. Exceptions

In the event the Contractor or sub-contractor(s) is/are a public entity, then the Insurance Requirements shall not apply. Such public entity shall provide a Certificate of Self- Insurance.

BUSINESS SERVICES DEPARTMENT Page 14 of 27

G. Standard Terms and Conditions

G.1. ADVERTISING

Contractor shall not advertise or publish information concerning this Contract without prior written consent of the City’s Director of Business Services.

G.2. AFFIRMATIVE ACTION

Contractor shall abide by the provisions of the Tucson Procurement Code Chapter 28, Article XII.

G.3. AMERICANS WITH DISABILITIES ACT

The Contractor shall comply with all applicable provisions of the Americans with Disabilities Act (Public Law 101-336, 42 U.S.C. 12101, et seq.) and applicable Federal regulations under the Act.

G.4. APPLICABLE LAW

This Contract shall be governed, and the City and Contractor shall have all remedies afforded to each, by the Tucson Procurement Code and the law of the State of Arizona. State law claims shall be brought only in Pima County Superior Court.

G.5. ASSIGNMENT DELEGATION

No right or interest in this Contract shall be assigned by the Contractor without prior written permission of the City, and no delegation of any duty of the Contractor shall be made without prior written permission of the City's Director of Business Services. The City shall not unreasonably withhold approval and shall notify the Contractor of the City's position by written notice.

G.6. CHILD/SWEAT-FREE LABOR POLICY

The Contractor shall comply with all applicable provisions of the United States Federal and State Child Labor and Worker's Right laws and agrees if called upon to affirm in writing, that they, and any subcontractor involved in the provision of goods to the City, are in compliance.

G.7. CLEAN-UP

The Contractor shall at all times keep the contract area, including storage areas used by the Contractor, free from accumulation of waste material or rubbish and, prior to completion of the work, remove any rubbish from the premises and all tools, scaffolding, equipment and materials not property of the City.

Upon completion of the repair, the Contractor shall leave the work and premises in clean, neat and workmanlike condition.

BUSINESS SERVICES DEPARTMENT Page 15 of 27

G.8. COMMENCEMENT OF WORK

The Contractor is cautioned not to commence any billable work or provide any material or service under this Contract until Contractor receives purchase order or is otherwise directed to do so, in writing, by the City.

G.9. CONFIDENTIALITY OF RECORDS

The Contractor shall establish and maintain procedures and controls that are acceptable to the City for the purpose of assuring that no information contained in its records or obtained from the City or from others in carrying out its functions under the Contract shall be used by or disclosed by it, its agents, officers, or employees, except as required to efficiently perform duties under the Contract. Persons requesting such information should be referred to the City. Information pertaining to individual persons shall not be divulged other than to employees or officers of Contractor as needed for the performance of duties under the Contract, unless otherwise agreed to in writing by the City.

G.10. CONTRACT ADDENDA

The Procurement Division has the sole authority to:

A. Amend the contract or enter into supplemental verbal or written agreements;

B. Grant time extensions or contract renewals; and

C. Otherwise modify the scope or terms and provisions of the contract.

This Contract shall only be modified with the approval of the Procurement Division. Except in the case of a documented emergency, approval must be granted prior to performance. Any contract modification not explicitly approved by the Procurement Division through a written contract addendum or change order is performed at the sole risk of the Contractor and may not be eligible for payment by the City.

G.11. CONTRACT

The Contract shall contain the entire agreement between the City of Tucson and the Contractor relating to this requirement and shall prevail over any and all previous agreements, contracts, proposals, negotiations, purchase orders, or master agreements in any form.

G.12. DEFAULT IN ONE INSTALLMENT TO CONSTITUTE TOTAL BREACH

Contractor shall deliver conforming materials in each installment or lot of this Contract and may not substitute nonconforming materials. Delivery of nonconforming materials, or default of any nature, may constitute breach of the Contract. Noncompliance may be deemed a cause for possible Contract termination.

G.13. DUPLEXED/RECYCLED PAPER

In accordance with efficient resource procurement and utilization policies adopted by the City of Tucson, the Contractor shall ensure that, whenever practicable, all printed materials produced by the Contractor

BUSINESS SERVICES DEPARTMENT Page 16 of 27 in the performance of this Contract are duplexed (two-sided copies), printed on recycled paper and labeled as such.

G.14. ENFORCEMENT, LAWS AND ORDINANCES

This agreement shall be enforced under the laws of the State of Arizona.

Each party must comply with all applicable federal, state, county, and City laws, ordinances, and regulations. Contractor shall ensure Contractor’s obligation regarding payment of all taxes, licenses, permits, and other expenses of any nature associated with the provision of services herein.

G.15. EQUAL PAY

The Contractor shall comply with the applicable provisions of the Equal Pay Act of 1963 (Pub.L. 88-38, 29 U.S.C. section 206(d)); Title VII of the Civil Rights Act of 1964 (Pub.L. 88-352, 42 U.S.C. 2000e et.seq.; and, the Lily Ledbetter Fair Pay Act of 2009 (Pub.L. 111-2).

G.16. EXCLUSIVE POSSESSION

All services, information, computer program elements, reports and other deliverables created under this Contract are the sole property of the City of Tucson and shall not be used or released by the Contractor or any other person except with prior written permission by the City.

G.17. FEDERAL IMMIGRATION LAWS AND REGULATIONS

Contractor warrants that it complies with all Federal Immigration laws and regulations that relate to its employees and complies with A.R.S. § 23-214(A) and that it requires the same compliance of all subcontractors under this Contract. Contractor acknowledges that pursuant to A.R.S. § 41-4401 and effective September 30, 2008, a breach of this warranty is a material breach of this Contract subject to penalties up to and including termination of this Contract. The City retains the legal right to audit the records of the Contractor and inspect the papers of any employee who works for the Contractor to ensure compliance with this warranty and the Contractor shall assist in any such audit. The Contractor shall include the requirements of this paragraph in each contract with subcontractors under this Contract.

Contractor warrants that it complies with all Federal Immigration laws and regulations that relate to its employees and complies with A.R.S. § 23-214(A) and that it requires the same compliance of all subcontractors under this Contract. Contractor acknowledges that pursuant to A.R.S. § 41-4401 and effective September 30, 2008, a breach of this warranty is a material breach of this Contract subject to penalties up to and including termination of this Contract. The City retains the legal right to audit the records of the Contractor and inspect the papers of any employee who works for the Contractor to ensure compliance with this warranty and the Contractor shall assist in any such audit. The Contractor shall include the requirements of this paragraph in each contract with subcontractors under this Contract.

BUSINESS SERVICES DEPARTMENT Page 17 of 27

G.18. FORCE MAJEURE

Except for payment of sums due, neither party shall be liable to the other nor deemed in default under this Contract if and to the extent that such party's performance of this Contract is prevented by reason of Force Majeure. The term "Force Majeure" means an occurrence that is beyond the control of the party affected and occurs without its fault or negligence. Force Majeure shall not include late performance by a subcontractor unless the delay arises out of a Force Majeure occurrence in accordance with this Force Majeure term and condition.

If either party is delayed at any time in the progress of the work by Force Majeure, the delayed party shall notify the other party in writing of such delay, as soon as is practical, of the commencement thereof and shall specify the causes of such delay in such notice. Such notice shall be hand-delivered or mailed certified-return receipt and shall make a specific reference to this article, thereby invoking its provisions.

The delayed party shall cause such delay to cease as soon as practicable and shall notify the other party in writing when it has done so. The time of completion shall be extended by contract modification for a period of time equal to the time that results or effects of such delay prevent the delayed party from performing in accordance with this Contract.

G.19. GRATUITIES

The City may, by written notice to the Contractor, terminate this Contract if it is found that gratuities, in the form of entertainment, gifts, meals or otherwise, were offered or given by the Contractor or any agent or representative of the Contractor, to any officer or employee of the City amending, or the making of any determinations with respect to the performing of such Contract. In the event this Contract is terminated by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold from the Contractor the amount of the gratuity.

G.20. HUMAN RELATIONS

Contractor shall abide by the provisions of the Tucson City Code Chapter 28, Article XII.

G.21. INDEMNIFICATION

To the fullest extent permitted by law, Contractor, its successors, assigns and guarantors, will indemnify, defend, and hold harmless the City and its officials, employees, volunteers, and agents, from and against all allegations, demands, proceedings, suits, actions, claims (including but not limited to claims of patent, trademark, or copyright infringement), liability, damages, losses, expenses (including but not limited to attorney fees and court costs, including the cost of appellate proceedings, and all claim-adjusting-and-handling expenses) or disbursements of any kind or nature, that may be asserted against, imposed on, or incurred by any of them, in any way relating to or arising from any actions, errors, mistakes or omissions of Contractor or any subcontractor or anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable relating to work, services and/or products provided under this Contract.

Contractor is responsible for primary loss investigation, defense and judgment costs where this indemnification is applicable. Contractor agrees to waive all rights of subrogation against the City, its agents, officials, employees, and volunteers for losses arising from the work performed by Contractor under this Contract.

BUSINESS SERVICES DEPARTMENT Page 18 of 27

G.22. INDEPENDENT CONTRACTOR

It is understood that each party shall act in its individual capacity and not as an agent, employee, partner, joint venturer, or associate of the other. An employee or agent of one party shall not be deemed or construed to be the employee or agent of the other party for any purpose.

The Contractor shall not be entitled to compensation in the form of salaries, holidays, paid vacation, sick days, or pension contributions by the City. The City of Tucson will not provide any insurance coverage to the Contractor, including Worker's Compensation coverage. The Contractor is advised that taxes, social security payments, and other withholdings shall not be withheld from a City payment issued under this Contract and that Contractor should make arrangements to directly pay such expenses. Contractor is responsible for compliance with the Affordable Care Act for Contractor and any of Contractor’s employees.

G.23. INSPECTION AND ACCEPTANCE

All material or service is subject to final inspection and acceptance by the City. Material or service failing to conform to the specifications of this Contract shall be held at the Contractor's risk and may be returned to the Contractor. If returned, all costs are the responsibility of the Contractor. Noncompliance may be deemed a cause for possible Contract termination.

G.24. INTERPRETATION PAROLE EVIDENCE

This Contract is intended by the parties to be a final expression of their agreement and is intended also as a complete and exclusive statement of the terms of this agreement. No course of prior dealings between the parties and no usage of the trade shall be relevant to supplement or explain any term used in the Contract. Acceptance or consent in the course of performance under this Contract shall not be relevant to determine the meaning of this Contract even though the accepting or consenting party has knowledge of the nature of the performance and the opportunity to object.

G.25. LICENSES

Contractor shall maintain in current status all Federal, State, and local licenses and permits required for the operation of the business conducted by the Contractor as applicable to this Contract.

G.26. LIENS

All materials, services, and other deliverables supplied to the City under this Contract shall be free of all liens other than the security interest. Security interest shall extinguish upon full payment made by the City. Upon the City’s request, the Contractor shall provide a formal release of all liens.

G.27. NO REPLACEMENT OF DEFECTIVE TENDER

Every tender of materials must fully comply with all provisions of this Contract. If a tender is made which does not fully comply, this shall conform to the termination clause set forth within this document.

BUSINESS SERVICES DEPARTMENT Page 19 of 27

G.28. NON-EXCLUSIVE CONTRACT

Any contract resulting from this solicitation shall be awarded with the understanding and agreement that it is for the sole convenience of the City of Tucson. The City reserves the right to obtain like goods or services from another source when necessary.

G.29. OVERCHARGES BY ANTITRUST VIOLATIONS

The City maintains that, in actual practice, overcharges resulting from antitrust violations are borne by the purchaser. Therefore, to the extent permitted by law, the Contractor hereby assigns to the City any and all claims for such overcharges as to the materials or services used to fulfill the Contract.

G.30. PAYMENT

The City’s preferred method of payment is via credit card. The City will issue a Purchase Order and, in some cases, either provide a credit card for payment at the time of ordering or pay subsequent invoices by credit card upon receipt of goods or services in good order. However, not all City employees will possess a credit card and, therefore, the City reserves the right to make payment by check as it deems necessary.

Unless payment is made by credit card at time of order or point of sale, a separate invoice shall be issued for each shipment of material or service performed, and no payment shall be issued prior to receipt of material or service and correct invoice. The invoice shall not be dated prior to the receipt of goods or completion of services.

The City shall make every effort to process payment for the purchase of materials or services within twenty-one (21) calendar days after receipt of materials or services and a correct invoice.

The Contractor's payment terms shall apply to all purchases and to all payment methods.

G.31. PREVENTION OF HEAT-RELATED ILLNESSES AND INJURIES

If Contractor’s employees or contract workers will perform work under this Contract in an outdoor environment, Contractor must have and implement a written plan listing the preventative and proactive measures that Contractor will take to protect those employees and contract workers from heat hazards (the “Heat Safety Plan”) while performing that work. The City may request a copy of this Heat Safety Plan and documentation of all heat safety and mitigation efforts currently implemented by Contractor to prevent heat-related illnesses and injuries for work done under this Contract. The Heat Safety Plan must also be posted where it is accessible to employees. At a minimum, the Heat Safety Plan must include each of the following elements as it relates to heat safety:

A. Availability of sanitized cool drinking water free of charge at locations that are accessible to all employees and contract workers.

B. Ability to take regular and necessary breaks as needed and additional breaks for hydration.

C. Access to shaded areas and/or air conditioning.

D. Access to air conditioning in vehicles with enclosed cabs.

BUSINESS SERVICES DEPARTMENT Page 20 of 27

E. Effective acclimatization practices to promote the physiological adaptation of employees or contract workers newly assigned or reassigned to work in an outside environment.

F. Training of employees and contract workers, no later than one week prior to being deployed to work in an outdoor environment, on heat illness and injury that focuses on environmental and personal risk factors, prevention, how to recognize and report signs and symptoms of heat illness and injury, how to administer appropriate first aid measures, and how to report heat illness and injury to emergency medical personnel.

G. The posting of signage at the job site that contains information, in both English and Spanish, explaining how to (a) recognize and report signs and symptoms of heat illness and injury; (b) administer appropriate first aid measures, and (c) report heat-related illness and injury to emergency medical personnel. The signage must also include a phone number for reporting heat violations to OSHA/ADOSH.

H. Providing written notification to all employees and contract workers regarding their new worker protections under this provision. This notification shall be provided to existing employees and during the onboarding process for new employees. The notification shall be provided to each worker in the language preferred by that worker and must be posted in the workplace.

Contractor will incorporate this section in all subcontracts with subcontractors or other entities or individuals who may perform work under this Contract, including the requirement that those subcontractors impose the same obligations under any sub-subcontractors. It is the obligation of Contractor to ensure compliance with this provision by its subcontractors. City may terminate this Contract for failure to comply with this provision.

G.32. PROTECTION OF GOVERNMENT PROPERTY

The Contractor shall use reasonable care to avoid damaging existing buildings, equipment, and vegetation (such as trees, shrubs, and grass) on City property. If the Contractor fails to do so and damages such property, the Contractor shall replace or repair the damage at no expense to the City, as determined and approved by the City’s Director of Business Services. If the Contractor fails or refuses to make such repair or replacement, the City will determine a cost and the Contractor shall be liable for the cost thereof, which may be deducted from the Contract price.

G.33. PROVISIONS REQUIRED BY LAW

Each and every provision of law and any clause required by law to be in the Contract shall be read and enforced as though it were included herein, and if through mistake or otherwise any such provision is not inserted, or is not correctly inserted, then upon the application of either party the Contract shall be amended to make such insertion or correction.

G.34. RECORDS

Internal control over all financial transactions related to this Contract shall be in accordance with sound fiscal policies. Contractor shall maintain books, records, documents, and other evidence directly pertinent to the performance of the Work under this Contract in accordance with generally accepted accounting principles and practices consistently applied and other applicable local, state or federal regulations.

BUSINESS SERVICES DEPARTMENT Page 21 of 27

Contractor shall, at all times during the term of this Contract and for a period of three years after the completion of this Contract, maintain such records, together with such supporting or underlying documents and materials.

Contractor shall ensure City has these rights with Contractor’s employees, agents, assigns, successors, and subcontractors, and the obligations of these rights shall be explicitly included in any subcontracts or agreements formed between the Contractor and any subcontractors to the extent that those subcontracts or agreements relate to fulfillment of the Contractor’s obligations to City.

G.35. RIGHT TO AUDIT

The City and its authorized representatives shall have the right, upon reasonable written notice to Contractor, to cause an audit to be made of the Contractor's books and records which relate to its operations under this Contract. The audit shall be limited to the term of this Contract. The City shall have the right to examine and to make copies of or extracts from all financial and related records (in whatever form they may be kept, whether written, electronic, or other) relating to or pertaining to this Contract kept by or under the control of the Contractor, including, but not limited to those kept by the Contractor, its employees, agents, assigns, successors and subcontractors. Such records shall include, but not be limited to, accounting records, subcontractor records, payment vouchers and invoices.

The Contractor shall at any time requested by City, whether during or after completion of this Contract, and at Contractor’s own expense make such records available for inspection and audit (including copies and extracts of records as required) by City. Such records shall be made available to City during normal business hours at the Contractor’s office, place of business, an agreed to location, mailed or provided electronically.

If, as a result of such audit, the Contractor is liable to the City for the payment of any sum, Contractor shall promptly pay such sum to the City together with interest thereon at the rate of one percent (1%) per month from the date such sums should have been paid. Payment shall be made within 90 days from presentation of City’s findings to Contractor.

If the audit discovers substantive findings related to fraud, misrepresentation, or non‐performance, City may recoup the costs of the audit work from the Contractor. The City's rights under this provision shall survive the expiration or termination of the Contract.

G.36. RIGHT TO ASSURANCE

Whenever one party to this Contract has reason to question, in good faith, the other party's intent to perform, the former party may demand that the other party give a written assurance of this intent to perform. In the event that a demand is made and no written assurance is given within five (5) days, the demanding party may treat this failure as the other party’s intent not to perform and as a cause for possible Contract termination.

G.37. RIGHT TO INSPECT

The City may, at reasonable times, and at the City's expense, inspect the place of business of a Contractor or subcontractor which is related to the performance of any Contract as awarded or to be awarded.

BUSINESS SERVICES DEPARTMENT Page 22 of 27

G.38. RIGHTS AND REMEDIES

No provision in this document or in the Contractor's bid shall be construed, expressly or by implication, as a waiver by either party of any existing or future right and/or remedy available by law in the event of any claim, default or breach of contract. The failure of either party to insist upon the strict performance of any term or condition of the Contract, to exercise or delay the exercise of any right or remedy provided in the Contract or by law, or to accept materials or services required by this Contract or by law shall not be deemed a waiver of any right of either party to insist upon the strict performance of the Contract.

G.39. SEVERABILITY

The provisions of this Contract are severable to the extent that any provision or application held to be invalid shall not affect any other provision or application of the Contract which may remain in effect without the valid provision or application.

G.40. SHIPMENT UNDER RESERVATION PROHIBITED

No tender of a bill of lading shall operate as a tender of the materials. Non-compliance shall conform to the termination clause set forth within this document.

G.41. SUBCONTRACTS

No subcontract shall be entered into by the Contractor with any other party to furnish any of the material/service specified herein without the advance written approval of the City's Director of Business Services. All subcontracts shall comply with Federal and State laws and regulations which are applicable to the services covered by the subcontract and shall include all the terms and conditions set forth herein which shall apply with equal force to the subcontract, as if the subcontractor were the Contractor referred to herein. The Contractor is responsible for contract performance whether or not subcontractors are used.

G.42. SUBSEQUENT EMPLOYMENT

The City may terminate this Contract without penalty or further obligation pursuant to A.R.S. Section 38-511 if any person significantly involved in initiating, negotiating, securing, drafting, or creating the Contract, on behalf of the City, is or becomes, at any time while the Contract or any extension of the Contract is in effect, an employee of, or a contractor to, any other party to this Contract with respect to the subject matter of the Contract. Termination shall be effective when written notice from the City’s Director of Business Services is received by the parties to this Contract, unless the notice specifies a later time.

G.43. TERMINATION OF CONTRACT

This Contract may be terminated at any time by mutual written consent, or by the City, with or without cause, upon giving thirty (30) days written notice. The City, at its convenience, by written notice, may terminate this Contract, in whole or in part. If this Contract is terminated, the City shall be liable only for payment under the payment provisions of this Contract for services rendered and accepted material received by the City before the effective date of termination.

BUSINESS SERVICES DEPARTMENT Page 23 of 27

The City reserves the right to terminate the whole or any part of this Contract due to the failure of the Contractor to carry out any term or condition of the Contract. The City will issue a written ten (10) day notice of default to the Contractor for acting or failing to act as specified in any of the following:

In the opinion of the City, the Contractor provides personnel that do not meet the requirements of the Contract;

• In the opinion of the City, the Contractor fails to perform adequately the stipulations, conditions or services/specifications required in this Contract;

• In the opinion of the City, the Contractor attempts to impose personnel, materials, products or workmanship of an unacceptable quality;

• The Contractor fails to furnish the required service and/or product within the time stipulated in the Contract;

• In the opinion of the City, the Contractor fails to make progress in the performance of the requirements of the Contract;

• The Contractor gives the City a positive indication that the Contractor will not or cannot perform to the requirements of the Contract.

Each payment obligation of the City created by this Contract is conditioned upon the availability of City, State and Federal funds that are appropriated or allocated for the payment of such an obligation. If funds are not allocated by the City and available for the continued purchase of the services and/or materials provided under this Contract, this Contract may be terminated by the City at the end of the period for which funds are available. The City will endeavor to notify the Contractor in the event that continued service will or may be affected by non-appropriation. No penalty shall accrue to the City in the event this provision is exercised, and the City shall not be obligated or liable for any future payments due or for any damages as a result of termination under this paragraph.

G.44. TITLE AND RISK OF LOSS

The title and risk of loss of material or service shall not pass to the City until the City actually receives the material or service at the point of delivery, unless otherwise provided within this Contract.

G.45. WAGE COMPLIANCE

Contractor shall pay their eligible employees the highest of:

A. the City of Tucson minimum wage

B. the State of Arizona minimum wage

Contractor shall cooperate with all efforts of the City of Tucson’s Labor Standards Unit (LSU) to monitor and ensure compliance with applicable labor standards to include, but not be limited to, the following:

• Providing copies of pertinent documentation upon request

• Cooperating with audits and interviews

• Abiding by deadlines and adhering to due dates for determinations and appeals filings

BUSINESS SERVICES DEPARTMENT Page 24 of 27

Contractor agrees to educate their employees on the applicable wage(s) that law requires them to minimally be paid.

All timely complaints that are received by the LSU will be evaluated in accordance with the procedures posted on the LSU’s webpage: www.tucsonaz.gov/minimumwage

G.46. WAIVER

The failure of either party of this Agreement to take affirmative action with respect to any conduct of the other which is in violation of the terms of this contract shall not be construed as a waiver thereof, or of any future breach or subsequent wrongful conduct.

G.47. WARRANTIES

Contractor warrants that all material or service delivered under this Contract shall conform to the specifications of this Contract. Mere receipt of shipment of the material or service specified and any inspection incidental thereto by the City shall not alter or affect the obligations of the Contractor or the rights of the City under the foregoing warranties. Additional warranty requirements may be set forth in this document.

G.48. WRITTEN CERTIFICATION PURSUANT TO A.R.S. §35-394

If Contractor engages in for-profit activities and has at least ten full time employees, Contractor certifies that Contractor does not currently, and agrees for the duration of the contract that it will not, use: 1) the forced labor of ethnic Uyghurs in the People’s Republic of China; 2) any goods or services produced by the forced labor of ethnic Uyghurs in the People’s Republic of China; and 3) any contractors, subcontractors or suppliers that use the forced labor or any goods or services produced by the forced labor of ethnic Uyghurs in the People’s Republic of China. If Contractor becomes aware during the term of the contract that it is not in compliance with the written certification, it must notify the City within five business days after becoming aware of the noncompliance. This Contract will be automatically terminated 180 days after the date of the notice unless Contractor has, before the end of that period, notified the City that the noncompliance has been remedied.

http://www.tucsonaz.gov/minimumwage

BUSINESS SERVICES DEPARTMENT Page 25 of 27

H. Evaluation Criteria

No. Evaluation Criteria Scoring Method Weight (Points)

1. Method of Approach A. Provide a detailed method of approach in how your firm plans to meet the requirements of each of the services outlined in the Scope of Work.

1. Approach to the installation of netting or process of any materials typically being used.

2. Process from start to finish (I.e how you will clean up and dispose, safety at work area, responsibility)

3. Please also include how your team handles the ethics and standards that come along with abatement in this service provided.

N/A N/A

2. Qualifications and Experience A. Provide a brief description and history of your firm to include the following but not limited to:

Location, years of experience, etc.

B. Provide a list of employee's that will work directly on any request work orders: Years of experience, role, any certifications or licenses your team may hold.

1. Please outline who will be the may point of contact, if awarded this contract.

C. Provide a list of previous or current references your firm has worked for in-regards to a similar Scope of Work outlined in this solicitation.

1. Any current contracts your company has or has held.

2. If no contracts apply, please provide a list of local/commercial businesses.

3. Please include: Dates, services provided, name's, title's, entity name, and best form of contact.

N/A N/A

BUSINESS SERVICES DEPARTMENT Page 26 of 27

3. Price

Provide a price proposal as request on the Price Page attached to this solicitation.

N/A N/A

BUSINESS SERVICES DEPARTMENT Page 27 of 27

OFFER AND ACCEPTANCE

OFFER

TO THE CITY OF TUCSON:

The Undersigned hereby offers and shall furnish the material or service in compliance with all terms, scope of work, conditions, specifications, and amendments in the Request for Quote which is incorporated by reference as if fully set forth herein.

For clarification of this offer, contact:

Name:

Company Name

Title:

Address

Phone:

City State Zip

Fax:

Signature of Person Authorized to Sign

E-mail:

Printed Name

Title

ACCEPTANCE OF OFFER

The Offer is hereby accepted. The Contractor is now bound to sell the materials or services specified in the Contract. This Contract shall be referred to as Contract No. ________________.

CITY OF TUCSON, a municipal corporation

Approved as to form: Awarded:

This ________ day of _______________ 20_____ This ________ day of _______________ 20_____

As Tucson City Attorney and not personally As Director of Business Services and not personally