Performance_Bond.docx

DOCX document 27 KB Posted

Attached to
Sewer Lateral Replacement Project
Solicitation number
IFB197641
Issued by
Santa Clara County, California

About this file

This is a Contractor's Performance Surety Bond template issued by the City of Palo Alto, California, for use in public improvement projects. The bond is required to ensure faithful performance of designated public works agreements and obligates both the contractor (Principal) and surety to complete the contracted work in accordance with all specifications and covenants. The bond covers the full scope of work outlined in the underlying agreement, with the penal sum amount to be determined based on the specific contract value. The surety remains liable for performance obligations regardless of any changes, extensions, or alterations made to the original agreement terms, and waives notice of such modifications per California Civil Code Sections 2845 and 2849.

The bond secures not only the principal contract amount but also encompasses liquidated damages, reasonable attorney's fees, and all costs and expenses incurred by the City in enforcing performance obligations. The surety assumes full liability for any financial penalties assessed against the contractor and indemnifies the City against claims arising from contractor default or failure to perform. The instrument requires execution by authorized representatives of both the contractor and surety, notarization per California Civil Code Section 1189, and acknowledgment of all terms before the bond becomes effective. This standard surety bond format applies to the City of Palo Alto's Sewer Lateral Replacement Project, a capital improvement program targeting replacement of 210 deteriorated public sewer laterals over a three-year construction period.

View the file

Other files

File Type Posted
Sewer_Lateral_Replacement_Project.pdf PDF
Payment_Bond.docx DOCX document
SLRP_-_Appendices.pdf PDF
SLRP_Index_&_Certification_Page.pdf PDF
utility-map-request-form.pdf PDF
Bid_Bond_Form.docx DOCX document
SLRP-_Spec_Prov.docx DOCX document
SLRP_-_Tech_Spec.pdf PDF
SLRP_Maps.pdf PDF
Construction_Contract,_General_Conditions,_and_Change_Orders.pdf PDF
SLRPBid_Table.xlsx XLSX spreadsheet
Show all 11

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

CONTRACTOR’S PERFORMANCE SURETY BOND

WHEREAS, the City Council of the City of Palo Alto, State of California (“City”) and , (“Principal”) have entered into an agreement dated , and identified as , which is hereby referred to and made a part hereof whereby Principal agrees to install and complete certain designated public improvements; and

WHEREAS, Principal is required under the terms of said agreement to furnish a surety bond for the faithful performance of said agreement.

NOW, THEREFORE, Principal and _______________________________________________, as Surety, incorporated under the Laws of the State of , and duly authorized to transact business as an admitted surety, under the Laws of the State of California, are held and firmly bound unto City in the penal sum of dollars ($ ), for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.

The condition of this obligation is such that if the Principal, Principal’s heirs, executors, administrators, successors, or assigns shall promptly and faithfully keep and perform the covenants, conditions, and provisions of the above-mentioned agreement and any alteration thereof, with or without notice to the Surety, and if Principal shall satisfy all claims and demands incurred under such agreement and shall fully protect, indemnify, defend, and hold harmless City, its officers, agents, and employees from all claims, demands, or liabilities which may arise by reason of Principal’s failure to do so, and shall reimburse and repay City all outlay and expenses which City may incur in making good any default, then this obligation shall be null and void; otherwise, it shall remain in full force and effect.

As part of the obligations secured hereto, and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney’s fees incurred by City in successfully enforcing such obligations, all to be taxed as costs and included in any judgment rendered. Surety shall be liable for any liquidated damages for which the Principal may be liable under its agreement with the City, and such liquidated damages shall be part of the obligations secured hereto, and in addition to the face amount specified therefore.

The Surety hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same, shall in any way affect its obligations on this security, and it does hereby waive notice of any such change, extension of time, alteration, or addition to the terms of the agreement or to the work or to the specifications. Surety hereby waives the provisions of California Civil Code Section 2845 and 2849. The City is the principal beneficiary of this bond and has all rights of a party hereto.

IN WITNESS WHEREOF, this instrument has been duly executed by the Principal Surety above named on _______________, 20_____.

_______________ Phone Number: ______ Name of Surety

Signature of Surety

By:Its:
Typed or Printed NameTitle

Name of Contractor/Principal

Signature of Contractor/Principal

By:Its:
Typed or Printed NameTitle

CERTIFICATE OF ACKNOWLEDGMENT

(Civil Code § 1189) A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document

STATE OF)
COUNTY OF)
On, before me,, a notary public in and for said County, personally appeared, who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under penalty of perjury under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

(Seal)

File details come from the government source that posted it. Updated .