Payment_Bond_-_City_Facilities_Remodel_and_Expansion_CMAR_Project_at_820_Ferris_Ave_and_401_S_Rogers.pdf
PDF 201 KB Posted
- Solicitation number
- RFP - 2026 - 2 -1
- Issued by
- Ellis County, Texas
About this file
This is a Payment Bond form for the City of Waxahachie, Texas, related to the City Facilities Remodel and Expansion Construction Manager at Risk (CMAR) Project at 820 Ferris Avenue and 401 S. Rogers Street. The payment bond is executed in five originals and is dated February 4, 2026. The bond serves as a guarantee that the principal contractor will pay all claimants, including laborers and material suppliers, who contribute to the prosecution of work under the construction contract. The bond is issued pursuant to V.T.C.A. Government Code Chapter 2253 and establishes joint and several liability between the principal and the surety company authorized to act under Texas law.
The payment bond includes standard provisions that protect claimants' rights while preserving the surety's obligations regardless of any modifications to the underlying contract terms, including changes, time extensions, alterations, or additions to the work, plans, specifications, or drawings. The bond requires identification of the principal contractor, the surety company with its resident agent information, and signatures from authorized representatives of both parties. The penal sum amount, bond number, execution date, and specific contract date are left blank on the form, indicating this is a template to be completed upon finalization of the CMAR contract between the City of Waxahachie and the selected contractor.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
2/4/26 Payment Bond
PAYMENT BOND
STATE OF TEXAS § BOND NO. ___________
COUNTY OF _____Ellis_____ § BOND EXECUTED IN FIVE (5) ORIGINALS
KNOW ALL MEN BY THESE PRESENT: That _ _ of the City of
_______________, County of _________________, State of ________ _______, as principal, and
________________________________, authorized under the laws of the State of Texas to act as surety on bonds for principals, are held and firmly bound unto the City of Waxahachie, Texas
(Owner), in penal sum of ( ) for the payment whereof, the said Principal and Surety themselves and their heirs, administrators, executors, successors, and assigns, jointly and severally, by these presents:
WHEREAS, the Principal has entered into a certain written contract with the Owner, dated the ____ day of ____________, 2_____, to construct the
(RFP – 2026 -2 – 1 City Facilities Remodel and Expansion CMAR Project at 820 Ferris Ave and 401 S Rogers) which contract is hereby referred to and made a part hereof as fully and to the same extent as if copied at length herein.
NOW, THEREFORE, THE CONDITIONS OF THIS OBLIGATION ARE SUCH, that if the said Principal shall pay all claimants supplying labor and material to him or a subcontractor in the prosecution of the work provided for in said contract, then this obligation shall be void;
otherwise to remain in full force and effect;
PROVIDED, HOWEVER, that this bond is executed pursuant to the provision of V.T.C.A., Government Code Chapter 2253 as amended and all liabilities on this bond shall be determined in accordance with the provisions of said Chapter to the same extent as if it were copied at length herein.
Surety, for value received, stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the work performed thereunder, or the plans, specifications, or drawings accompanying the same, shall in anyway affect its obligation on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition tot the terms of the contract, or to the work to be performed thereunder.
2/4/26 Payment Bond
IN WITNESS WHEREOF, the said Principal and Surety have signed and sealed this instrument this _____ day of ______________________, 2_____.
Principal Surety
By _______________________________ By _______________________________
Title ______________________________ Title ______________________________
Address ___________________________ Address ____________________________
The Resident Agent of Surety is:
__________________________________ Name
__________________________________ Address
__________________________________ Telephone Number
(Accompany this bond with attorney-in-fact’s authority from the Surety company certified to include the date of the bond.)
File details come from the government source that posted it. Updated .