Past_Performance_Survey.pdf

PDF 25 KB Posted

Attached to
Well Redevelopment & Decommissioning - VT
Solicitation number
140FC225R0002
Issued by

About this file

This document is a Past or Present Performance Survey. It requests the respondent to provide information on up to three completed or in-progress contracts, including the contracting agency, contract details, their role, and any quality control or safety issues encountered. The purpose is to allow the respondent to demonstrate their past performance and experience.

The related federal contract opportunity is for Well Redevelopment & Decommissioning services for the Department of the Interior Fish and Wildlife Service. This appears to be an amendment to a solicitation, with no further details provided on the specific products, services, or requirements.

View the file

Other files

File Type Posted
Provisions___Clauses_0001.pdf PDF
Sol_140FC225R0002_Amd_0001.pdf PDF
Photos.pdf PDF
A04_Scope_current.pdf PDF
B08_Bid_Shedule.pdf PDF
Sol_140FC225R0002.pdf PDF
B03_Wages.pdf PDF

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

PAST OR PRESENT PERFORMANCE SURVEY

Your Company Name:

Street Address:

City, State and ZIP Code:

1. GENERAL BUSINESS INFORMATION

Date Firm Organized/Established:

Company President: Vice President:

SAM.gov Unique Entity ID: ___________________

Is company a ; Partnership [ ] Separate entity [ ] Division [ ] N/A [ ]

2. CONTRACTS/SUBCONTRACTS COMPLETED OR IN PROGRESS

Complete and submit the information requested on page 2-4 below on prime contracts or subcontracts completed or in progress. Government contracts are preferred; but, if you have not performed Government contracts, indicate any other contracts completed or in progress.

a. First Contract:

Contracting Agency or Company:

Point of Contact: Telephone Number:

Contract Number: Contract/Subcontract Amount: $ _____

Project Title and Location:

General Scope of Project:

Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:

Describe any Work You Subcontracted to Others:

Total Amount of Subcontract(s): $

Period of Performance: days

Scheduled Completion Date:

Actual Completion Date: Percentage of Work Completed: %

Were You Terminated?

Did you use a Quality Control Plan? _________ Did you use a Safety Plan?_______________

Quality Control or Safety Problems encountered (if any):

How were the problems resolved?

b. Second Contract:

Point of Contact: Telephone Number:

Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:

Scheduled Completion Date:

Actual Completion Date: Percentage of Work Completed: %

c. Third Contract:

Point of Contact: Telephone Number:

Your Role (Prime [ ], Joint Venture [ ], or Subcontractor [ ]) and the work your firm performed:

Scheduled Completion Date:

Actual Completion Date: Percentage of Work Completed: %

4. Certification of Past Performance Information:

Type or Print Information

Name of Survey Preparer _______________________________Phone:_________________

E-Mail;___________________________

Title__________________________________________

Signature______________________________________

Date__________________________________________

File details come from the government source that posted it. Updated .