N69450-21-Q-1525 RFQ.pdf

PWD WHITING FIELD

INSPECTOR OF RECORD

7183 LANGLEY ST, BLDG 1416

MILTON FL 32570-6105

TEL: 850-623-7024 FAX:

ACQR5825779

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

DO-C2N6945021Q1525 22-Oct-2020 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

NAVFAC SOUTHEAST

PWD WHITING FIELD

7183 LANGLEY STREET

MILTON FL 32570-6159

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

23-Nov-2020(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

850-623-7435WILLIAM A. HILLIARD

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

N6945021Q1525

Section 00010 - Solicitation Contract Form

INFORMATION AND INSTRUCTIONS

GENERAL INFORMATION

This solicitation may result in the award of a Firm-Fixed Price (FFP) contract for South Field sidewalk improvements at NAS Whiting Field FL. Offers shall have a minimum acceptance period of 120 days from the due date for proposals.

The contractor shall provide all labor, materials, equipment, supervision and any other work necessary to provide South Field sidewalk improvements complete and ready for use. The work shall be accomplished using commercial grade products and materials and installed in accordance with all applicable Federal, State, and local codes and ordinances. The primary purpose of this project is to enhance the pedestrian pathways around the new Simulator Building (B.3200). The work shall include construction of new sidewalks, new pedestrian marked crossings and pedestrian crossing signs. The new pedestrian crossing signs shall be complete with solar powered flashing lights.

The project will involve demolition and construction, crosswalk markings and signage, traffic maintenance plan, and tree removal and planting.

OFFERORS ARE ADVISED THAT FUNDING MAY NOT BECOME AVAILABLE. IF FUNDS ARE NOT

AVAILABLE, NO AWARD WILL BE MADE AS A RESULT OF THIS SOLICITATION. OFFERORS

WILL NOT BE REIMBURSED FOR ANY EFFORT OR PROPOSAL COSTS RESULTING FROM THIS

SOLICITATION.

This procurement is set aside 100% for 8(a) small business contractors. A current 8(a) certification letter from the SBA must be submitted with the proposal to verify 8(a) status.

The NAICS for this procurement is 236220.

The size standard is $39,500,000.

The dollar magnitude of this construction project is between $100,000 and $250,000.

The time for completion is 180 calendar days from date of award.

The DPAS rating (15 CFR 350) is DO-C2

Performance and payment bonds are required, as well as proper certificate of insurance, within 10 days after contract award.

An organized site visit has been scheduled for 9 Nov 2020 at 0900 local (CST). The site visit will be held at NAS Whiting Field. Please see clause 52.236-27 for additional details. An access request roster is attached to this solicitation.

All Pre-Proposal Inquiries (PPIs) shall be submitted no later than 10 days prior to the due date for proposals to william.a.hilliard@navy.mil and brent.m.pittman@navy.mil. Any PPIs submitted after that date may not receive a response. A PPI request is attached to this solicitation.

Per FAR clause 52.219-14, Limitations on Subcontracting, the offeror/prime contractor must perform at least 15% of the cost of the contract, not including the cost of materials. The 15% must be performed by onsite workers.

GENERAL INSTRUCTIONS

Please read this solicitation and all associated documents in their entirety before submitting a proposal. The following documentation is due with the proposal prior to the due date/time for proposals. Failure to submit any of the items may result in the offer not being accepted/evaluated.

1. One signed copy of the SF-18 with lump sum price for each CLIN.

2. One signed copy of any/each amendment issued for this solicitation.

3. All Representations & Certifications required by Section 00700 of this solicitation.

4. Current 8(a) certification letter from SBA.

5. Electronic copy of Bid Bond (SF-24) for at least 20% of the proposd price.

6. VETS-4212 registration (or statement that offeror is not required to submit a report).

The due date/time for proposals is no later than 23 Nov 2020 at 1400 local (CST).

Proposals must be received by electronic mail (e-mail) no later than the stated due date/time. Hard copies will not be accepted. Electronic proposals shall be e-mailed to william.a.hilliard@navy.mil and contain “N69450-21-Q- 1525” in the subject line. Late proposals may not be accepted/evaluated. Proposals are highly advised to be submitted at least one day prior to avoid late submission.

The basis of contract award will be lowest price to a responsible contractor. Familiarity and understanding of Government contracts is strongly desired, especially regarding the submittal process and performing work on Government installations. The Government will evaluate price based on the total price of all CLINs. The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer later determines it to be necessary.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each Sidewalk Improvements NASWF

FFP

The contractor shall provide all labor, material, equipment, supervision, and other incidental work required to complete necessary sidewalk improvements at NAS Whiting Field, FL.

FOB: Destination

PURCHASE REQUEST NUMBER: ACQR5825779

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 180 dys. ADC 1 PWD WHITING FIELD

INSPECTOR OF RECORD

7183 LANGLEY ST, BLDG 1416

MILTON FL 32570-6105

850-623-7024 FOB: Destination

N44260

Section 00700 - Contract Clauses

52.222-99 52.222-99, Establishing a Minimum Wage for Contractors. (DEVIATION)

The contracting officer shall insert the following clause in solicitations and resultant contracts that include the FAR clause 52.222-6 and/or 52.222-41, and work is to be performed in whole or in part in the United States (the 50 States and the District of Columbia).

ESTABLISHING A MINIMUM WAGE FOR CONTRACTORS

(DEVIATION 2014-O0017) (JUNE 2014)

This clause implements Executive Order 13658, Establishing a Minimum Wage for Contractors, dated February 12, 2014, and OMB Policy Memorandum M-14-09, dated June 12, 2014.

(a) Each service employee, laborer, or mechanic employed in the United States (the 50 States and the District of Columbia) in the performance of this contract by the prime Contractor or any subcontractor, regardless of any contractual relationship which may be alleged to exist between the Contractor and service employee, laborer, or mechanic, shall be paid not less than the applicable minimum wage under Executive Order 13658. The minimum wage required to be paid to each service employee, laborer, or mechanic performing work on this contract between January 1, 2015, and December 31, 2015, shall be $10.10 per hour.

(b) The Contractor shall adjust the minimum wage paid under this contract each time the Secretary of Labor’s annual determination of the applicable minimum wage under section 2(a)(ii) of Executive Order 13658 results in a higher minimum wage. Adjustments to the Executive Order minimum wage under section 2(a)(ii) of Executive Order 13658 will be effective for all service employees, laborers, or mechanics subject to the Executive Order beginning January 1 of the following year. The Secretary of Labor will publish annual determinations in the Federal Register no later than 90 days before such new wage is to take effect. The Secretary will also publish the applicable minimum wage on www.wdol.gov (or any successor website). The applicable published minimum wage is incorporated by reference into this contract.

(c) The Contracting Officer will adjust the contract price or contract unit price under this clause only for the increase in labor costs resulting from the annual inflation increases in the Executive Order 13658 minimum wage beginning on January 1, 2016. The Contracting Officer shall consider documentation as to the specific costs and workers impacted in determining the amount of the adjustment.

(d) The Contractor Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (c) of this clause, and will not provide price adjustments under this clause that result in duplicate price adjustments with the respective clause of this contract implementing the Service Contract Labor Standards statute (formerly known as the Service Contract Act) or the Wage Rate Requirements (Construction) statute (formerly known as the Davis Bacon Act).

(e) The Contractor shall include the substance of this clause, including this paragraph (e) in all subcontracts.

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-14 Display of Hotline Poster(s) OCT 2015 52.203-15 Whistleblower Protections Under the American Recovery and

Reinvestment Act of 2009

JUN 2010

52.203-16 Preventing Personal Conflicts of Interest DEC 2011 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-2 Security Requirements AUG 1996 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.204-14 Service Contract Reporting Requirements OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-13 Violation of Arms Control Treaties or Agreements -- Certification.

JUN 2018

52.211-5 Material Requirements AUG 2000 52.211-6 Brand Name or Equal AUG 1999 52.211-13 Time Extensions SEP 2000 52.211-14 Notice Of Priority Rating For National Defense, Emergency

Preparedness, and Energy Program Use

APR 2008

52.211-15 Defense Priority And Allocation Requirements APR 2008 52.213-4 Terms and Conditions--Simplified Acquisitions (Other Than

Commercial Items)

AUG 2020

52.215-2 Audit and Records--Negotiation OCT 2010 52.215-5 Facsimile Proposals OCT 1997 52.215-6 Place of Performance OCT 1997 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-12 Subcontractor Certified Cost or Pricing Data OCT 2010 52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications OCT 2010 52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997 52.215-20 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data

OCT 2010

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.219-6 Notice Of Total Small Business Set-Aside MAR 2020 52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-14 Limitations On Subcontracting MAR 2020 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.219-28 Post-Award Small Business Program Rerepresentation MAR 2020 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-22 Previous Contracts And Compliance Reports FEB 1999 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-25 Affirmative Action Compliance APR 1984 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method)

AUG 2018

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-46 Evaluation Of Compensation For Professional Employees FEB 1993 52.222-50 Combating Trafficking in Persons JAN 2019 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

JUN 2016

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners.

JUN 2016

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-16 Acquisition of EPEAT (R) - Registered Personal Computer

Products

OCT 2015

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-5 Trade Agreements OCT 2019 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

AUG 2018

52.226-1 Utilization Of Indian Organizations And Indian-Owned Economic Enterprises

JUN 2000

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-13 Alternative Payment Protections JUL 2000 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.229-4 Federal, State, And Local Taxes (State and Local

Adjustments)

FEB 2013

52.230-3 Disclosure And Consistency Of Cost Accounting Practices OCT 2015 52.232-1 Payments APR 1984 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-8 Discounts For Prompt Payment FEB 2002 52.232-9 Limitation On Withholding Of Payments APR 1984 52.232-11 Extras APR 1984 52.232-16 Progress Payments APR 2012 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-25 Prompt Payment JAN 2017 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-28 Invitation to Propose Performance-Based Payments MAR 2000

52.232-33 Payment by Electronic Funds Transfer--System for Award Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.234-1 Industrial Resources Developed Under Title III, Defense

Production Act

SEP 2016

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-23 Responsibility of the Architect-Engineer Contractor APR 1984 52.236-24 Work Oversight in Architect-Engineer Contracts APR 1984 52.236-25 Requirements for Registration of Designers JUN 2003 52.236-26 Preconstruction Conference FEB 1995 52.236-28 Preparation of Proposals--Construction OCT 1997 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Items AUG 2019 52.246-12 Inspection of Construction AUG 1996 52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

52.246-21 Warranty of Construction MAR 1994 52.247-6 Financial Statement APR 1984 52.247-34 F.O.B. Destination NOV 1991 52.247-64 Preference for Privately Owned U.S. - Flag Commercial

Vessels

FEB 2006

52.248-3 Value Engineering-Construction OCT 2015 52.249-1 Alt I Termination for Convenience of the Government (Fixed-price) (Short Form) (Apr 1984) - Alternate I

APR 1984

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Alt I Default (Fixed-Price Construction) (Apr 1984) Alternate I APR 1984

52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions OCT 2005 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.213-7000 Notice to Prospective Suppliers on Use of Supplier Performance Risk System in Past Performance Evaluations

SEP 2019

252.215-7002 Cost Estimating System Requirements DEC 2012 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7016 Restriction On Acquisition Of Ball and Roller Bearings JUN 2011 252.225-7017 Photovoltaic Devices JAN 2020 252.225-7021 Trade Agreements--Basic SEP 2019 252.225-7030 Restriction On Acquisition Of Carbon, Alloy, And Armor

Steel Plate

DEC 2006

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005 252.225-7048 Export-Controlled Items JUN 2013 252.225-7050 Disclosure of Ownership or Control by the Government of a

Country that is a State Sponsor of Terrorism

DEC 2018

252.225-7993 (Dev) Prohibition on Providing Funds to the Enemy (Deviation 2020-O0001)

NOV 2019

252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.229-7000 Invoices Exclusive of Taxes or Duties JUN 1997 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7005 Airfield Safety Precautions DEC 1991

252.236-7006 Cost Limitation JAN 1997 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (AUG 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in the provision at 52.204-26, Covered Telecommunications Equipment or Services--Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ] will, [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ] does, [ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (DEC

2019)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representation. The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative…